Acceptance of the Contractor Estimate Sample Clauses

Acceptance of the Contractor Estimate. If the Agency accepts the cost proposal presented by the Contractor, the Contractor shall provide the modified Deliverable subject to the cost proposal included in the Contractor response. The Contractor’s provision of the modified Deliverables shall be governed by the terms and conditions of this Contract.
Sample 1Sample 2Sample 3See All (21)
AutoNDA by SimpleDocs
Acceptance of the Contractor Estimate. If DNR accepts the estimate presented by the Contractor within five business days of receiving the Contractor’s response, the Contractor shall perform the modified services subject to the time and cost estimates included in the Contractor response. The Contractor’s performance and the modified services shall be governed by the terms and conditions of this Contract.
Sample 1Sample 2Sample 3
Acceptance of the Contractor Estimate. If DNR accepts the time estimate and estimated budget presented by the Contractor within five business days of receiving the Contractor’s response, then the parties may amend the Contract, and the Contractor shall agree to perform the modified services subject to the time estimate and estimated budget included in the Contractor response. The parties shall agree to a beginning date for the Amendment. The Contractor shall not begin work prior to the time an Amendment is signed by both parties.
Sample 1Sample 2Sample 3
Acceptance of the Contractor Estimate. If the County accepts the cost proposal presented by the Contractor, the Contractor shall provide the modified Deliverable subject to the cost proposal included in the Contractor response. The Contractor’s provision of the modified deliverables shall be governed by the terms and conditions of this Contract.
Sample 1Sample 2Sample 3
Acceptance of the Contractor Estimate. If the Agency accepts the estimate presented by the Contractor within five (5) business days of receiving the Contractor’s response, the Contractor shall perform the modified services subject to the time and cost estimates included in the Contractor response. The Contractor’s performance and the modified services shall be governed by the terms and conditions of this Contract. Allowing five (5) business days is only a suggestion. Adjust the number of days as necessary to fit your circumstances.
Sample 1

Related to Acceptance of the Contractor Estimate

  • PERFORMANCE OF THE CONTRACT II.1.1. The Contractor shall perform the Contract to the highest professional standards. The Contractor shall have sole responsibility for complying with any legal obligations incumbent on him, notably those resulting from employment, tax and social legislation. II.1.2. The Contractor shall have sole responsibility for taking the necessary steps to obtain any permit or licence required for performance of the Contract under the laws and regulations in force at the place where the tasks assigned to him are to be executed. II.1.3. Without prejudice to Article II.3 any reference made to the Contractor’s staff in the Contract shall relate exclusively to individuals involved in the performance of the Contract. II.1.4. The Contractor must ensure that any staff performing the Contract have the professional qualifications and experience required for the execution of the tasks assigned to them. II.1.5. The Contractor shall neither represent the Agency nor behave in any way that would give such an impression. The Contractor shall inform third parties that he does not belong to the European public service. II.1.6. The Contractor shall have sole responsibility for the staff who execute the tasks assigned to him. II.1.7. In the event of disruption resulting from the action of a member of the Contractor's staff working on Agency premises or in the event of the expertise of a member of the Contractor's staff failing to correspond to the profile required by the Contract, the Contractor shall replace him without delay. The Agency shall have the right to request the replacement of any such member of staff, stating its reasons for so doing. Replacement staff must have the necessary qualifications and be capable of performing the Contract under the same contractual conditions. The Contractor shall be responsible for any delay in the execution of the tasks assigned to him resulting from the replacement of staff in accordance with this Article. II.1.8. Should any unforeseen event, action or omission directly or indirectly hamper execution of the tasks, either partially or totally, the Contractor shall immediately and on his own initiative record it and report it to the Agency. The report shall include a description of the problem and an indication of the date on which it started and of the remedial action taken by the Contractor to ensure full compliance with his obligations under the Contract. In such event the Contractor shall give priority to solving the problem rather than determining liability. II.1.9. Should the Contractor fail to perform his obligations under the Contract in accordance with the provisions laid down therein, the Agency may - without prejudice to its right to terminate the Contract - reduce or recover payments in proportion to the scale of the failure. In addition, the Agency may impose penalties or liquidated damages provided for in Article II.16.

  • CONTRACT COMPLETE This Contract represents the complete agreement between the parties. No other understanding regarding this Contract, whether written or oral, may be used to bind either party. For any conflict between the attached Proposal and the terms set out in Articles 1-22 of this Contract, the terms of Articles 1-22 will govern.

  • Claim by Contractor After receipt of the Notice of Termination from the state, the Contractor shall submit any claim for additional costs not covered herein or elsewhere in the Contract within 60 days of the effective termination date, and not thereafter. Should the Contractor fail to submit a claim within the 60-day period, the State may, at its sole discretion, based on information available to it, determine what, if any, compensation is due the Contractor and pay the Contractor the determined amount.

  • APPLICABILITY TO SUBCONTRACTORS Respondent agrees that all contracts it awards pursuant to the contract awarded as a result of this Agreement will be bound by the foregoing terms and conditions.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!