Maintenance of Hazard Insurance; Maintenance of Primary Insurance Policies (a) The Master Servicer shall maintain, for each Mortgage Loan, hazard insurance with extended coverage in an amount that is at least equal to the lesser of
(i) the maximum insurable value of the improvements securing the Mortgage Loan and
(ii) the greater of (y) the outstanding principal balance of the Mortgage Loan and (z) an amount such that the proceeds of the policy are sufficient to prevent the Mortgagor or the mortgagee from becoming a co-insurer. Each policy of standard hazard insurance shall contain, or have an accompanying endorsement that contains, a standard mortgagee clause. Any amounts collected under the policies (other than the amounts to be applied to the restoration or repair of the related Mortgaged Property or amounts released to the Mortgagor in accordance with the Master Servicer's normal servicing procedures) shall be deposited in the Certificate Account. Any cost incurred in maintaining any insurance shall not, for the purpose of calculating monthly distributions to the Certificateholders or remittances to the Trustee for their benefit, be added to the principal balance of the Mortgage Loan, notwithstanding that the Mortgage Loan so permits. Such costs shall be recoverable by the Master Servicer out of late payments by the related Mortgagor or out of Liquidation Proceeds to the extent permitted by Section 3.09. No earthquake or other additional insurance is to be required of any Mortgagor or maintained on property acquired in respect of a Mortgage other than pursuant to any applicable laws and regulations in force that require additional insurance. If the Mortgaged Property is located at the time of origination of the Mortgage Loan in a federally designated special flood hazard area and the area is participating in the national flood insurance program, the Master Servicer shall maintain flood insurance for the Mortgage Loan. The flood insurance shall be in an amount equal to the least of (i) the original principal balance of the related Mortgage Loan, (ii) the replacement value of the improvements that are part of the Mortgaged Property, and (iii) the maximum amount of flood insurance available for the related Mortgaged Property under the national flood insurance program. If the Master Servicer obtains and maintains a blanket policy insuring against hazard losses on all of the Mortgage Loans, it shall have satisfied its obligations in the first sentence of this Section 3.10. The policy may contain a deductible clause on terms substantially equivalent to those commercially available and maintained by comparable servicers. If the policy contains a deductible clause and a policy complying with the first sentence of this Section 3.10 has not been maintained on the related Mortgaged Property, and if a loss that would have been covered by the required policy occurs, the Master Servicer shall deposit in the Certificate Account, without any right of reimbursement, the amount not otherwise payable under the blanket policy because of the deductible clause. In connection with its activities as Master Servicer of the Mortgage Loans, the Master Servicer agrees to present, on behalf of itself, the Depositor, and the Trustee for the benefit of the Certificateholders, claims under any blanket policy.
(b) The Master Servicer shall not take any action that would result in non-coverage under any applicable Primary Insurance Policy of any loss that, but for the actions of the Master Servicer, would have been covered thereunder. The Master Servicer shall not cancel or refuse to renew any Primary Insurance Policy that is in effect at the date of the initial issuance of the Certificates and is required to be kept in force hereunder unless the replacement Primary Insurance Policy for the canceled or non-renewed policy is maintained with a Qualified Insurer. The Master Servicer need not maintain any Primary Insurance Policy if maintaining the Primary Insurance Policy is prohibited by applicable law. The Master Servicer agrees, to the extent permitted by applicable law, to effect the timely payment of the premiums on each Primary Insurance Policy, and any costs not otherwise recoverable shall be recoverable by the Master Servicer from the related liquidation proceeds. In connection with its activities as Master Servicer of the Mortgage Loans, the Master Servicer agrees to present, on behalf of itself, the Trustee and the Certificateholders, claims to the insurer under any Primary Insurance Policies and, in this regard, to take any reasonable action in accordance with the Servicing Standard necessary to permit recovery under any Primary Insurance Policies respecting defaulted Mortgage Loans. Any amounts collected by the Master Servicer under any Primary Insurance Policies shall be deposited in the Certificate Account or the Collection Account (as applicable).
Account Maintenance Trade Allocations Trade Reporting; (Futures) Daily Trade Checkout Daily Statement Reconciliation
Maintenance of Primary Insurance Policies; Collections Thereunder The Master Servicer shall use commercially reasonable efforts to keep, and to cause the Servicers to keep, in full force and effect each Primary Insurance Policy (except any Special Primary Insurance Policy) required with respect to a Mortgage Loan, in the manner set forth in the applicable Selling and Servicing Contract, until no longer required, and the Master Servicer shall use commercially reasonable efforts to keep in full force and effect each Special Primary Insurance Policy, if any. Notwithstanding the foregoing, the Master Servicer shall have no obligation to maintain any Primary Insurance Policy for a Mortgage Loan for which the outstanding Principal Balance thereof at any time subsequent to origination was 80% or less of the Appraised Value of the related Mortgaged Property, unless required by applicable law. Unless required by applicable law, the Master Servicer shall not cancel or refuse to renew, or allow any Servicer under its supervision to cancel or refuse to renew, any Primary Insurance Policy in effect at the date of the initial issuance of the Certificates that is required to be kept in force hereunder; provided, however, that neither the Master Servicer nor any Servicer shall advance funds for the payment of any premium due under (i) any Primary Insurance Policy (other than a Special Primary Insurance Policy) if it shall determine that such an advance would be a Nonrecoverable Advance or (ii) any Special Primary Insurance Policy.
Construction Administration Phase Delete the following paragraph if Submittal Exchange isn’t going to be used: 2.
Shareholder Account Maintenance (a) Maintain all shareholder records for each account in the Company.
(b) Issue customer statements on scheduled cycle, providing duplicate second and third party copies if required.
(c) Record shareholder account information changes.
(d) Maintain account documentation files for each shareholder.
Operation and Maintenance Manuals Receipts for transmittal of Operation and Maintenance Manuals, Brochures and Data to the Design Professional (or Commissioning Agent) as required by Section 6.1.1.5.
Maintenance of the Primary Insurance Policies; Collections Thereunder (a) The Master Servicer shall not take, or permit any Subservicer to take, any action which would result in non-coverage under any applicable Primary Insurance Policy of any loss which, but for the actions of the Master Servicer or Subservicer, would have been covered thereunder. To the extent coverage is available, the Master Servicer shall keep or cause to be kept in full force and effect each such Primary Insurance Policy until the principal balance of the related Mortgage Loan secured by a Mortgaged Property is reduced to 80% or less of the Appraised Value in the case of such a Mortgage Loan having a Loan-to-Value Ratio at origination in excess of 80%, provided that such Primary Insurance Policy was in place as of the Cut-off Date and the Company had knowledge of such Primary Insurance Policy. The Master Servicer shall be entitled to cancel or permit the discontinuation of any Primary Insurance Policy as to any Mortgage Loan, if the Stated Principal Balance of the Mortgage Loan is reduced below an amount equal to 80% of the appraised value of the related Mortgaged Property as determined in any appraisal thereof after the Closing Date, or if the Loan-to-Value Ratio is reduced below 80% as a result of principal payments on the Mortgage Loan after the Closing Date. In the event that the Company gains knowledge that as of the Closing Date, a Mortgage Loan had a Loan-to-Value Ratio at origination in excess of 80% and is not the subject of a Primary Insurance Policy (and was not included in any exception to the representation in Section 2.03(b)(iv)) and that such Mortgage Loan has a current Loan-to-Value Ratio in excess of 80% then the Master Servicer shall use its reasonable efforts to obtain and maintain a Primary Insurance Policy to the extent that such a policy is obtainable at a reasonable price. The Master Servicer shall not cancel or refuse to renew any such Primary Insurance Policy applicable to a Nonsubserviced Mortgage Loan, or consent to any Subservicer canceling or refusing to renew any such Primary Insurance Policy applicable to a Mortgage Loan subserviced by it, that is in effect at the date of the initial issuance of the Certificates and is required to be kept in force hereunder unless the replacement Primary Insurance Policy for such canceled or non-renewed policy is maintained with an insurer whose claims-paying ability is acceptable to each Rating Agency for mortgage pass-through certificates having a rating equal to or better than the lower of the then-current rating or the rating assigned to the Certificates as of the Closing Date by such Rating Agency.
(b) In connection with its activities as administrator and servicer of the Mortgage Loans, the Master Servicer agrees to present or to cause the related Subservicer to present, on behalf of the Master Servicer, the Subservicer, if any, the Trustee and Certificateholders, claims to the related Insurer under any Primary Insurance Policies, in a timely manner in accordance with such policies, and, in this regard, to take or cause to be taken such reasonable action as shall be necessary to permit recovery under any Primary Insurance Policies respecting defaulted Mortgage Loans. Pursuant to Section 3.07, any Insurance Proceeds collected by or remitted to the Master Servicer under any Primary Insurance Policies shall be deposited in the Custodial Account, subject to withdrawal pursuant to Section 3.10.
Maintenance of Mortgage Impairment Insurance In the event that the Company shall obtain and maintain a blanket policy insuring against losses arising from fire and hazards covered under extended coverage on all of the Mortgage Loans, then, to the extent such policy provides coverage in an amount equal to the amount required pursuant to Section 4.10 and otherwise complies with all other requirements of Section 4.10, it shall conclusively be deemed to have satisfied its obligations as set forth in Section 4.10. Any amounts collected by the Company under any such policy relating to a Mortgage Loan shall be deposited in the Custodial Account subject to withdrawal pursuant to Section 4.05. Such policy may contain a deductible clause, in which case, in the event that there shall not have been maintained on the related Mortgaged Property a policy complying with Section 4.10, and there shall have been a loss which would have been covered by such policy, the Company shall deposit in the Custodial Account at the time of such loss the amount not otherwise payable under the blanket policy because of such deductible clause, such amount to deposited from the Company's funds, without reimbursement therefor. Upon request of any Purchaser, the Company shall cause to be delivered to such Purchaser a certified true copy of such policy and a statement from the insurer thereunder that such policy shall in no event be terminated or materially modified without 30 days' prior written notice to such Purchaser.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Operation and Maintenance 17.1 O&M obligations of the Concessionaire
17.1.1 During the Operation Period, the Concessionaire shall operate and maintain the Bus Terminal in accordance with this Agreement either by itself, or through the O&M Contractor and if required, modify, repair or otherwise make improvements to the Bus Terminal to comply with the provisions of this Agreement, Applicable Laws and Applicable Permits, and conform to Specifications and Standards and Good Industry Practice. The obligations of the Concessionaire hereunder shall include:
(a) permitting safe, smooth and uninterrupted flow of traffic on the Bus Terminal during normal operating conditions. Buses of other state road transport corporations shall be parked inside the Bus Terminal for which no charges shall be payable to the Concessionaire and if any charges are applicable for such parking then it shall be realized by Authority only;
(b) minimising incidents affecting the safety and use of the Bus Terminal by providing a rapid and effective response and maintaining liaison with emergency services of the State;
(c) carrying out periodic preventive maintenance of the Bus Terminal;
(d) undertaking routine maintenance including prompt repairs of ticket counters, Workshops, Authority's Office and other infrastructure as mentioned in the Operation and Maintenance Schedule;
(e) undertaking major maintenance such as per the Maintenance Schedule of the major infrastructure in the Bus Terminal;
(f) preventing, with the assistance of the concerned law enforcement agencies, any encroachments on the Bus Terminal;
(g) protection of the environment and provision of equipment and materials therefor;
(h) operation and maintenance of all communication, control and administrative systems necessary for the efficient operation of the Bus Terminal;
(i) maintaining a public relations unit to interface with and attend to suggestions from the Users, passengers, government agencies, media and other agencies;
(j) complying with Safety Requirements in accordance with Article 18;
(k) operation and maintenance of all Project Assets diligently and efficiently and in accordance with Good Industry Practice;
(l) maintaining punctuality and reliability in operating the Bus Terminal; and
(m) maintaining a high standard of cleanliness and hygiene in the Bus Terminal.
17.1.2 The Concessionaire shall remove promptly from the Bus Terminal all surplus construction machinery and materials, waste materials (including hazardous materials and waste water), rubbish and other debris (including, without limitation, accident debris) and keep the Bus Terminal in a clean, tidy and orderly condition,
