Additional Responsibilities This paragraph applies to all phases of Architect's work.
(a) Architect shall be responsible for the professional quality, technical accuracy, timely completion and coordination of all of Architect's work, including that performed by Architect's consultants, and including designs, Drawings, Specifications, reports and other services, irrespective of Owner's approval or acquiescence in same. Architect shall, without additional compensation, correct or revise any errors, omissions or other deficiencies in his work.
(b) Architect shall be responsible, in accordance with applicable law, to Owner for all loss or damage to Owner caused by Architect's negligent act or omission; except that Architect hereby irrevocably waives and excuses Owner and its attorneys from compliance with any requirement to obtain a certificate of review as a condition precedent to commencement of an action, including any such requirements set forth in Section 00-00-000, C.R.S. or similar statute.
(c) Architect's professional responsibility shall comply with the standard of care applicable to the type of engineering and architectural services provided, commensurate with the size, scope and nature of the Project.
(d) Architect shall be completely responsible for the safety of Architect's employees in the execution of work under this Agreement, shall provide all necessary safety equipment for said employees, and shall hold harmless and indemnify and defend Owner from any and all claims, suits, loss or injury to Architect's employees.
(e) Architect acknowledges that, due to the nature of architectural and related professional services and the impact of same on the Project, the Owner has a substantial interest in the personnel and consultants to whom Architect assigns principal responsibility for services performed under this Agreement. Consequently, Architect represents that Architect has selected and intends to employ or assign the key personnel and consultants identified in Appendix C - "Identification of Personnel, Subcontractors and Task Responsibility", attached hereto for the Project assignments and areas of responsibility stated therein. Within 10 days of execution of this Agreement, Owner shall have the right to object in writing to employment on the Project of any such key person, consultant or assignment of principal responsibility, in which case Architect will employ alternate personnel for such function or reassign such responsibility to another to whom Owner has no reasonable objection. Thereafter, Architect shall not assign or reassign Project work to any person to whom Owner has reasonable objection. Within 5 days of execution of this Agreement, Architect shall designate in writing a Project representative who shall have complete authority to bind Architect, and to whom Owner should address communications.
(f) Promptly after execution of this Agreement and upon receipt of authorization from Owner to proceed, Architect shall submit to Owner for approval a schedule showing the order in which Architect proposes to accomplish his work, with dates on which he will commence and complete each major work item. The schedule shall provide for performance of the work in a timely manner so as to not delay Owner's time table for achievement of interim tasks and final completion of Project work, provided however, the Architect will not be responsible for delays beyond his control.
(g) Before undertaking any work which Architect considers beyond or in addition to the scope of work and services which Architect has contractually agreed to perform under the terms of this Agreement, Architect shall advise Owner in writing (i) that Architect considers the work beyond the scope of this Agreement, (ii) the reasons the Architect believes the out of scope or additional work should be performed, and (iii) a reasonable estimate of the cost of such work. Architect shall not proceed with such out of scope or additional work until authorized in writing by Owner. The compensation for such authorized work shall be negotiated, but in the event the parties fail to negotiate or are unable to agree as to compensation, then Architect shall be compensated for his direct costs and professional time at the rates set forth in Appendix B - "Fee Schedule".
General Responsibilities of the Parties 1. The Parties will work together in a spirit of cooperation and partnership, with the responsibilities and accountabilities set out in this Agreement, to implement the Programme Documents in full in a timely, efficient, and effective, manner.
2. The Parties agree to carry out their respective responsibilities in accordance with the provisions of this Agreement, including the Programme Documents.
3. The Parties shall keep each other informed of all relevant activities pertaining to the implementation of the Programme Documents, and shall hold consultations when either Party considers it appropriate, including any circumstance that may affect the achievement of the results of the Programme and the Programme Documents.
4. The Parties shall fulfill their commitments with the fullest regard for the terms and conditions of this Agreement and the principles of the United Nations.
Contractor’s General Responsibilities The Contractor, regardless of any delegation or subcontract entered by the Contractor, shall be responsible for the following when providing information technology staff augmentation services:
3.1 The Contractor is responsible for the comprehensive management of Staff. Staff shall not be deemed an employee of the State or deemed to be entitled to any benefits associated with such employment and the Contractor shall be responsible for the administration and maintenance of all employment and payroll records, payroll processing, remittance of payroll and taxes, and all administrative tasks required by state and federal law associated with payment of Staff.
3.2 The Contractor shall provide Staff in accordance with Customer Requests for Quote (RFQ), and as described in Contract Exhibit J, Job Family Descriptions document. Customers may include detailed scopes of work, specific requirements of the work to be performed, and any requirements of Staff within the Request for Quote.
3.3 The Contractor shall possess the professional and technical staff necessary to allocate, outsource, and manage qualified Staff to perform the services requested by the Customer.
3.4 The Contractor shall provide Customers with Staff who have sufficient skill and experience to perform the services assigned to them.
3.5 The Contractor is responsible for ensuring that all information technology staff augmentation services furnished under the Contract meet the professional standards and quality that prevails among information technology professionals in the same discipline and of similar knowledge and skill engaged in related work throughout Florida under the same or similar circumstances.
3.6 The Contractor shall provide, at its own expense, training necessary for keeping Contractor’s Staff abreast of industry advances and for maintaining proficiency in equipment and systems that are available on the commercial market.
3.7 The Contractor shall, at its own expense, be responsible for adhering to the Contract background screening requirements, testing, evaluations, advertising, recruitment, and disciplinary actions of Contractor’s Staff.
3.8 The Contractor, throughout the term of the Contract, shall maintain all licenses, permits, qualifications, insurance, and approvals of whatever nature that are legally required for Contractor and Staff to perform the information technology staff augmentation services.
3.9 Contractor shall be responsible for all costs associated with the administration of this Contract.
3.10 The Contractor shall adhere to all work policies, procedures, and standards established by the Department and Customer.
3.11 The Contractor shall ensure that Staff conform with the Customer’s policies in all respects while on the Customer’s premises, and is responsible for obtaining all rules, regulations, policies, etc.
3.12 Contractor shall only provide information technology staff augmentation services for those Job Titles awarded to the Contractor and shall be paid on an hourly basis. Contracts resulting from this solicitation should not be structured as fixed-price agreements or used for any services requiring authorization for payment of milestone tasks.
Mutual Responsibilities It is recognized by this Agreement to be the duty of the Company to explain fully the terms of this Agreement to all its officers, foremen and others engaged in a supervisory capacity and it is recognized to be the duty of the Union to explain fully to its members, its and their responsibilities and obligations under this Agreement.
General Responsibilities Issuer hereby engages Distributor to act as exclusive distributor of the shares of each class of the Funds. The Funds subject to this Agreement as of the date hereof are identified on SCHEDULE A, which may be amended from time to time in accordance with Section 11 below. Sales of a Fund's shares shall be made only to investors residing in those states in which such Fund is registered. After effectiveness of each Fund’s registration statement, Distributor will hold itself available to receive, as agent for the Fund, and will receive by mail, telex, telephone, or such other method as may be agreed upon between Distributor and Issuer, orders for the purchase of Fund shares, and will accept or reject such orders on behalf of the Fund in accordance with the provisions of the applicable Fund’s prospectus. Distributor will be available to transmit orders, as promptly as possible after it accepts such orders, to the Fund’s transfer agent for processing at the shares’ net asset value next determined in accordance with the prospectuses.
Specific Responsibilities Without limiting the responsibilities of the Manager, the Manager will:
1. Maintain office facilities (which may be in the offices of the Manager or a corporate affiliate but shall be in such location as the Trust reasonably determines).
2. Furnish statistical and research data, clerical services and stationery and office supplies.
3. Compile data for, prepare for execution by the Fund and file all the Fund’s federal and state tax returns and required tax filings other than those required by this Agreement to be made by the Fund’s custodian and transfer agent.
4. Prepare compliance filings pursuant to state securities laws with the advice of the Trust’s counsel.
5. Prepare the Trust’s Annual and Semi-Annual Reports to Shareholders and amendments to its Registration Statements (on Form N-1A or any replacement therefor).
6. Compile data for, prepare and file timely Notices to the SEC required pursuant to Rule 24f-2 under the 1940 Act.
7. Determine the daily pricing of the portfolio securities and computation of the net asset value and the net income of Fund in accordance with the Prospectus, resolutions of the Trust’s Board of Trustees, and the procedures set forth in EXHIBIT A: NET ASSET VALUE CALCULATIONS.
8. Keep and maintain the financial accounts and records of the Fund and provide the Trust with certain reports, as needed or requested by the Fund.
9. Provide officers for the Trust as requested by the Trust’s Board of Trustees.
10. Perform fund accounting services for the Fund as set forth in EXHIBIT B: FUND ACCOUNTING FUNCTIONS.
11. Generally assist in all aspects of the operations of the Fund.
MUTUAL RESPONSIBILITY 6.2.1 The Contractor shall afford the State and separate contractors reasonable opportunity for the introduction and storage of their materials and equipment and the execution of their work, and shall connect and coordinate his / her Work with the work of the State and separate contractors as required by the Contract Documents.
6.2.2 If any part of the Contractor's Work depends for proper execution or results upon the work of the State or any separate contractor, the Contractor shall, prior to proceeding with the Work, promptly report to the Architect any apparent discrepancies or defects in such other work that render it unsuitable for such proper execution and results. Failure of the Contractor so to report shall constitute an acceptance of the State's or separate contractors work as fit and proper to receive
6.2.3 Any costs caused by defective or ill-timed work shall be borne by the party responsible therefor.
6.2.4 Should the Contractor wrongfully cause damage to the work or property of the State, or to other work on the site, the Contractor shall promptly remedy such damage as provided in Subparagraph 10.2.5 of these General Conditions.
Custodial Responsibilities (a) Each Custodian shall provide access to the Mortgage Loan Documents in possession of the applicable Custodian regarding the related Mortgage Loans and REO Property and the servicing thereof to the Trustee, the Certificateholders, the FDIC, and the supervisory agents and examiners of the FDIC, such access being afforded only upon reasonable prior written request and during normal business hours at the office of the applicable Custodian. Each Custodian shall allow representatives of the above entities to photocopy any of the records and documentation and shall provide equipment for that purpose at the expense of the person requesting such access.
(b) Each Custodian may resign from its obligations hereunder upon 60 days' prior written notice to the Trustee, the Depositor, the Securities Administrator and the Servicers. Such resignation shall take effect upon (i) the appointment of a successor Custodian reasonably acceptable to the Depositor within such 60 day period; and (ii) delivery of all Mortgage Loan Files to the successor Custodian. The Trustee shall have the right, but not the obligation, to become the successor Custodian. If no successor Custodian is appointed within 60 days after written notice of such Custxxxxx'x xesignation is received by the Trustee, the applicable Custxxxxx xxx petition a court of competent jurisdiction to appoint a successor Custodian. Upon such resignation and appointment of succesxxx Xxxxxdian, the applicable Custodian shall, at such Custodian's expense, xxxxxxxx transfer to the successor Custodian, as directed in writing by the Trustee, all applicable Mortgage Files being administered under this Agreement. Notwithstanding the foregoing, the Trust Fund, not the applicable Custodian, shall bear the costs relating to the transfer of Mortgage Files if such Custodian shall resign with cause (including such Custodian's resignation due to the failure of such Custodian to be paid xxx xxxx due to such Custodian hereunder).
(c) For so long as reports are required to be filed with the Commission under the Exchange Act with respect to the Trust, each Custodian shall not utilize any Subcontractor for the performance of its duties hereunder if such Subcontractor would be "participating in the servicing function" within the meaning of Item 1122 of Regulation AB without the prior written consent of the Depositor, in its sole discretion.
(d) Each Custodian shall indemnify the Depositor, the Sponsor, the Securities Administrator and any director, officer, employee, agent and affiliate of the Depositor, the Sponsor or the Securities Administrator and hold them harmless against any and all claims, losses, damages, penalties, fines, forfeitures, reasonable and necessary legal fees and related costs, judgments, and any other costs, fees and expenses that any of them may sustain in any way related to (i) the failure of the applicable Custodian to deliver when required any assessment of compliance required to be delivered by the applicable Custodian or (ii) any material misstatement or omission contained in any assessment of compliance provided to be delivered by the applicable Custodian. This indemnity shall survive the termination of this Agreement or the earlier resignation or removal of the applicable Custodian.
(e) Notwithstanding anything in this Agreement to the contrary, no Custodian shall be required to deliver, or to cause to be delivered, an assessment of compliance or accountant's attestation report pursuant to Section 3.23 for any fiscal year of the Trust in which the Custodian's Weighted Average Percentage is 5% or less. The "Custodian's Weighted Average Percentage" means, for each fiscal year of the Trust and each Custodian, the quotient, expressed as a percentage, of (A) the aggregate of the Stated Principal Balance for each Distribution Date in such fiscal year of the Mortgage Loans for which such Custodian acted as Custodian divided by (B) the aggregate of the Pool Stated Principal Balance for each Distribution Date in such fiscal year.
ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals.
§ 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project.
§ 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project.
§ 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project.
§ 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9.
§ 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage.
§ 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage.
§ 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
Lobbying Activities - Standard Form - LLL No response Do not upload this form unless Vendor has reportable lobbying activities. There are Attributes entitled, “2 CFR Part 200 or Federal Provision - Xxxx Anti-Lobbying Amendment – Continued.” Properly respond to those Attributes and only upload this form if applicable/instructed. If upload is required based on your response to those Attributes, the Disclosure of Lobbying Activities – Standard Form - LLL must be downloaded from the “Attachments” section of the IonWave eBid System, reviewed, properly completed, and uploaded to this location.
