Design Development Phase Services 3.3.1 Based on the Owner’s approval of the Schematic Design Documents, and on the Owner’s authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Design Development Documents for the Owner’s approval. The Design Development Documents shall illustrate and describe the development of the approved Schematic Design Documents and shall consist of drawings and other documents including plans, sections, elevations, typical construction details, and diagrammatic layouts of building systems to fix and describe the size and character of the Project as to architectural, structural, mechanical and electrical systems, and other appropriate elements. The Design Development Documents shall also include outline specifications that identify major materials and systems and establish, in general, their quality levels.
Research, Science and Technology Cooperation 1. The aims of cooperation in research, science and technology, carried out in the mutual interest of the Parties and in compliance with their policies, will be: (a) to build on existing agreements already in place for cooperation on research, science and technology; (b) to encourage, where appropriate, government agencies, research institutions, universities, private companies and other research organizations in the Parties to conclude direct arrangements in support of cooperative activities, programs or projects within the framework of this Agreement, specially related to trade and commerce; and (c) to focus cooperative activities towards sectors where mutual and complementary interests exist, with special emphasis on information and communication technologies and software development to facilitate trade between the Parties. 2. The Parties will encourage and facilitate, as appropriate, the following activities including, but not limited to:
Additional Works If the Employer requests the Contractor to provide additional works or services which are not either envisaged by, or ancillary to the Works to be provided under, this Contract then the Contractor shall comply with any such request as if such request were a Variation instruction and the provisions of this clause 13 [Variations and Adjustments] shall apply accordingly.
COMMENCEMENT OF WORKS Amend Sub-Clause 41.1 as follows: Delete the words “as soon as is reasonably possible” in the first sentence and replace with “within the period stated in the Appendix to Bid”.
Contract Term Extension “Contract Term Extension” means an extension of the term of this contract, at the request of Purchaser, under this Subsection. This Subsection does not obligate Contracting Officer to grant Contract Term Extension. When such extension is made, Forest Service shall make an appraisal using standard Forest Service methods and appraisal data in effect 45 days prior to the original Termination Date. Bid Premium Rates shall be added to such appraised rates to establish Flat Rates or Tentative Rates for the extension period. In event rates so established would develop Current Contract Value immediately prior to such an extension that is less than Current Contract Value at that time, Flat Rates and Tentative Rates in effect immediately prior to extension shall be retained for the extension period. In consideration for granting an extension, Purchaser shall pay the Government for Purchaser’s failure to cut and remove timber meeting Utilization Standards prior to Contract Term Extension, an amount that shall be the total of the costs to the Government resulting from the delay in harvest of Included Timber. Such costs will be determined by Forest Service and shall include, but not be limited to, the following:
Design Development Phase INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
Development Schedule The Project shall substantially comply with the specific timetables and triggers for action set forth in Article 5 of this Agreement. The parties acknowledge that, as provided in G.S. 160A-400.25(b), the failure to meet a commencement or completion date shall not, in and of itself, constitute a material breach of this Agreement pursuant to G.S. 160A-400.27 but must be judged based upon the totality of the circumstances.
TECHNICAL TASKS Products that require a draft version are indicated by marking “(draft and final)” after the product name in the “Products” section of the task/subtask. If “(draft and final)” does not appear after the product name, only a final version of the product is required. Subtask 1.1 (Products) describes the procedure for submitting products to the CAM.
Technical Consultations 1. A Party may initiate technical consultations with another Party through the respective contact points with the aim of resolving any matter arising under this Chapter.
Notice of Technological Change (a) For the purpose of technological change, the Employer agrees to provide the Union with as much notice as possible, but in any event not less than sixty (60) days notice of a technological change.
