Service Delivery Requirements The following sections describe in detail the work activity required by this program. All CONTRACTORS will be expected to fulfill the work activity requirements in these areas.
A. Staff Requirements & Policies CONTRACTOR shall provide the necessary management and administrative personnel whose expertise will ensure efficient operation of SNEMT services. OoA recognizes that a high quality operation begins with key personnel. Therefore, a minimum level of required staffing is described for the positions and functions described below.
1. Program Manager/Director The program manager/director will be in charge of all management and day- to-day operations of the CONTRACTOR’s SNEMT program. The position will maintain consistent and sufficient contact and communication with the OoA and be responsible for all CONTRACT obligations.
Certain Requirements as to Furniture, Equipment and Fixtures If the Assuming Institution purchases owned Bank Premises or accepts an assignment of the lease (or enters into a sublease or a new lease in lieu thereof) for leased Bank Premises as provided in Section 4.6(a) or 4.6(b), or if the Assuming Institution does not exercise such option but within twelve (12) months following Bank Closing obtains the right to occupy such premises (whether by assignment, lease, sublease, purchase or otherwise), other than in accordance with Section 4.6(a) or (b), the Assuming Institution shall (i) effective as of the date of Bank Closing, purchase from the Receiver all Furniture and Equipment and Fixtures owned by the Failed Bank at Fair Market Value and located thereon as of Bank Closing, (ii) accept an assignment or a sublease of the leases or negotiate new leases for all Furniture and Equipment and Fixtures leased by the Failed Bank and located thereon, and (iii) if applicable, accept an assignment or a sublease of any ground lease or negotiate a new ground lease with respect to any land on which such Bank Premises are located; provided, that the Receiver shall not have disposed of such Furniture and Equipment and Fixtures or repudiated the leases specified in clause (ii) or (iii).
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Compliance with Federal, State and Local Laws a. The Grantee and all its agents shall comply with all federal, state and local regulations, including, but not limited to, nondiscrimination, wages, social security, workers’ compensation, licenses, and registration requirements. The Grantee shall include this provision in all subcontracts issued as a result of this Agreement.
b. No person, on the grounds of race, creed, color, religion, national origin, age, gender, or disability, shall be excluded from participation in; be denied the proceeds or benefits of; or be otherwise subjected to discrimination in performance of this Agreement.
c. This Agreement shall be governed by and construed in accordance with the laws of the State of Florida.
d. Any dispute concerning performance of the Agreement shall be processed as described herein. Jurisdiction for any damages arising under the terms of the Agreement will be in the courts of the State, and venue will be in the Second Judicial Circuit, in and for Leon County. Except as otherwise provided by law, the parties agree to be responsible for their own attorney fees incurred in connection with disputes arising under the terms of this Agreement.
Compliance with Xxxxx-Xxxxx and Related Act requirements All rulings and interpretations of the Xxxxx-Xxxxx and Related Acts contained in 29 CFR parts 1, 3, and 5 are herein incorporated by reference in this contract.
New Hampshire Specific Data Security Requirements The Provider agrees to the following privacy and security standards from “the Minimum Standards for Privacy and Security of Student and Employee Data” from the New Hampshire Department of Education. Specifically, the Provider agrees to:
(1) Limit system access to the types of transactions and functions that authorized users, such as students, parents, and LEA are permitted to execute;
(2) Limit unsuccessful logon attempts;
(3) Employ cryptographic mechanisms to protect the confidentiality of remote access sessions;
(4) Authorize wireless access prior to allowing such connections;
(5) Create and retain system audit logs and records to the extent needed to enable the monitoring, analysis, investigation, and reporting of unlawful or unauthorized system activity;
(6) Ensure that the actions of individual system users can be uniquely traced to those users so they can be held accountable for their actions;
(7) Establish and maintain baseline configurations and inventories of organizational systems (including hardware, software, firmware, and documentation) throughout the respective system development life cycles;
(8) Restrict, disable, or prevent the use of nonessential programs, functions, ports, protocols, and services;
(9) Enforce a minimum password complexity and change of characters when new passwords are created;
(10) Perform maintenance on organizational systems;
(11) Provide controls on the tools, techniques, mechanisms, and personnel used to conduct system maintenance;
(12) Ensure equipment removed for off-site maintenance is sanitized of any Student Data in accordance with NIST SP 800-88 Revision 1;
(13) Protect (i.e., physically control and securely store) system media containing Student Data, both paper and digital;
(14) Sanitize or destroy system media containing Student Data in accordance with NIST SP 800-88 Revision 1 before disposal or release for reuse;
(15) Control access to media containing Student Data and maintain accountability for media during transport outside of controlled areas;
(16) Periodically assess the security controls in organizational systems to determine if the controls are effective in their application and develop and implement plans of action designed to correct deficiencies and reduce or eliminate vulnerabilities in organizational systems;
(17) Monitor, control, and protect communications (i.e., information transmitted or received by organizational systems) at the external boundaries and key internal boundaries of organizational systems;
(18) Deny network communications traffic by default and allow network communications traffic by exception (i.e., deny all, permit by exception);
(19) Protect the confidentiality of Student Data at rest;
(20) Identify, report, and correct system flaws in a timely manner;
(21) Provide protection from malicious code (i.e. Antivirus and Antimalware) at designated locations within organizational systems;
(22) Monitor system security alerts and advisories and take action in response; and
(23) Update malicious code protection mechanisms when new releases are available.
CAUTIONS FOR GLOBAL USE AND EXPORT AND IMPORT COMPLIANCE Due to the global nature of the internet, through the use of our network you hereby agree to comply with all local rules relating to online conduct and that which is considered acceptable Content. Uploading, posting and/or transferring of software, technology and other technical data may be subject to the export and import laws of the United States and possibly other countries. Through the use of our network, you thus agree to comply with all applicable export and import laws, statutes and regulations, including, but not limited to, the Export Administration Regulations (xxxx://xxx.xxxxxx.xxx.xxx/bis/ear/ear_data.html), as well as the sanctions control program of the United States (xxxx://xxx.xxxxxxxx.xxx/resource- center/sanctions/Programs/Pages/Programs.aspx). Furthermore, you state and pledge that you:
Compliance with Xxxxxxxx Act requirements The contractor shall comply with the requirements of 29 CFR part 3, which are incorporated by reference in this contract.
Delivery Requirements Contractor must ensure that the Goods and/or Services are delivered or provided as required by this Contract, the Purchase Order used by Purchaser, and as otherwise mutually agreed in writing between Purchaser and Contractor. The following apply to all deliveries:
(a) Contractor shall make all deliveries to the applicable delivery location specified in the Purchase Order. Such deliveries shall occur during Purchaser’s normal work hours and within the time period mutually agreed in writing between Purchaser and Contractor.
(b) Contractor shall ship all Goods and/or Services purchased pursuant to this Contract, freight charges prepaid by Contractor, FOB Purchaser’s specified destination with all transportation and handling charges included. Contractor shall bear all risk of loss, damage, or destruction of the Goods and/or Services ordered hereunder that occurs prior to delivery, except loss or damage attributable to Purchaser’s fault or negligence.
(c) All packing lists, packages, instruction manuals, correspondence, shipping notices, shipping containers, and other written materials associated with this Contract shall be identified by the Contract number set forth on the cover of this Contract and the applicable Purchaser’s Purchase Order number. Packing lists shall be enclosed with each shipment and clearly identify all contents and any backorders.
Federal Medicaid System Security Requirements Compliance Party shall provide a security plan, risk assessment, and security controls review document within three months of the start date of this Agreement (and update it annually thereafter) in order to support audit compliance with 45 CFR 95.621 subpart F, ADP System Security Requirements and Review Process.
