RESPONSIBILITIES OF THE STATE 3.2.1 The State will identify a Project Manager for the Project. The Project Manager will be the sole point of contact between the Contractor and the State. The Project Manager will be the State’s representative authorized to communicate the State’s position and directions related to all contract work and to coordinate all change orders with the Commissioner of Buildings and General Services as deemed necessary.
3.2.2 If applicable, the State shall furnish all surveys describing the physical characteristics, legal limitations and utility locations for the site of the Project, and a legal description of the site.
3.2.3 Except as provided in Subparagraph 4.7.1, the State shall secure and pay for necessary approvals, easements, assessments and charges required for the construction, use or occupancy of permanent structures or for permanent changes in existing facilities.
3.2.4 Information or services under the State's control shall be furnished by the State with reasonable promptness to avoid delay in the orderly progress of the Work.
3.2.5 Unless otherwise provided in the Contract Documents, the Contractor will be furnished, free of charge, all copies of Drawings and Specifications reasonably necessary for the execution of the Work.
3.2.6 The State shall forward instructions to the Contractor through the Architect.
3.2.7 The foregoing are in addition to any other duties and responsibilities of the State enumerated in the Contract Documents including those responsibilities described in Articles 6, 9 and 11 of this agreement.
3.2.8 The State may utilize a Clerk-of-the-Works to provide inspection and monitoring work on behalf of the State. If a Clerk-of-the-Works is utilized, it is the responsibility of the Architect and the Contractor to review and understand the Clerk’s duties, responsibilities and limitations of authority. Upon request, the State shall provide a copy of the Clerk-of-the-Works contract to Architect and Contractor.
Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever.
(ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties.
(iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority.
(iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i).
(v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party.
(vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway.
(vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.
Scope of the Services UNOPS intends to retain the Contractor for the implementation of the Services, and the Contractor intends to provide the Services. The Contractor has represented to UNOPS that it has the appropriate experience, expertise, licences, and resources to undertake the Services and has agreed to undertake the Services in accordance with the Contract. In reliance on the Contractor’s representations UNOPS has entered into the Contract. The Contract sets out the terms and conditions upon which the Contractor will undertake the Services.
Appointment of the Servicer (a) The servicing, administering and collection of the Pool Receivables shall be conducted by the Person so designated from time to time as the Servicer in accordance with this Section 9.01. Until the Administrative Agent gives notice to BrightView (in accordance with this Section 9.01) of the designation of a new Servicer, BrightView is hereby designated as, and hereby agrees to perform the duties and obligations of, the Servicer pursuant to the terms hereof. Upon the occurrence of an Event of Default, the Administrative Agent may (with the consent of the Majority Lenders) and shall (at the direction of the Majority Lenders) designate as Servicer any Person (including itself) to succeed BrightView or any successor Servicer, on the condition in each case that any such Person so designated shall agree to perform the duties and obligations of the Servicer pursuant to the terms hereof.
(b) Upon the designation of a successor Servicer as set forth in clause (a) above, BrightView agrees that it will terminate its activities as Servicer hereunder in a manner that the Administrative Agent reasonably determines will facilitate the transition of the performance of such activities to the new Servicer, and BrightView shall cooperate with and assist such new Servicer. Such cooperation shall include access to and transfer of records (including all Contracts) related to Pool Receivables and use by the new Servicer of all licenses (or the obtaining of new licenses), hardware or software necessary or reasonably desirable to collect the Pool Receivables and the Related Security.
(c) BrightView acknowledges that, in making its decision to execute and deliver this Agreement, the Administrative Agent and each Lender have relied on BrightView’s agreement to act as Servicer hereunder. Accordingly, BrightView agrees that it will not voluntarily resign as Servicer without the prior written consent of the Administrative Agent and the Majority Lenders.
(d) The Servicer may delegate its duties and obligations hereunder to any subservicer (each a “Sub-Servicer”); provided, that, in each such delegation: (i) such Sub-Servicer shall agree in writing to perform the delegated duties and obligations of the Servicer pursuant to the terms hereof, (ii) the Servicer shall remain liable for the performance of the duties and obligations so delegated, (iii) the Borrower, the Administrative Agent and each Lender shall have the right to look solely to the Servicer for performance, (iv) the terms of any agreement with any Sub-Servicer shall provide that the Administrative Agent may terminate such agreement upon the termination of the Servicer hereunder by giving notice of its desire to terminate such agreement to the Servicer (and the Servicer shall provide appropriate notice to each such Sub-Servicer) and (v) if such Sub-Servicer is not an Affiliate of the Parent, the Administrative Agent and the Majority Lenders shall have consented in writing in advance to such delegation.
Description of the Services 1.1 The scope of the service to be rendered is described more fully in the Annexures and Schedules referred to below: ❑ Annexure A – Scope / Specification ❑ Annexure C – Pricing Schedule The Deliverables, due for completion by and governed by this Schedule 1. In the event that the Service Provider fails to meet the delivery dates as agreed, the following penalties will be imposed:
Authorization of the Servicer (a) Each of the Borrower, each Managing Agent, on behalf of itself and the related Lenders, the Administrative Agent and each Hedge Counterparty hereby authorizes the Servicer (including any successor thereto) to take any and all reasonable steps in its name and on its behalf necessary or desirable and not inconsistent with the pledge of the Transferred Loans to the Lender, each Hedge Counterparty, and the Collateral Custodian, in the determination of the Servicer, to collect all amounts due under any and all Transferred Loans, including, without limitation, endorsing any of their names on checks and other instruments representing Collections, executing and delivering any and all instruments of satisfaction or cancellation, or of partial or full release or discharge, and all other comparable instruments, with respect to the Transferred Loans and, after the delinquency of any Transferred Loan and to the extent permitted under and in compliance with Applicable Law, to commence proceedings with respect to enforcing payment thereof, to the same extent as the Originator could have done if it had continued to own such Loan; provided, however, that the Servicer may not execute any document in the name of, or which imposes any direct obligation on, any Lender. The Borrower shall furnish the Servicer (and any successors thereto) with any powers of attorney and other documents necessary or appropriate to enable the Servicer to carry out its servicing and administrative duties hereunder, and shall cooperate with the Servicer to the fullest extent in order to ensure the collectibility of the Transferred Loans. In no event shall the Servicer be entitled to make the Borrower, any Lender, any Managing Agent, any Hedge Counterparty, the Collateral Custodian or the Administrative Agent a party to any litigation without such party’s express prior written consent, or to make the Borrower a party to any litigation (other than any routine foreclosure or similar collection procedure) without the Administrative Agent’s consent.
(b) After an Early Termination Event has occurred and is continuing, at the Administrative Agent’s direction, the Servicer shall take such action as the Administrative Agent may deem necessary or advisable to enforce collection of the Transferred Loans; provided, however, that the Administrative Agent may, at any time that an Early Termination Event has occurred and is continuing, notify any Obligor with respect to any Transferred Loans of the assignment of such Transferred Loans to the Administrative Agent and direct that payments of all amounts due or to become due to the Borrower thereunder be made directly to the Administrative Agent or any servicer, collection agent or lock-box or other account designated by the Administrative Agent and, upon such notification and at the expense of the Borrower, the Administrative Agent may enforce collection of any such Transferred Loans and adjust, settle or compromise the amount or payment thereof. The Administrative Agent shall give written notice to any Successor Servicer of the Administrative Agent’s actions or directions pursuant to this Section 7.3(b), and no Successor Servicer shall take any actions pursuant to this Section 7.3(b) that are outside of its Credit and Collection Policy.
Activities of the Subadviser Except to the extent necessary to perform its obligations hereunder, nothing herein shall be deemed to limit or restrict the Subadviser's right, or the right of any of the Subadviser's directors, officers or employees to engage in any other business or to devote time and attention to the management or other aspects of any other business, whether of a similar or dissimilar nature, or to render services of any kind to any other corporation, trust, firm, individual or association.
Maintenance of the Primary Insurance Policies; Collections Thereunder (a) The Master Servicer shall not take, or permit any Subservicer to take, any action which would result in non-coverage under any applicable Primary Insurance Policy of any loss which, but for the actions of the Master Servicer or Subservicer, would have been covered thereunder. To the extent coverage is available, the Master Servicer shall keep or cause to be kept in full force and effect each such Primary Insurance Policy until the principal balance of the related Mortgage Loan secured by a Mortgaged Property is reduced to 80% or less of the Appraised Value in the case of such a Mortgage Loan having a Loan-to-Value Ratio at origination in excess of 80%, provided that such Primary Insurance Policy was in place as of the Cut-off Date and the Company had knowledge of such Primary Insurance Policy. The Master Servicer shall be entitled to cancel or permit the discontinuation of any Primary Insurance Policy as to any Mortgage Loan, if the Stated Principal Balance of the Mortgage Loan is reduced below an amount equal to 80% of the appraised value of the related Mortgaged Property as determined in any appraisal thereof after the Closing Date, or if the Loan-to-Value Ratio is reduced below 80% as a result of principal payments on the Mortgage Loan after the Closing Date. In the event that the Company gains knowledge that as of the Closing Date, a Mortgage Loan had a Loan-to-Value Ratio at origination in excess of 80% and is not the subject of a Primary Insurance Policy (and was not included in any exception to the representation in Section 2.03(b)(iv)) and that such Mortgage Loan has a current Loan-to-Value Ratio in excess of 80% then the Master Servicer shall use its reasonable efforts to obtain and maintain a Primary Insurance Policy to the extent that such a policy is obtainable at a reasonable price. The Master Servicer shall not cancel or refuse to renew any such Primary Insurance Policy applicable to a Nonsubserviced Mortgage Loan, or consent to any Subservicer canceling or refusing to renew any such Primary Insurance Policy applicable to a Mortgage Loan subserviced by it, that is in effect at the date of the initial issuance of the Certificates and is required to be kept in force hereunder unless the replacement Primary Insurance Policy for such canceled or non-renewed policy is maintained with an insurer whose claims-paying ability is acceptable to each Rating Agency for mortgage pass-through certificates having a rating equal to or better than the lower of the then-current rating or the rating assigned to the Certificates as of the Closing Date by such Rating Agency.
(b) In connection with its activities as administrator and servicer of the Mortgage Loans, the Master Servicer agrees to present or to cause the related Subservicer to present, on behalf of the Master Servicer, the Subservicer, if any, the Trustee and Certificateholders, claims to the related Insurer under any Primary Insurance Policies, in a timely manner in accordance with such policies, and, in this regard, to take or cause to be taken such reasonable action as shall be necessary to permit recovery under any Primary Insurance Policies respecting defaulted Mortgage Loans. Pursuant to Section 3.07, any Insurance Proceeds collected by or remitted to the Master Servicer under any Primary Insurance Policies shall be deposited in the Custodial Account, subject to withdrawal pursuant to Section 3.10.
Appointment of the Sub-Adviser The Adviser hereby appoints the Sub-Adviser to act as an investment adviser for each Portfolio, subject to the supervision and oversight of the Adviser and the Trustees of the Trust, and in accordance with the terms and conditions of this Agreement. The Sub-Adviser will be an independent contractor and will have no authority to act for or represent the Trust or the Adviser in any way or otherwise be deemed an agent of the Trust or the Adviser except as expressly authorized in this Agreement or another writing by the Trust, the Adviser and the Sub-Adviser.
Liability of the Subadviser (a) In the absence of willful misfeasance, bad faith, gross negligence or reckless disregard of obligations or duties ("disabling conduct") hereunder on the part of the Subadviser (and its officers, directors/trustees, agents, employees, controlling persons, shareholders and any other person or entity affiliated with the Subadviser) the Subadviser shall not be subject to liability to the Adviser (and its officers, directors/trustees, agents, employees, controlling persons, shareholders and any other person or entity affiliated with the Adviser) or to the Trust (and its officers, directors/trustees, agents, employees, controlling persons, shareholders and any other person or entity affiliated with the Trust) for any act or omission in the course of, or connected with, rendering services hereunder, including without limitation, any error of judgment or mistake of law or for any loss suffered by any of them in connection with the matters to which this Agreement relates, except to the extent specified in Section 36(b) of the Act concerning loss resulting from a breach of fiduciary duty with respect to the receipt of compensation for services. Except for such disabling conduct, the Adviser shall indemnify the Subadviser (and its officers, directors, partners, agents, employees, controlling persons, shareholders and any other person or entity affiliated with the Subadviser) from any and all losses, claims, damages, liabilities or litigation (including reasonable legal and other expenses) arising from Subadviser's rendering of services under this Agreement.
(b) The Subadviser agrees to indemnify and hold harmless the Adviser (and its officers, directors/trustees, agents, employees, controlling persons, shareholders and any other person or entity affiliated with the Adviser) and/or the Trust (and its officers, directors/trustees, agents, employees, controlling persons, shareholders and any other person or entity affiliated with the Trust) against any and all losses, claims, damages, liabilities or litigation (including reasonable legal and other expenses), to which the Adviser and/or the Trust and their affiliates or such directors/trustees, officers or controlling person may become subject under the Act, the 1933 Act, under other statutes, common law or otherwise, which arise from the Subadviser's disabling conduct, including but not limited to any material failure by the Subadviser to comply with the provisions and representations and warranties set forth in Section 1 of this Agreement; provided, however, that in no case is the Subadviser's indemnity in favor of any person deemed to protect such other persons against any liability to which such person would otherwise be subject by reasons of willful misfeasance, bad faith, or gross negligence in the performance of his, her or its duties or by reason of his, her or its reckless disregard of obligations and duties under this Agreement.
