Construction of the Improvements Once development of the Property has commenced, the construction of the Improvements shall be pursued with due diligence and continuity, in a good and workmanlike manner, and in accordance with sound building and engineering practices, all applicable governmental requirements, and the Development Plan. Borrower shall not permit cessation of work for a period in excess of thirty (30) days during any period of time during which development on the Property is scheduled to be performed without the prior written consent of Lender, which may be given or withheld in Lender’s sole discretion, except for delays due to strikes, riots, acts of God, war, unavailability of labor or materials, governmental laws, regulations or restrictions and Borrower shall promptly notify Lender of any such delays; provided, however, that in no event shall work cease for a period in excess of sixty (60) days regardless of the cause. Borrower shall cause all materials supplied for, or intended to be utilized in, the development of any part of the Property, but not affixed to or incorporated into the Property, to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards, as required by Lender, to prevent loss, theft, damage, or commingling with other materials or projects.
AMENDMENT OR ALTERATION No amendment or alteration of the terms of this Agreement shall be valid unless made in writing and signed by both of the parties hereto.
Installation and Use You may install and use the Software only for the number of licenses acquired by you. In order to exercise your rights to the Software under this Agreement, you must activate your copy of the Software in the manner described during the launch sequence.
Alteration That the Licensee shall not make or permit to do any alteration or addition to the construction or arrangements (internal or external) to the Licensed premises without previous consent in writing from the Licensor.
Construction of the Agreement The Agreement sets forth the entire understanding between two sophisticated business entities with legal counsel as to its subject and supersedes all prior agreements, conditions, warranties, representations, arrangements and communications, including purchase orders issued by Client, whether oral or written, and whether with or by Accenture, any of its affiliates, or any of their employees, officers, directors, agents or shareholders. Each party acknowledges that it entered into the Agreement solely based on the agreements and representations contained herein, and has not relied upon any representations, warranties, promises, or inducements of any kind, whether oral or written, and from any source. If a court of competent jurisdiction finds any term of the Agreement to be invalid, illegal or otherwise unenforceable, such term or provision will not affect the other terms of this Agreement and will be deemed modified to the extent necessary, in the court’s opinion, to render such term enforceable while preserving to the fullest extent permissible the intent and agreements of the parties set forth in this Agreement. No waiver or modification of any provision of the Agreement will be effective unless it is in writing and signed by the party against which it is sought to be enforced. The delay or failure by either party to exercise or enforce any of its rights under this Agreement is not a waiver of that party’s right to later enforce those rights, nor will any single or partial exercise of any such right preclude any other or further exercise of these rights or any other right. There are no third-party beneficiaries to the Agreement. In the event of a conflict between these GTC and an Order Form, the Order Form controls for purposes of that Order Form only.
Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.
ALTERATION OF TERMS 17 A. This Agreement, together with Exhibits A, B, and C attached hereto and incorporated herein, 18 fully expresses the complete understanding of COUNTY and CONTRACTOR with respect to the 19 subject matter of this Agreement. 20 B. Unless otherwise expressly stated in this Agreement, no addition to, or alteration of the terms of 21 this Agreement or any Exhibits, whether written or verbal, made by the parties, their officers, employees 22 or agents shall be valid unless made in the form of a written amendment to this Agreement, which has 23 been formally approved and executed by both parties. 24
Removal of Alterations If Tenant fails to remove by the expiration or earlier termination of this Lease all of its personal property, or any Alterations identified by Landlord for removal, Landlord may, at its option, treat such failure as a hold-over pursuant to Subparagraph 11(b) above, and/or Landlord may (without liability to Tenant for loss thereof) treat such personal property and/or Alterations as abandoned and, at Tenant's sole cost and expense, and in addition to Landlord's other rights and remedies under this Lease, at law or in equity: (a) remove and store such items; and/or (b) upon ten (10) days prior notice to Tenant, sell, discard or otherwise dispose of all or any such items at private or public sale for such price as Landlord may obtain or by other commercially reasonable means. Tenant shall be liable for all costs of disposition of Tenant's abandoned property and Landlord shall have no liability to Tenant with respect to any such abandoned property. Landlord agrees to apply the proceeds of any sale of any such property to any amounts due to Landlord under this Lease from Tenant (including Landlord's attorneys' fees and other costs incurred in the removal, storage and/or sale of such items), with any remainder to be paid to Tenant.
ALTERATION OF AGREEMENT A. It is hereby agreed that any alteration or modification of this Agreement shall be binding upon the parties only if agreed to in writing by both parties. B. The waiver of any condition of this Agreement by either party shall not constitute a precedent in the future enforcement of all terms and conditions herein.
Installation and Use Rights You may install and use any number of copies of the software on your devices.
