Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Miscellaneous Conditions Consultant shall be responsible for and remedy all damage or loss to any property, including property of City, caused in whole or in part by Consultant, any SubConsultant, or anyone employed, directed, or supervised by Consultant.
Miscellaneous Terms and Conditions 11.1 Nothing contained in this Amendment shall be deemed: (a) to obligate Verizon to offer or provide unbundled access to any UNE (whether as a stand-alone UNE, as part of a combination, or otherwise) that was not already available to Customer under the Agreements prior to this Amendment, (b) to obligate Verizon to offer or provide unbundled access at rates prescribed under Section 251(c)(3) of the Act to any facility that is or becomes a Discontinued UNE, whether as a stand-alone UNE, as part of a combination, or otherwise or (c) to limit any right of Verizon under the Agreement (independent of this Amendment), any Verizon tariff or SGAT, or otherwise, to cease providing a Discontinued UNE, whether as a stand-alone facility, as part of a combination, or otherwise.
11.2 Notwithstanding any other provision of the Agreement, and without limiting any existing rights Verizon may have to cease providing UNEs that are discontinued under Applicable Law, in the event that the FCC determines or has determined (whether by forbearance of existing rules, a rule change or otherwise) that Verizon is not required to provide any UNEs contained in the Amended Agreements beyond the UNEs specifically addressed in this Amendment, then Verizon (to the extent it has not already done so prior to execution of this Amendment) may implement such discontinuation by notifying Customer and/or by publishing notice of such discontinuation on Verizon’s wholesale website, and no amendment to the Amended Agreement shall be required for such purposes. Any such notice that Verizon issues (or has issued) shall address, among other things, the date on which new orders are disallowed and any transition period that is required for the embedded base (which shall be at least 90 (ninety) days unless the FCC requires a longer transition period for the embedded base). After the end of any such transition period, Customer’s embedded base of the subject UNE will be treated as a Discontinued UNE under Section 10 above.
Miscellaneous Rules 1 The provisions of this Agreement shall not be construed to restrict in any manner any exclusion, exemption, deduction, credit, or other allowances now or hereafter accorded:
(a) by the laws of a Contracting State in the determination of the tax imposed by that State; or
(b) by any other agreement entered into by a Contracting State.
Other Miscellaneous Terms The provisions of Article IX (General Provisions) of the Merger Agreement shall apply mutatis mutandis to this Amendment, and to the Merger Agreement as modified by this Amendment, taken together as a single agreement, reflecting the terms therein as modified by this Amendment.
Miscellaneous Terms The term "or" is disjunctive; the term "and" is conjunctive. The term "shall" is mandatory; the term "may" is permissive. Masculine terms also apply to females; feminine terms also apply to males. The term "including" is by way of example and not limitation.
Miscellaneous Requirements A. To comply with Texas Health and Safety Code, §85.113 and §85.115 concerning workplace and confidentiality guidelines for persons with AIDS or HIV.
B. To comply with applicable provisions of the Clean Air Act (42 U.S.C. §7401-7671q) and the Federal Water Pollution Control Act (33 U.S.C. §1251-1387), if funding for the Contract exceeds $100,000.
C. That in accordance with §2155.4441, Texas Government Code, the Contractor shall, in performing any service under this Contract, purchase products and materials produced in Texas when they are available at a comparable price and in a comparable period to products and materials produced outside of Texas.
D. To make a good faith effort to utilize historically underutilized businesses ("HUBs") when subcontracting. Some methods for locating HUBs include using searchable HUB databases at the Texas Comptroller of Public Accounts' website, using websites or other minority/women directory listings maintained by local xxxxxxxx of commerce, advertising subcontract work in local minority publications or contacting HHSC for assistance in locating available HUBs.
E. That except as provided in the paragraphs below, the Contractor must not use HHSC's name, the State of Texas or refer to HHSC or the State directly or indirectly in any media release, public announcement, or public disclosure relating to this Contract or its subject matter, including, but not limited to, in any promotional or marketing materials, customer lists or business presentations (other than those submitted to HHSC, an administrative agency of the State of Texas, or a governmental agency or unit of another state or the Federal Government). The Contractor may publish, at its sole expense, results of Contractor performance under this Contract with HHSC's prior review and approval, which HHSC may exercise at its sole discretion. Any publication (written, visual, or sound) will acknowledge the support received from HHSC and any Federal agency, as appropriate. The Contractor will provide HHSC at least 3 copies of such publication prior to public release. The Contractor will provide additional copies at the request of HHSC. The Contractor may include information concerning this Contract's terms, subject matter, and estimated value in any report to a governmental body to which the law requires the Contractor to report such information. The Contractor must not use HHSC’s logo under any circumstances.
MISCELLANEOUS CLAUSES 18.1. No waiver of any right under this Agreement shall be deemed effective unless contained in a written document signed by the Party charged with such waiver, and no waiver of any breach or failure to perform shall be deemed to be a waiver of any other breach or failure to perform or of any other right arising under this Agreement.
18.2. If any provision in this Agreement is agreed by the Parties to be, or is deemed to be, or becomes invalid, illegal, void or unenforceable under any law that is applicable hereto, (i) such provision will be deemed amended to conform to applicable laws so as to be valid and enforceable or, if it cannot be so amended without materially altering the intention of the Parties, it will be deleted, with effect from the date of such agreement or such earlier date as the Parties may agree, and (ii) the validity, legality and enforceability of the remaining provisions of this Agreement shall not be impaired or affected in any way.
18.3. The Parties shall use their respective reasonable endeavours to ensure that the Parties and any necessary Independent Third Party shall do, execute and perform all such further deeds, documents, assurances, acts and things as any of the Parties hereto may reasonably require by notice in writing to the other Party or such Independent Third Party to carry the provisions of this Agreement.
18.4. This Agreement shall be binding upon and enure to the benefit of the Parties hereto, their successors and permitted assigns and sub-licensees.
18.5. No provision of this Agreement shall be construed so as to negate, modify or affect in any way the provisions of any other agreement between the Parties unless specifically referred to, and solely to the extent provided, in any such other agreement. In the event of a conflict between the provisions of this Agreement and the provisions of the Development Agreement, the terms of the Development Agreement shall prevail unless this Agreement specifically provides otherwise.
18.6. No amendment, modification or addition hereto shall be effective or binding on either Party unless set forth in writing and executed by a duly authorised representative of each Party.
18.7. This Agreement may be executed in any number of counterparts, each of which when so executed shall be deemed to be an original and all of which when taken together shall constitute this Agreement.
18.8. Each of the Parties undertake to do all things reasonably within its power which are necessary or desirable to give effect to the spirit and intent of this Agreement.
18.9. Each of the Parties hereby acknowledges that in entering into this Agreement it has not relied on any representation or warranty save as expressly set out herein or in any document referred to herein.
18.10. Nothing contained in this Agreement is intended or is to be construed to constitute Elan and the Company as partners, or Elan as an employee of the Company, or the Company as an employee of Elan. Neither Party hereto shall have any express or implied right or authority to assume or create any obligations on behalf of or in the name of the other Party or to bind the other Party to any contract, agreement or undertaking with any Independent Third Party.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Commencement and Completion of Construction Subject to Unavoidable Delays, Developer shall cause construction of the Minimum Improvements to be undertaken and completed: (i) by no later than June 1, 2020; or (ii) by such other date as the parties shall mutually agree upon in writing. Time lost as a result of Unavoidable Delays shall be added to extend this date by a number of days equal to the number of days lost as a result of Unavoidable Delays. All work with respect to the Minimum Improvements shall be in conformity with the Construction Plans approved by the building official or any amendments thereto as may be approved by the building official. Developer agrees that it shall permit designated representatives of the City, upon reasonable notice (which does not have to be written), to enter upon the Development Property during the construction of the Minimum Improvements to inspect such construction and the progress thereof.
