MAINTENANCE, REPAIRS, OR ALTERATIONS The Tenant shall, at their own expense and at all times, maintain premises in a clean and sanitary manner, and shall surrender the same at termination hereof, in as good condition as received, normal wear and tear excepted. The Tenant may not make any alterations to the leased premises without the consent in writing of the Landlord. The Landlord shall be responsible for repairs to the interior and exterior of the building. If the Premises includes a washer, dryer, freezer, dehumidifier unit and/or air conditioning unit, the Landlord makes no warranty as to the repair or replacement of units if one or all shall fail to operate. The Landlord will place fresh batteries in all battery-operated smoke detectors when the Tenant moves into the premises. After the initial placement of the fresh batteries it is the responsibility of the Tenant to replace batteries when needed. A monthly "cursory" inspection may be required for all fire extinguishers to make sure they are fully charged.
Access to Work District representatives shall at all times have access to the Work, wherever it is, in preparation or in progress. Contractor shall provide safe and proper facilities for such access.
CERTIFICATION OF NO ASBESTOS CONTAINING MATERIALS OR WORK 8.1 The Contractor shall be responsible for ensuring that no asbestos containing materials or work is included within the scope of the Work. The Contractor shall take whatever measures it deems necessary to insure that all employees, suppliers, fabricators, material men, subcontractors, or their assigns, comply with this requirement.
8.2 The Contractor shall ensure that Texas Department of Health licensed individuals, consultants or companies are used for any required asbestos work including asbestos inspection, asbestos abatement plans/specifications, asbestos abatement, asbestos project management and third-party asbestos monitoring.
General specifications For the purpose of this Regulation, the vehicle shall fulfil the following requirements:
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Failure to Meet Timelines Failure by the Union to comply with the timelines will result in the automatic withdrawal of the grievance. Failure by the Employer to comply with the timelines will entitle the Union to move the grievance to the next step of the procedure.
The Specifications The Specifications are that portion of the Contract Documents consisting of the written requirements for materials, equipment, systems, standards and workmanship for the Work, and performance of related services.
Submission of Grievance Information a. Upon appointment of the arbitrator, the appealing party shall, within five (5) days after notice of appointment, forward to the arbitrator, with a copy to the School Board, the submission of the grievance which shall include the following:
1. The issues involved.
2. Statement of the facts.
3. Position of the grievant.
4. The written documents relating to Section 5 of the grievance procedure.
Software Requirements 7 Developer shall prepare the Project Schedule using Oracle’s Primavera P6.
Specific Requirements compensation insurance with statutory limits required by South Dakota law. Coverage B-Employer’s Liability coverage of not less than $500,000 each accident, $500,000 disease-policy limit, and $500,000 disease-each employee.
