Applicable Standards for the Work Sample Clauses

Applicable Standards for the Work. Subject to the remedies provided for herein, Contractor shall perform the Work and turn the Project over to Owner in a manner that is: (i) sufficient, complete and adequate in all respects necessary for the Project to successfully achieve WTG Mechanical Completion for each WTG Shipment on or before the Guaranteed Mechanical Completion Date; (ii) in conformance with professional standards and skill, expertise and diligence of design and construction professionals regularly involved in wind power projects of similar size and nature to the Project; (iii) in compliance with the terms of this Agreement, all Applicable Laws and Applicable Permits and Applicable Standards; and (iv) approved as to form, use and content by public and private entities authorized to administer or enforce any building or construction code or standard whose approval of the final design of the Project, or any portion thereof, is necessary for the construction, operation of the Project, or interconnection of the Project in compliance with the Interconnection Agreement.
Sample 1
AutoNDA by SimpleDocs
Applicable Standards for the Work. Subject to the remedies provided for herein, Contractor shall perform the Work and turn the Project over to Owner in a manner that is: (i) sufficient, complete and adequate in all respects necessary for the Project to successfully achieve WTG Mechanical Completion for each WTG Shipment on or before the Guaranteed Mechanical Completion Date for that WTG Shipment, respectively; (ii) in conformance with professional standards and skill, expertise and diligence of design and construction professionals regularly involved in wind power projects of similar size and nature to the Project; (iii) in compliance with the terms of this Agreement, the Utilities’ switching procedures, as set forth in Exhibit L, all Applicable Laws and Applicable Permits and Applicable Standards; and
Sample 1
Applicable Standards for the Work. Subject to the remedies provided for herein, Contractor shall perform the Work and turn the Project over to Owner in a manner that is:
Sample 1

Related to Applicable Standards for the Work

  • Applicable Standards The requirements and guidelines of NERC, the Applicable Regional Entity, and the Control Area in which the Customer Facility is electrically located; the PJM Manuals; and Applicable Technical Requirements and Standards.

  • Contract Work Hours and Safety Standards Act The following clauses apply to any Federal-aid construction contract in an amount in excess of $100,000 and subject to the overtime provisions of the Contract Work Hours and Safety Standards Act. These clauses shall be inserted in addition to the clauses required by 29 CFR 5.5(a) or 29 CFR 4.6. As used in this paragraph, the terms laborers and mechanics include watchmen and guards.

  • CONTRACT WORK HOURS AND SAFETY STANDARDS As per the Contract Work Hours and Safety Standards Act (40 U.S.C. 3701-3708), where applicable, all Customer Purchase Orders in excess of ,000 that involve the employment of mechanics or laborers must include a provision for compliance with 40 U.S.C. 3702 and 3704, as supplemented by Department of Labor regulations (29 CFR Part 5). Under 40 U.S.C. 3702 of the Act, each contractor must be required to compute the wages of every mechanic and laborer on the basis of a standard work week of 40 hours. Work in excess of the standard work week is permissible provided that the worker is compensated at a rate of not less than one and a half times the basic rate of pay for all hours worked in excess of 40 hours in the work week. The requirements of 40 U.S.C. 3704 are applicable to construction work and provide that no laborer or mechanic must be required to work in surroundings or under working conditions which are unsanitary, hazardous or dangerous. These requirements do not apply to the purchases of supplies or materials or articles ordinarily available on the open market, or contracts for transportation or transmission of intelligence.

  • Design Criteria and Standards All Projects/Services shall be performed in accordance with instructions, criteria and standards set forth by the Director.

  • Quality Standards Each Party agrees that the nature and quality of its products and services supplied in connection with the other Party's Marks will conform to quality standards set by the other Party. Each Party agrees to supply the other Party, upon request, with a reasonable number of samples of any Materials publicly disseminated by such Party which utilize the other Party's Marks. Each Party will comply with all applicable laws, regulations, and customs and obtain any required government approvals pertaining to use of the other Party's marks.

  • Specifications and Standards a) All articles supplied shall strictly conform to the specifications, trademark laid down in the bidding document and wherever articles have been required according to ISI/ ISO/ other applicable specifications/ certifications/ standards, those articles should conform strictly to those specifications/ certifications/ standards. The supply shall be of best quality and description. The decision of the competent authority/ purchase committee whether the articles supplied conforms to the specifications shall be final and binding on the supplier/ selected bidder.

  • Service Level Standards In addition to all other requirements in this Agreement, and in accordance with the Best Claims Practices & Estimating Guidelines, Vendor shall use reasonable and good faith efforts to meet the Service Level Standards set forth below.

  • Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.

  • CERTIFICATION REGARDING DRUG-FREE WORKPLACE REQUIREMENTS 1. The Contractor certifies that it will provide a drug-free workplace by: a. Publishing a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the Contractor’s workplace and specifying the actions that will be taken against employees for violation of such prohibition;

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!