Application for Site Plan Approval Sample Clauses

Application for Site Plan Approval. Each Governmental Application submitted by or on behalf of the Redeveloper in connection with the Redevelopment Project shall conform in all material respects to the Redevelopment Plan and all Applicable Laws; provided, however, that nothing herein shall be construed as limiting the Redeveloper’s ability to apply for reasonable bulk or area variances or waivers as may necessary or appropriate under the circumstances and in accordance with the applicable provisions of the Redevelopment Plan.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Application for Site Plan Approval. Each Governmental Application submitted by or on behalf of the Redeveloper in connection with the Redevelopment Project shall conform in all material respects to the Redevelopment Plan and all Applicable Laws; provided, however, that nothing herein shall be construed as limiting the Redeveloper’s ability to apply for reasonable bulk or area variances or waivers as may necessary or appropriate under the circumstances and in accordance with the applicable provisions of the Redevelopment Plan. Within ninety (90) days following the Effective Date, Redeveloper shall at a minimum have filed with the Planning Board a Governmental Application seeking at least preliminary site plan approval for Phase 2A of the Project. Unless tolled as provided in the following sentence, Redeveloper’s failure to file a bona fide application for Phase 2A site plan approval by such date or to diligently pursue that application after filing it shall constitute a Default by Redeveloper in the performance of its obligations hereunder. Notwithstanding the foregoing, if Redeveloper is unable to submit a Phase 2A site plan within the timeframe provided herein because of delays arising out of or in connection with ISRA compliance, then upon Notice of such delay to the Township Redeveloper’s obligation to file the Phase 2A site shall be tolled for a period equal to the delay, but in no event to exceed a total of an additional ninety (90) days.
Sample 1Sample 2

Related to Application for Site Plan Approval

  • Application for approval 3.1. The application for approval of a vehicle type with regard to braking shall be submitted by the vehicle manufacturer or by his duly accredited representative.

  • Application for Use a. The Employer agrees to accept properly executed leave applications within six (6) months of the first day of the period of leave being requested.

  • IRS Plan Approval Articles I through VIII of the agreement used to establish this Xxxx XXX have been approved by the IRS. The IRS approval is a determination only as to form. It is not an endorsement of the plan in operation or of the investments offered.

  • Application Approval Our representative will notify you (or one of you, if there are co-applicants) of the Application approval, execute the Lease agreements for signature prior to occupancy, and, once complete, credit the application deposit of all applicants toward the required security deposit.

  • Motion for Preliminary Approval The Parties agree to jointly prepare and file a motion for preliminary approval (“Motion for Preliminary Approval”) that complies with the Court’s current checklist for Preliminary Approvals.

  • Deadline for Submission of Bids 19.1 Bids must be received by the Purchaser at the address specified under ITB Clause 18.2 no later than the time and date specified in the Bid Data Sheet. 19.2 The Purchaser may, at its discretion, extend this deadline for the submission of bids by amending the bidding documents in accordance with ITB Clause 7, in which case all rights and obligations of the Purchaser and bidders previously subject to the deadline will thereafter be subject to the deadline as extended.

  • New Application for Licensure Any time after the three-month period has lapsed from the Effective Date of this Agreement and Respondent has paid the Administrative Penalty set forth in Section III, Paragraph 1 of this Order, Respondent may apply for a new mortgage loan originator license or, as applicable, petition for the reinstatement of an MLO Activity Endorsement in any or all of the Participating States with the understanding that each State Mortgage Regulator reserves the rights to fully investigate such application for licensure or petition for reinstatement of an MLO Activity Endorsement and may either approve or deny such application or petition pursuant to the normal process for such licensing or endorsement investigations. No license application or petition described in this paragraph will be denied solely based on the facts, circumstances, or consensual resolution provided for in this Agreement. Respondent further agrees that Respondent must satisfy the Administrative Penalty provision prior to submitting an application for a new mortgage loan originator license or, as applicable, petition for the reinstatement of an MLO Activity Endorsement.

  • Application for Service (a) You must comply with any application form or process we specify.

  • 000 APPLICATION FOR PROJECT AGREEMENT 1.100 Any Company desiring to enter into a Project Agreement for Maintenance by Contract, must appear before the General Presidents' Committee (hereinafter the "Committee") for purposes of review and orientation and present to the Committee written evidence of the Owner's intent to engage that Company in the performance of maintenance service for a minimum period of one full year, subject to the usual termination clauses in such contracts.

  • Plan Approval 5.5.1.1 The A/E shall secure the required structural, plumbing, HVAC, and electrical plan approvals.

Time is Money Join Law Insider Premium to draft better contracts faster.