Application of this Warranty Sample Clauses

Application of this Warranty. 6.1 This Warranty applies only to those Parts sold to You by Komatsu and used within Australia within the Warranty Period. 6.2 This Warranty is conditional upon the Machine being maintained by You in accord with the Maintenance Program. 6.3 This Warranty does not apply: (a) if You breach or do not comply with any of Your Responsibilities in item 4. above or otherwise; (b) if any Defect is caused or contributed to by Your misuse, negligence, accident, or failure to maintain or use the Machine or the Part in accordance with the Maintenance Program or the recommendations of Komatsu or the OEM; (c) if any Defect arises as a result of or in connection with, a condition identified through the Maintenance Program or otherwise, for which Komatsu has recommended certain action to You and You fail to comply with that recommendation; (d) in relation to alterations, modifications or repairs to a Part or Machine, including the fitting of attachments parts or use of consumables, that are not authorised or approved by Komatsu and which in Komatsu’s reasonable judgment, cause or contribute to the Defect; (e) to repairs or replacements required due to normal maintenance or operating services for the Machines or Parts, including but not limited to inspections, adjustments, tune-ups, fuel, lubricants, or Consumables, routine or scheduled parts repairs or replacements; (f) if You have delayed more than seven (7) days in notifying of any potential Defect after first becoming aware of it; (g) if You have unreasonably delayed in providing the Machine or Part to Komatsu after first becoming aware of it; (h) if You fail to adhere to any recommendation made by Komatsu; (i) if You fail to supply the Required Documents when requested by Komatsu; or (j) if Komatsu in its sole discretion determines any use or installation of the Machine or Part has caused or contributed to the Defect. 6.4 If otherwise applicable, the Vienna Convention (Contracts for the International sale of Goods) does not apply to this Warranty or the Machine or Parts and is excluded in its entirety.
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs

Related to Application of this Warranty

  • Application of this Agreement This Agreement applies to the Land and to the Development proposed in the Development Application, as may be modified.

  • Registration of this Agreement 8.1 The Parties agree this Agreement is to be registered by the Registrar-General as provided for in section 7.6 of the Act. 8.2 The Developers warrant that they have done everything necessary to enable this Agreement to be registered under section 7.6 of the Act. 8.3 Without limiting clause 8.2, the Developers warrant that they have obtained the express written consent to the registration of this Agreement under section 7.6 of the Act from: (a) If this Agreement relates to land under the Real Property Act 1900, each person who has an estate or interest in the Land registered under that Act; or (b) If this Agreement relates to land not under the Real Property Act 1900, each person who is seized or in possessed of an estate or interest in the Land. 8.4 Within 14 days of entering into this Agreement and prior to the issue of any Construction Certificate that relates to any building work, other than demolition, excavation, piling, shoring and ancillary work for construction purposes including site hoardings and temporary site sheds that relates to works contained in DA-152/2021/B, the Developers will at their cost arrange and effect registration of this Agreement under s7.6 upon the title to the Land and as soon as possible will: (a) deliver to the Council the Registration Application in registrable form noting the Council as applicant and executed by the o wner of the Land and any other person the subject of the warranty in clause 8.3; (b) provide the Council with a cheque in favour of NSW Land Registry Services, for the registration fees for registration of this Agreement; (c) provide the Council with a cheque in favour of the Council for its reasonable costs, expenses and fees incurred or to be incurred in connection with the preparation of this Agreement and any documents, form or instrument created or to be created in accordance with the provisions of this Agreement; and (d) take any other necessary action so as to ensure this Agreement is registered on the title to the Land prior to the issue of any Construction Certificate that relates to any building work, other than demolition, excavation, piling, shoring and ancillary work for construction purposes including site hoardings and temporary site sheds that relates to works contained in DA-152/2021/B. 8.5 Upon compliance with clause 8.4 by the Developers, the Council will promptly lodge the Registration Application with the Registrar General. 8.6 The Parties will co-operate with each other to ensure that the Agreement is registered by the Registrar General. 8.7 Upon payment of the Development Contribution, the Developers may request the removal of the dealing created by registration of the Agreement from the title to the Land. The Council will not withhold its consent to such removal, provided the Developers pay all reasonable costs, expenses and fees of the Council relating to such removal. 8.8 Should payment of the Development Contribution occur upon the date of this Agreement and prior to issue of a Construction Certificate that relates to any building work, other than demolition, excavation, piling, shoring and ancillary work for construction purposes including site hoardings and temporary site sheds that relates to works contained in DA-152/2021/B, then there will be no obligation to register this Agreement in accordance with this clause nor provide the Bank Guarantee in accordance with clause 9.1. 8.9 Upon registration of this Agreement by the Registrar General, this Agreement is binding on, and is enforceable against the owner of the Land from time to time as if each owner for the time being had entered into this Agreement.

  • Construction of this Agreement The Parties agree that each Party and its legal counsel have reviewed and revised this Agreement and that any rule of construction to the effect that ambiguities are to be resolved against the drafting Party shall not apply in the interpretation of this Agreement or any amendments or exhibits thereto.

  • Examination of this Agreement A copy of this Agreement shall be available at all reasonable times at the office of the Right Agent in the Borough of Manhattan, City and State of New York, for inspection by the registered holder of any Right. The Right Agent may require any such holder to submit his, her or its Right for inspection by it.

  • Variation of this Agreement ‌ This Agreement may be varied during its term by agreement in writing by the parties subject to the ratification process of the Union.

  • Authorization of this Agreement This Agreement has been duly authorized, executed and delivered by or on behalf of such Selling Stockholder.

  • Termination of this Agreement Prior to the Closing Date, this Agreement may be terminated by the Representatives by notice given to the Company if at any time: (i) trading or quotation of any of the Company’s securities shall have been suspended or limited by the Commission or by the New York Stock Exchange (the “NYSE”), or trading in securities generally on either the Nasdaq Stock Market or the NYSE shall have been suspended or limited, or minimum or maximum prices shall have been generally established on any of such quotation system or stock exchange by the Commission or FINRA; (ii) a general banking moratorium shall have been declared by any of federal, New York or Washington authorities; (iii) there shall have occurred any outbreak or escalation of national or international hostilities or any crisis or calamity, or any change in the United States or international financial markets, or any substantial change or development involving a prospective substantial change in United States’ or international political, financial or economic conditions, as in the judgment of the Representatives is material and adverse and makes it impracticable or inadvisable to proceed with the offering sale or delivery of the Securities in the manner and on the terms described in the Pricing Disclosure Package or to enforce contracts for the sale of securities; (iv) in the judgment of the Representatives there shall have occurred any Material Adverse Change; or (v) the Company shall have sustained a loss by strike, fire, flood, earthquake, accident or other calamity of such character as in the judgment of the Representatives may interfere materially with the conduct of the business and operations of the Company regardless of whether or not such loss shall have been insured. Any termination pursuant to this Section 10 shall be without liability on the part of (x) the Company to any Initial Purchaser, except that the Company shall be obligated to reimburse the expenses of the Initial Purchasers pursuant to Sections 4 and 6 hereof, (y) any Initial Purchaser to the Company, or (z) any party hereto to any other party except that the provisions of Sections 8 and 9 hereof shall at all times be effective and shall survive such termination.

  • Duration of this Agreement The Term of this Agreement shall be as specified in Schedule A hereto.

  • Modification of this Agreement This Agreement may not be modified, nor may compliance with any of its terms be waived, except as noted in Section 11.1, “Notices to Parties,” regarding change in personnel or place, and except by written instrument executed and approved in the same manner as this Agreement. Contractor shall cooperate with Department to submit to the Director of CMD any amendment, modification, supplement or change order that would result in a cumulative increase of the original amount of this Agreement by more than 20% (CMD Contract Modification Form).

  • Operation of this Agreement This Agreement shall take effect on and from the date of this Agreement. The parties must execute and enter into this Agreement as soon as possible after the Development Consent is granted and prior to the issue of any Construction Certificate that relates to any building work, other than demolition, excavation, piling, shoring and ancillary work for construction purposes including site hoardings and temporary site sheds that relates to works contained in DA-152/2021/B.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!