Authority to Stop or Suspend Work Sample Clauses

Authority to Stop or Suspend Work. The District, Architect, and Inspector of Record each have the authority to stop or suspend some or all of the Work if: (i) they determine in their reasonable judgment that conditions are unsuitable for proceeding with the Work, including, without limitation, if harm or damage to persons or property reasonably may result if the Work were to proceed; (ii) the Contractor fails to correct Defective Work as directed; or (iii) the Contractor fails to carry out the Work in a manner that ensures it will be completed in accordance with the Contract Documents. The Contractor shall immediately comply with, and shall cause each Subcontractor to immediately comply with, each order to stop or suspend the Work. The Contractor shall not permit the stopped or suspended portion of the Work to resume until so ordered. In no event shall the District, Architect or Inspector of Record be liable for any failure to identify situations in which the Work arguably should or could have been stopped or suspended, and no such failure shall be deemed or construed to relieve the Contractor from its obligation to complete the Work in accordance with the Contract Documents.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to Authority to Stop or Suspend Work

  • CERTIFICATION REGARDING DEBARMENT OR SUSPENSION Contractor certifies that neither Contractor or its principals; its subcontractors or their principals; the sub-recipients (if applicable) or their principals are suspended, debarred, proposed for debarment, voluntarily excluded from covered transactions, or otherwise disqualified by any federal department or agency from doing business with the Federal Government pursuant to Executive Orders 12549 and 12689. Contractor specifically covenants that neither the Contractor or its principals, its sub-contractors or their principals, or the sub-recipients (if applicable) or their principals are included on the Excluded Parties List System (“EPLS”) maintained by the General Services Administration (“GSA”).

  • TEN TERMINATION OR SUSPENSION CONTRACTOR shall be considered in material default of this Agreement and such default will be considered cause for OWNER to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) failure to begin work under the Agreement within the times specified under the Notice(s) to Proceed, or (b) failure to properly and timely perform the services to be provided hereunder or as directed by OWNER, or (c) the bankruptcy or insolvency or a general assignment for the benefit of creditors by CONTRACTOR or by any of CONTRACTOR's principals, officers or directors, or (d) failure to obey laws, ordinances, regulations or other codes of conduct, or (e) failure to perform or abide by the terms or spirit of this Agreement, or (f) for any other just cause. The OWNER may so terminate this Agreement, in whole or in part, by giving the CONTRACTOR seven (7) calendar day’s written notice.

  • Authorization for Secured Party to Take Certain Action (a) Each Grantor irrevocably authorizes the Collateral Agent at any time and from time to time in the sole discretion of the Collateral Agent and appoints the Collateral Agent as its attorney in fact (i) to execute on behalf of such Grantor as debtor and to file financing statements necessary or desirable in the Collateral Agent’s sole discretion to perfect and to maintain the perfection and priority of the Collateral Agent’s security interest in the Collateral, (ii) to endorse and collect any cash Proceeds of the Collateral, (iii) to file a carbon, photographic or other reproduction of this Security Agreement or any financing statement with respect to the Collateral as a financing statement and to file any other financing statement or amendment of a financing statement (which does not add new collateral or add a debtor) in such offices as the Collateral Agent in its sole discretion deems necessary or desirable to perfect and to maintain the perfection and priority of the Collateral Agent’s security interest in the Collateral, (iv) to contact and enter into one or more agreements with the issuers of uncertificated securities which are Pledged Collateral or with securities intermediaries holding Pledged Collateral as may be necessary or advisable to give the Collateral Agent Control over such Pledged Collateral, (v) to apply the Proceeds of any Collateral received by the Collateral Agent to the Secured Obligations as provided in Section 7.3, (vi) to discharge past due taxes, assessments, charges, fees or Liens on the Collateral (except for such Liens as are specifically permitted hereunder), (vii) to contact Account Debtors for any reason, (viii) to demand payment or enforce payment of the Receivables in the name of the Collateral Agent or such Grantor and to endorse any and all checks, drafts, and other instruments for the payment of money relating to the Receivables, (ix) to sign such Grantor’s name on any invoice or xxxx of lading relating to the Receivables, drafts against any Account Debtor of such Grantor, assignments and verifications of Receivables, (x) to exercise all of such Grantor’s rights and remedies with respect to the collection of the Receivables and any other Collateral, (xi) to settle, adjust, compromise, extend or renew the Receivables, (xii) to settle, adjust or compromise any legal proceedings brought to collect Receivables, (xiii) to prepare, file and sign such Grantor’s name on a proof of claim in bankruptcy or similar document against any Account Debtor of such Grantor, (xiv) to prepare, file and sign such Grantor’s name on any notice of Lien, assignment or satisfaction of Lien or similar document in connection with the Receivables, (xv) to change the address for delivery of mail addressed to such Grantor to such address as the Collateral Agent may designate and to receive, open and dispose of all mail addressed to such Grantor, and (xvi) to do all other acts and things necessary to carry out this Security Agreement; and such Grantor agrees to reimburse the Collateral Agent on demand for any payment made or any expense incurred by the Collateral Agent in connection with any of the foregoing; provided that, this authorization shall not relieve such Grantor of any of its obligations under this Security Agreement or under the Credit Agreement. (b) All acts of said attorney or designee are hereby ratified and approved. The powers conferred on the Collateral Agent, for the benefit of the Collateral Agent and Secured Parties, under this Section 6.2 are solely to protect the Collateral Agent’s interests in the Collateral and shall not impose any duty upon the Collateral Agent or any Lender to exercise any such powers.

  • TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Architect’s option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, the Architect shall give seven days’ written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.2 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days’ written notice. § 9.4 Either party may terminate this Agreement upon not less than seven days’ written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination. § 9.5 The Owner may terminate this Agreement upon not less than seven days’ written notice to the Architect for the Owner’s convenience and without cause. § 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall compensate the Architect for services performed prior to termination, Reimbursable Expenses incurred, and costs attributable to termination, including the costs attributable to the Architect’s termination of consultant agreements. § 9.7 In addition to any amounts paid under Section 9.6, if the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall pay to the Architect the following fees:

  • BANKRUPTCY, DEBARMENT, OR SUSPENSION CERTIFICATION Supplier certifies and warrants that it is not in bankruptcy or that it has previously disclosed in writing certain information to Sourcewell related to bankruptcy actions. If at any time during this Contract Supplier declares bankruptcy, Supplier must immediately notify Sourcewell in writing. Supplier certifies and warrants that neither it nor its principals are presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from programs operated by the State of Minnesota; the United States federal government or the Canadian government, as applicable; or any Participating Entity. Supplier certifies and warrants that neither it nor its principals have been convicted of a criminal offense related to the subject matter of this Contract. Supplier further warrants that it will provide immediate written notice to Sourcewell if this certification changes at any time.

  • AUTHORITY TO MODIFY No modification or change in this Agreement shall be valid and enforceable against UNICEF unless provided by a written amendment to this Agreement signed by a duly authorized officer of UNICEF and an Authorized Officer of IP.

  • Dismissal or Suspension Grievance (a) In the case of a dispute arising from an employee's dismissal, the grievance may be filed directly at arbitration within thirty (30) days of the date on which the dismissal occurred, or within thirty (30) days of the employee receiving notice of dismissal. (b) In the case of a dispute arising from an employee's suspension, the grievance may commence at Step 2 of the grievance procedure within thirty (30) days of the date on which the suspension occurred, or within thirty (30) days of the employee receiving notice of suspension.

  • Purchaser's Election to Delay Foreclosure Proceedings (a) The Purchaser shall be deemed to direct the Company to direct (to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement) the related Servicer that in the event that the Company does not receive written notice of the Purchaser's election pursuant to subsection (b) below within 24 hours (exclusive of any intervening non-Business Days) of transmission of the notice provided by the Company under Section 2.01 (a) (ii) subject to extension as set forth in Section 2.02(b), the related Servicer may proceed with the Commencement of Foreclosure in respect of such Mortgage Loan in accordance with its normal foreclosure policies without further notice to the Purchaser. Any foreclosure that has been initiated may be discontinued (i) without notice to the Purchaser if the Mortgage Loan has been brought current or if a refinancing or prepayment occurs with respect to the Mortgage Loan (including by means of a short payoff approved by the related Servicer) or (ii) if the related Servicer has reached the terms of a forbearance agreement with the borrower. In the latter case, the related Servicer may complete such forbearance agreement unless instructed otherwise by the Purchaser within two Business Days notification. (b) In connection with any Mortgage Loan with respect to which a notice under Section 2.01(a)(ii) has been given to the Purchaser, the Purchaser may elect to instruct the Company to cause, to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement, the related Servicer to delay the Commencement of Foreclosure until such time as the Purchaser determines that the related Servicer may proceed with the Commencement of Foreclosure. Such election must be evidenced by written notice received within 24 hours (exclusive of any intervening non-Business Days) of transmission of the notice provided by the Company under Section 2.01(a)(ii). Such 24 hour period shall be extended for no longer than an additional four Business Days after the receipt of the information if the Purchaser requests additional information related to such foreclosure; provided, however, that the Purchaser will have at least one Business Day to respond to any requested additional information. Any such additional information shall be provided only to the extent it (i) is not confidential in nature and (ii) is obtainable by the related Servicer from existing reports, certificates or statements or is otherwise readily accessible to its servicing personnel. The Purchaser agrees that it has no right to deal with the mortgagor during such period. However, if such servicing activities include acceptance of a deed-in-lieu of foreclosure or short payoff, the Purchaser will be notified and given two Business Days to respond. (c) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Delay Foreclosure, the Purchaser shall obtain a Current Appraisal as soon as practicable, but in no event more than 15 business days thereafter, and shall provide the Company with a copy of such Current Appraisal. (d) Within two Business Days of making any Election to Delay Foreclosure, the Purchaser shall remit by wire transfer to the Company, for deposit in the Collateral Fund, an amount, as calculated by the Company, equal to the sum of (i) 125% of the greater of the unpaid principal balance of the Mortgage Loan and the value shown in the Current Appraisal referred to in subsection (c) above (or, if such Current Appraisal has not yet been obtained, the Company's estimate thereof, in which case the required deposit under this subsection shall be adjusted upon obtaining such Current Appraisal), and (ii) three months' interest on the Mortgage Loan at the applicable Mortgage Interest Rate. If any Election to Delay Foreclosure extends for a period in excess of three months (such excess period being referred to herein as the "Excess Period"), within two Business Days the Purchaser shall remit by wire transfer in advance to the Company for deposit in the Collateral Fund the amount of each additional month's interest, as calculated by the Company, equal to interest on the Mortgage Loan at the applicable Mortgage Interest Rate for the Excess Period. The terms of this Agreement will no longer apply to the servicing of any Mortgage Loan upon the failure of the Purchaser to deposit any of the above amounts relating to the Mortgage Loan within two Business Days of the Election to Delay Foreclosure or within two Business Days of the commencement of the Excess Period subject to Section 3.01. (e) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Delay Foreclosure, the Company may withdraw from the Collateral Fund from time to time amounts necessary to reimburse the related Servicer for all related Monthly Advances and Liquidation Expenses thereafter made by such Servicer in accordance with the Pooling and Servicing Agreement and the related Servicing Agreement. To the extent that the amount of any such Liquidation Expenses is determined by the Company based on estimated costs, and the actual costs are subsequently determined to be higher, the Company may withdraw the additional amount from the Collateral Fund. In the event that the Mortgage Loan is brought current by the mortgagor and the foreclosure action is discontinued, the amounts so withdrawn from the Collateral Fund shall be redeposited if and to the extent that reimbursement therefor from amounts paid by the mortgagor is not prohibited pursuant to the Pooling and Servicing Agreement or the related Servicing Agreement, applicable law or the related mortgage note. Except as provided in the preceding sentence, amounts withdrawn from the Collateral Fund to cover Monthly Advances and Liquidation Expenses shall not be redeposited therein or otherwise reimbursed to the Purchaser. If and when any such Mortgage Loan is brought current by the mortgagor, all amounts remaining in the Collateral Fund in respect of such Mortgage Loan (after adjustment for all permitted withdrawals and deposits pursuant to this subsection) shall be released to the Purchaser. (f) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Delay Foreclosure, the related Servicer shall continue to service the Mortgage Loan in accordance with its customary procedures (other than the delay in Commencement of Foreclosure as provided herein). If and when the Purchaser shall notify the Company that it believes that it is appropriate to do so, the related Servicer may proceed with the Commencement of Foreclosure. In any event, if the Mortgage Loan is not brought current by the mortgagor by the time the loan becomes 6 months delinquent, the Purchaser's election shall no longer be effective and at the Purchaser's option, either (i) the Purchaser shall purchase the Mortgage Loan from the related Trust Estate at a purchase price equal to the fair market value as shown on the Current Appraisal, to be paid by (x) applying any balance in the Collateral Fund to such to such purchase price, and (y) to the extent of any deficiency, by wire transfer of immediately available funds from the Purchaser to the Company for deposit in the related Certificate Account; or (ii) the related Servicer shall proceed with the Commencement of Foreclosure. (g) Upon the occurrence of a liquidation with respect to any Mortgage Loan as to which the Purchaser made an Election to Delay Foreclosure and as to which the related Servicer proceeded with the Commencement of Foreclosure in accordance with subsection (f) above, the Company shall calculate the amount, if any, by which the value shown on the Current Appraisal obtained under subsection (c) exceeds the actual sales price obtained for the related Mortgaged Property (net of Liquidation Expenses and accrued interest related to the extended foreclosure period), and the Company shall withdraw the amount of such excess from the Collateral Fund, shall remit the same to the Trust Estate and in its capacity as Master Servicer shall apply such amount as additional Liquidation Proceeds pursuant to the Pooling and Servicing Agreement. After making such withdrawal, all amounts remaining in the Collateral Fund in respect of such Mortgage Loan (after adjustment for all permitted withdrawals and deposits pursuant to this Agreement) shall be released to the Purchaser.

  • Dismissal or Suspension Grievances (a) In the case of a dispute arising from an employee’s dismissal, the grievance may be filed directly at Step 3, within thirty (30) days of the date on which the dismissal occurred, or within thirty (30) days of the employee receiving notice of dismissal. (b) In the case of a dispute arising from an employee’s suspension, the grievance may commence at Step 2 of the grievance procedure within thirty (30) days of the date on which the suspension occurred, or within (30) days of the employee receiving notice of suspension.

  • Evaluation License If You are licensing the Software for evaluation purposes, Your use of the Software is only permitted in a non-production environment and for the period limited by the License Key. Notwithstanding any other provision in this XXXX, an Evaluation License of the Software is provided “AS-IS” without indemnification, support or warranty of any kind, expressed or implied.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!