Overriding powers of the Authority (i) If in the reasonable opinion of the Authority, the Contractor is in material breach of its obligations under this Agreement and, in particular, the Maintenance Requirements, and such breach is causing or likely to cause material hardship or danger to the Users and pedestrians, the Authority may, without prejudice to any of its rights under this Agreement including Termination thereof, by notice require the Contractor to take reasonable measures immediately for rectifying or removing such hardship or danger, as the case may be.
(ii) In the event that the Contractor, upon notice under Clause 14.9 (i), fails to rectify or remove any hardship or danger within a reasonable period, the Authority may exercise overriding powers under this Clause 14.9 (ii) and take over the performance of any or all the obligations of the Contractor to the extent deemed necessary by it for rectifying or removing such hardship or danger; provided that the exercise of such overriding powers by the Authority shall be of no greater scope and of no longer duration than is reasonably required hereunder; provided further that any costs and expenses incurred by the Authority in discharge of its obligations hereunder shall be recovered by the Authority from the Contractor, and the Authority shall be entitled to deduct any such costs and expenses incurred from the payments due to the Contractor under Clause 19.7 for the performance of its Maintenance obligations.
(iii) In the event of a national emergency, civil commotion or any other circumstances specified in Clause 21.3, the Authority may take over the performance of any or all the obligations of the Contractor to the extent deemed necessary by it, and exercise such control over the Project Highway or give such directions to the Contractor as may be deemed necessary; provided that the exercise of such overriding powers by the Authority shall be of no greater scope and of no longer duration than is reasonably required in the circumstances which caused the exercise of such overriding power by the Authority. For the avoidance of doubt, it is agreed that the consequences of such action shall be dealt in accordance with the provisions of Article 21. It is also agreed that the Contractor shall comply with such instructions as the Authority may issue in pursuance of the provisions of this Clause 14.9 (iii), and shall provide assistance and cooperation to the Authority, on a best effort basis, for performance of its obligations hereunder.
The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).
Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works.
(iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor:
(a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre.
(b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7
(c) all environmental clearances as required under Clause 4.3.8
(iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
Restrictions on Business There shall be no restrictions on the business that Amalco may carry on.
Restrictions on Business Activities There is no agreement, commitment, judgment, injunction, order or decree binding upon Company or its subsidiaries or to which Company or any of its subsidiaries is a party which has or could reasonably be expected to have the effect of prohibiting or materially impairing any business practice of Company or any of its subsidiaries, any acquisition of property by Company or any of its subsidiaries or the conduct of business by Company or any of its subsidiaries as currently conducted.
Authority to Carry on Business The Trustee represents to the Corporation that at the date of execution and delivery by it of this Indenture it is authorized to carry on the business of a trust company in each of the provinces and territories of Canada but if, notwithstanding the provisions of this Section 14.14, it ceases to be so authorized to carry on business, the validity and enforceability of this Indenture and the Debentures issued hereunder shall not be affected in any manner whatsoever by reason only of such event but the Trustee shall, within 60 days after ceasing to be authorized to carry on the business of a trust company in any of the provinces and territories of Canada, either become so authorized or resign in the manner and with the effect specified in Section 14.2.
Routes All bus stops and bus routes will be mutually agreed upon prior to the start of the school year. Additional stops will be not be added until approved by SSAS and reviewed for safety and approved by the School Board’s Transportation Department. Route changes, if approved, will require 7 calendar days from the date of request to the date of implementation. Special needs transportation requests must be made a minimum of 14 days prior to the requested date of implementation.
Activities of the Adviser The services of the Adviser to the Fund hereunder are not to be deemed exclusive, and the Adviser and any of its affiliates shall be free to render similar services to others. Subject to and in accordance with the Agreement and Declaration of Trust and By-Laws of the Trust and Section 10(a) of the 1940 Act, it is understood that trustees, officers, agents and shareholders of the Trust are or may be interested in the Adviser or its affiliates as directors, officers, agents or stockholders; that directors, officers, agents or stockholders of the Adviser or its affiliates are or may be interested in the Trust as trustees, officers, agents, shareholders or otherwise; that the Adviser or its affiliates may be interested in the Fund as shareholders or otherwise; and that the effect of any such interests shall be governed by said Agreement and Declaration of Trust, By-Laws and the 1940 Act.
Power of the Authority to undertake works (i) In the event the Parties are unable to agree to the proposed Change of Scope Orders in accordance with Clause 13.2, the Authority may, after giving notice to the Contractor and considering its reply thereto, award such Works or services to any person or agency on the basis of open competitive bidding. It is also agreed that the Contractor shall provide assistance and cooperation to the person or agency who undertakes the works or services hereunder. The Contractor shall not be responsible for rectification of any Defects, but the Contractor shall carry out maintenance of such works after completion of Defect Liability Period of work by other person or agency during the remaining period of this agreement without any extra payment.
(ii) The Works undertaken in accordance with this Clause 13.5 shall conform to the Specifications and Standards and shall be carried out in a manner that minimises the disruption in operation of the Project Highway. The provisions of this Agreement, insofar as they relate to Works and Tests, shall apply mutatis mutandis to the Works carried out under this Clause 13.5.
Other Activities of the Administrator Nothing herein shall prevent the Administrator or its Affiliates from engaging in other businesses or, in its sole discretion, from acting in a similar capacity as an Administrator for any other Person even though such Person may engage in business activities similar to those of the Issuer, the Owner Trustee or the Indenture Trustee.
