Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of subsection 4.7 of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.
B. Such liquidated damages shall be calculated as an amount equaling the difference between:
1. All sums identified for payment to MWBEs had the Contractor achieved the contractual MWBE goals; and
2. All sums actually paid to MWBEs for work performed or materials supplied under the Contract.
C. If OGS determines that Contractor is liable for liquidated damages and such identified sums have not been withheld by OGS, Contractor shall pay such liquidated damages to OGS within sixty (60) days after they are assessed. Provided, however, that if the Contractor has filed a complaint with the Director of the Division of Minority and Women’s Business Development pursuant to 5 NYCRR § 142.12, liquidated damages shall be payable only in the event of a determination adverse to the Contractor following the complaint process.
Breach of Contract The failure of the Contractor to comply with any of the provisions, covenants or conditions of this Contract shall be a material breach of this Contract. In such event the County may, and in addition to any other remedies available at law, in equity, or otherwise specified in this Contract:
a) Terminate the Contract immediately, pursuant to Section K herein;
b) Afford the Contractor written notice of the breach and ten (10) calendar days or such shorter time that may be specified in this Contract within which to cure the breach;
c) Discontinue payment to the Contactor for and during the period in which the Contractor is in breach; and
d) Offset against any monies billed by the Contractor but yet unpaid by the County those monies disallowed pursuant to the above.
Breach of Amendment This Amendment shall be part of the Loan Agreement and a breach of any representation, warranty or covenant herein shall constitute an Event of Default.
Breach of Contract Claims [Option (Include if University prefers an abbreviated Breach of Contract Claims provision): To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.]
19.1 To the extent that Chapter 2260, Texas Government Code, as it may be amended from time to time (Chapter 2260), is applicable to this Agreement and is not preempted by other Applicable Laws, the dispute resolution process provided for in Chapter 2260 will be used, as further described herein, by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor:
12.19.1.1 Contractor’s claims for breach of this Agreement that the parties cannot resolve pursuant to other provisions of this Agreement or in the ordinary course of business will be submitted to the negotiation process provided in subchapter B of Chapter 2260. To initiate the process, Contractor will submit written notice, as required by subchapter B of Chapter 2260, to University in accordance with the notice provisions in this Agreement. Contractor's notice will specifically state that the provisions of subchapter B of Chapter 2260 are being invoked, the date and nature of the event giving rise to the claim, the specific contract provision that University allegedly breached, the amount of damages Contractor seeks, and the method used to calculate the damages. Compliance by Contractor with subchapter B of Chapter 2260 is a required prerequisite to Contractor's filing of a contested case proceeding under subchapter C of Chapter 2260. The chief business officer of University, or another officer of University as may be designated from time to time by University by written notice to Contractor in accordance with the notice provisions in this Agreement, will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims.
12.19.1.2 If the parties are unable to resolve their disputes under Section 12.19.1.1, the contested case process provided in subchapter C of Chapter 2260 is Contractor’s sole and exclusive process for seeking a remedy for any and all of Contractor's claims for breach of this Agreement by University.
12.19.1.3 Compliance with the contested case process provided in subchapter C of Chapter 2260 is a required prerequisite to seeking consent to xxx from the Legislature under Chapter 107,
Material Breach of Contract In the event Contractor fails to deliver the product and services as contracted for herein, to the satisfaction of the City of Sparks or otherwise fails to perform any provisions of this Contract, the City, after providing five (5) days written notice and Contractor’s failure to cure such breach within the time specified in the notice, may without waiving any other remedy, make good the deficiencies and deduct the actual cost of providing alternative products and/or services from payment due the Contractor. Non-performance after the first notice of non-performance shall be considered a material breach of contract.
Breach of Confidentiality Contractor acknowledges that there can be no adequate remedy at law for any breach of Contractor’s obligations hereunder, that any such breach will likely result in irreparable harm, and therefore, that upon any breach or threatened breach of the confidentiality obligations, the Court shall be entitled to appropriate equitable relief, without the requirement of posting a bond, in addition to its other remedies at law. INDEMNIFICATION
Breach of Obligations The Parties acknowledge that a breach of any of the obligations contained herein would result in injuries. The Parties further acknowledge that the amount of the liquidated damages or the method of calculating the liquidated damages specified in this Agreement is a genuine and reasonable pre-estimate of the damages that may be suffered by the non-defaulting party in each case specified under this Agreement.
Indemnification Obligation The Offerors shall jointly and severally indemnify and hold harmless the Placement Agents and the Purchaser and each of their respective agents, employees, officers and directors and each person that controls either of the Placement Agents or the Purchaser within the meaning of Section 15 of the Securities Act or Section 20 of the Exchange Act, and agents, employees, officers and directors or any such controlling person of either of the Placement Agents or the Purchaser (each such person or entity, an “Indemnified Party”) from and against any and all losses, claims, damages, judgments, liabilities or expenses, joint or several, to which such Indemnified Party may become subject under the Securities Act, the Exchange Act or other federal or state statutory law or regulation, or at common law or otherwise (including in settlement of any litigation, if such settlement is effected with the written consent of the Offerors), insofar as such losses, claims, damages, judgments, liabilities or expenses (or actions in respect thereof) arise out of, or are based upon, or relate to, in whole or in part, (a) any untrue statement or alleged untrue statement of a material fact contained in any information (whether written or oral) or documents executed in favor of, furnished or made available to the Placement Agents or the Purchaser by the Offerors, or (b) any omission or alleged omission to state in any information (whether written or oral) or documents executed in favor of, furnished or made available to the Placement Agents or the Purchaser by the Offerors a material fact required to be stated therein or necessary to make the statements therein not misleading, and shall reimburse each Indemnified Party for any legal and other expenses as such expenses are reasonably incurred by such Indemnified Party in connection with investigating, defending, settling, compromising or paying any such loss, claim, damage, judgments, liability, expense or action described in this Section 9.1. In addition to their other obligations under this Section 9, the Offerors hereby agree that, as an interim measure during the pendency of any claim, action, investigation, inquiry or other proceeding arising out of, or based upon, or related to the matters described above in this Section 9.1, they shall reimburse each Indemnified Party on a quarterly basis for all reasonable legal or other expenses incurred in connection with investigating or defending any such claim, action, investigation, inquiry or other proceeding, notwithstanding the absence of a judicial determination as to the propriety and enforceability of the possibility that such payments might later be held to have been improper by a court of competent jurisdiction. To the extent that any such interim reimbursement payment is so held to have been improper, each Indemnified Party shall promptly return such amounts to the Offerors together with interest, determined on the basis of the prime rate (or other commercial lending rate for borrowers of the highest credit standing) announced from time to time by First Tennessee Bank National Association (the “Prime Rate”). Any such interim reimbursement payments which are not made to an Indemnified Party within 30 days of a request for reimbursement shall bear interest at the Prime Rate from the date of such request.
NO BREACH OF CONTRACT The Executive hereby represents to the Company that: (i) the execution and delivery of this Agreement by the Executive and the performance by the Executive of the Executive’s duties hereunder shall not constitute a breach of, or otherwise contravene, the terms of any other agreement or policy to which the Executive is a party or otherwise bound, except for agreements entered into by and between the Executive and any member of the Group pursuant to applicable law, if any; (ii) that the Executive has no information (including, without limitation, confidential information and trade secrets) relating to any other person or entity which would prevent, or be violated by, the Executive entering into this Agreement or carrying out his duties hereunder; (iii) that the Executive is not bound by any confidentiality, trade secret or similar agreement (other than this) with any other person or entity except for other member(s) of the Group, as the case may be.
Breach of Agreement Failure by the party to comply with or perform any agreement or obligation (other than an obligation to make any payment under this Agreement or delivery under Section 2(a)(i) or 2(e) or to give notice of a Termination Event or any agreement or obligation under Section 4(a)(i), 4(a)(iii) or 4(d)) to be complied with or performed by the party in accordance with this Agreement if such failure is not remedied on or before the thirtieth day after notice of such failure is given to the party;
