Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements.
(b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.
Tenant Improvement Allowance Items Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord only for the following items and costs (collectively, the “Tenant Improvement Allowance Items”):
2.2.1.1 Payment of the fees of the “Architect” and the “Engineers,” as those terms are defined in Section 3.1 of this Tenant Work Letter, the costs of Tenant’s project manager (if any) and payment of the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord’s consultants in connection with the preparation and review of the “Construction Drawings,” as that term is defined in Section 3.1 of this Tenant Work Letter;
2.2.1.2 The payment of plan check, permit and license fees relating to construction of the Tenant Improvements;
2.2.1.3 The cost of construction of the Tenant Improvements, including, without limitation, contractors’ fees and general conditions, testing and inspection costs, costs of utilities, trash removal, parking and hoists, and the costs of after-hours freight elevator usage.
2.2.1.4 The cost of any changes in the Base, Shell and Core work when such changes are required by the Construction Drawings (including if such changes are due to the fact that such work is prepared on an unoccupied basis), such cost to include all direct architectural and/or engineering fees and expenses incurred in connection therewith;
2.2.1.5 The cost of any changes to the Construction Drawings or Tenant Improvements required by applicable laws and building codes (collectively, “Code”);
2.2.1.6 Sales and use taxes;
2.2.1.7 The “Coordination Fee,” as that term is defined in Section 4.2.2.2 of this Tenant Work Letter; and
2.2.1.8 All other costs to be expended by Landlord in connection with the construction of the Tenant Improvements.
Construction Allowance (a) Landlord shall provide to Tenant a construction allowance not to exceed $135.00 per rentable square foot in the Relocation Premises (the “Construction Allowance”) to be applied toward the Total Construction Costs, as adjusted for any changes to the Tenant Work. If the Total Construction Costs are estimated to exceed the Construction Allowance by more than $5.00 per rentable square foot of the Relocation Premises, then no advance of the Construction Allowance shall be made by Landlord until Tenant has first paid to the contractor from its own funds (and provided reasonable evidence thereof to Landlord) the anticipated amount by which the projected Total Construction Costs exceed the amount of the Construction Allowance. Thereafter, Landlord shall pay to Tenant (or at Tenant’s request directly to Tenant’s general contractor) the Construction Allowance in multiple disbursements (but not more than once in any calendar month) following the receipt by Landlord of the following items: (i) a request for payment and sworn statements of Tenant and contractor, (ii) final or partial lien waivers, as the case may be, from all persons performing work or supplying or fabricating materials for the Tenant Work, fully executed, acknowledged and in recordable form, which waivers may be conditioned upon receipt of payment, (iii) the Architect’s certification that the Tenant Work for which reimbursement has been requested has been finally completed, including (with respect to the last application for payment only) any punch-list items, on the appropriate AIA form or another form approved by Landlord, and, (iv) with respect to the disbursement of the last 10% of the Construction Allowance, (1) the permanent certificate of occupancy issued for the Relocation Premises, if required by applicable law, (2) the record drawing in CAD format, PDF format and hard copy required by Section 5 above, and (3) an estoppel certificate confirming such factual matters as Landlord or Landlord’s Mortgagee may reasonably request (collectively, a “Completed Application for Payment”). Landlord shall pay the amount requested in the applicable Completed Application for Payment to Tenant within 30 days following Tenant’s submission of the Completed Application for Payment. If, however, the Completed Application for Payment is incomplete or incorrect, Landlord shall promptly notify Tenant of the same and Landlord’s payment of such request shall be deferred until 30 days following Landlord’s receipt of the corrected Completed Application for Payment. Notwithstanding anything to the contrary contained in this Exhibit, Landlord shall not be obligated to make any disbursement of the Construction Allowance during the pendency of any of the following: (1) Landlord has received written notice of any unpaid claims relating to any portion of the Tenant Work or materials in connection therewith covered by previously funded applications for payment, (2) there is an unbonded lien outstanding against the Building or the Relocation Premises or Tenant’s interest therein by reason of work done, or claimed to have been done, or materials supplied or specifically fabricated, claimed to have been supplied or specifically fabricated, to or for Tenant or the Relocation Premises, (3) the conditions to the advance of the Construction Allowance are not satisfied, or (4) Tenant is in Default under the Lease.
(b) The Construction Allowance must be used on Tenant Work performed within the Relocation Premises and the Total Construction Costs and may not be used to pay for furniture, fixtures or equipment or as rent abatement, HOWEVER, notwithstanding the foregoing, provided Tenant is not in Default, Tenant may use a portion of the Construction Allowance, not to exceed an amount equal to $35.00 per rentable square foot of the Relocation Premises, to pay for furniture, fixtures or equipment, moving costs, cabling costs, and other soft costs associated with the Relocation Premises. Should Tenant elect to use a portion of the Construction Allowance to pay for such soft costs, at Landlord’s request Tenant shall execute and deliver a letter to Landlord confirming the exact amount of the Construction Allowance used to pay for such soft costs. Should Tenant elect to use a portion of the Construction Allowance to pay for such costs, Tenant shall provide Landlord with a written request that includes copies of paid invoices or receipts for reimbursement of such costs, and Landlord shall reimburse Tenant for such amounts within 30 days of receipt of Tenant’s request. Tenant shall provide lien waivers as appropriate. No portion of the Construction Allowance may be used as a credit against Rent due under the Lease.
(c) The Construction Allowance must be used (i.e. work performed and invoices submitted to Landlord) by June 30, 2020, or the Construction Allowance shall be deemed forfeited with no further obligation by Landlord with respect thereto.
(d) If Landlord defaults in Landlord’s obligation to pay the Construction Allowance pursuant to Section 9 of this Exhibit B-1, or any portion thereof, within five (5) days after the date the same is due, then Tenant shall have the right to give Landlord a second written notice (“Offset Exercise Notice”) requesting payment of such unpaid amounts and notifying Landlord that Tenant intends to offset against rent if not paid. In the event that Landlord fails to contest in good faith or fully pay such amounts within ten (10) business days after such Offset Exercise Notice is received by Landlord, then provided no Default exists Tenant may withhold and offset such unpaid sums from and against 25% of Base Rent next due until paid.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Construction Phase Fee Contractor’s Construction Phase Fee is the maximum amount payable to Contractor for any cost or profit expectation incurred in the performance of the Work that is not specifically identified as being eligible for reimbursement by Owner elsewhere in this Agreement. References in the UGSC to Contractor’s “overhead” and “profit” mean Contractor’s Construction Phase Fee. The Construction Phase Fee includes, but is not limited to, the following items:
9.1 All profit, profit expectations and costs associated with profit sharing plans such as personnel bonuses, incentives, and rewards; company stock options; or any other like expenses of Contractor.
Construction Phase Services 3.1.1 – Basic Construction Services
Tenant Improvement Allowance Commencing as of January 1, 2011, Tenant shall be entitled to use the “Tenant Improvement Allowance”, as defined in Section 2 of this Amendment, for the costs relating to the design and construction of Tenant’s improvements or which are otherwise “Tenant Improvement Allowance items,” as that term is defined in Section 2.2.1, below (collectively, the “Tenant Improvements”). In no event shall Landlord be obligated to make disbursements pursuant to this Tenant Work Letter or otherwise in connection with Tenant’s construction of the Tenant Improvements or any Tenant Improvement Allowance Items, as defined below, in a total amount which exceeds the sum of the Tenant Improvement Allowance. All Tenant Improvements for which the Tenant Improvement Allowance has been made available shall be deemed Landlord’s property under the terms of the Lease; provided, however, Landlord may, by written notice to Tenant given concurrently with Landlord’s approval of the “Final Working Drawings”, as that term is defined in Section 3.3, below, require Tenant, prior to the end of the Lease Term or promptly following any earlier termination of this Lease, at Tenant’s expense, to remove any Tenant Improvements and to repair any damage to the Premises and Building caused by such removal and return the affected portion of the Premises to a Building standard general office condition; provided, however, that Landlord shall not require Tenant to remove upon termination or expiration of this Lease, or condition its approval upon Tenant’s agreement to remove upon termination or expiration of this Lease, any Tenant Improvements constructed pursuant to this Tenant Work Letter (including, without limitation, Larc improvements) which constitute standard, non-extraordinary improvements for ordinary office, laboratory and/or Larc uses in biotech facilities. Any portion of the Tenant Improvement Allowance that is not disbursed or allocated for disbursement by December 31, 2013, shall revert to Landlord and Tenant shall have no further rights with respect thereto.
Disbursement of Tenant Improvement Allowance During the construction of the Tenant Improvements, Landlord shall make monthly disbursements of the Tenant Improvement Allowance for Tenant Improvement Allowance Items for the benefit of Tenant and shall authorize the release of monies for the benefit of Tenant as follows.
Construction Phase Part 1 –
