Restoration of Property In the event Railroad authorizes Contractor to take down any fence of Railroad or in any manner move or disturb any of the other property of Railroad in connection with the work to be performed by Contractor, then in that event Contractor shall, as soon as possible and at Contractor's sole expense, restore such fence and other property to the same condition as the same were in before such fence was taken down or such other property was moved or disturbed. Contractor shall remove all of Contractor's tools, equipment, rubbish and other materials from Railroad's property promptly upon completion of the work, restoring Railroad's property to the same state and condition as when Contractor entered thereon.
POSSESSION AND OCCUPATION 3.1 The CONTRACTOR, its agents, servants and subcontractors shall at all times until the Works have been completed and the OWNER has signed and handed to the CONTRACTOR the final completion form, be entitled to enter and be present on the property for construction purposes. The CONTRACTOR shall further be entitled to enter into and be present on the property for purposes of completing minor works and snags listed on the snag list.
3.2 At no time whatsoever shall the OWNER be entitled to make claim, attach or in any way claim possession or retention of any of the CONTRACTOR's tools, equipment or building material and by signature hereof the OWNER waives all or any right which he may have acquired in this regard.
3.3 The OWNER shall be obliged to take occupation and possession of the Works at a date agreed upon between the parties but not later than 14 (fourteen) days after the handover date and it shall be incumbent on the OWNER to monitor progress of the Works in order to enable him to make whatever arrangements which may be necessary or required by him to:
3.3.1 take possession and occupation of the Works;
3.3.2 make payment of all or any amounts which may then still be due by him to the CONTRACTOR.
3.4 Should the OWNER fail to take occupation and possession of the Works as provided in clause 3.3 OR on such other date as may be agreed between the parties in writing –
3.4.1 it shall irrevocably be deemed for all purposes hereunder, that the OWNER has effectively and fully taken occupation and possession of the property and Works as set out in clause 3.3 and that all items on the snag list have been completed and accepted by the OWNER;
3.4.2 the CONTRACTOR shall not be responsible for any damages to the property after the deemed occupation date and the OWNER shall at his own cost provide security for the property against any vandalism and/or theft and/or any other damages thereto.
3.5 The CONTRACTOR shall, within 14 (fourteen) days from the commencement date as defined in clause 1.1.12, inform the OWNER of the estimated occupation date in writing. It is recorded that -
3.5.1 subject to the bond being registered and/or required proof regarding payment arrangements being submitted by the estimated building commencement date, the date on which the OWNER shall be able to occupy the property is estimated to be approximately 150 (one hundred and fifty) days after the commencement date, subject to the provisions of clause 5.6.
3.5.2 should the CONTRACTOR be unable to meet the estimated occupation date defined in clause 1.1.12 and referred to in clause 3.5.1, he shall be obliged to inform the OWNER in writing thereof at least 30 (thirty) days in advance.
Restoration of Premises Lessee shall conduct all operations on the Leased Premises in such a manner as not to unreasonably damage the portion of the Leased Premises where there will be no mining operations. Lessee shall conduct all operations in such a manner as to observe and comply with all Laws applicable to the Leased Premises and all Laws applicable to the conduct of Lessee’s operations. Lessee expressly agrees to dispose of all tailings and other mining wastes in accordance with all applicable Laws and shall reclaim all of disturbed perimeter portions of any lakes created by mining such that those perimeter portions shall be left at a slope no steeper than four feet horizontal to one foot vertical within three (3) months of termination of the Lease Agreement. By the expiration or earlier termination of the term of this Lease Agreement, Lessee shall grade that portion of the Leased Premises which has been excavated by Lessee or on which Lessee has conducted operations so as to eliminate all unreasonable irregularities therein and so that such portion of the Leased Premises which has been excavated by Lessee conforms to the drawing set forth on Exhibit C attached hereto. Upon completion of the required grading, Lessee shall cover such area with sand, clay, or topsoil, or a mixture of any of the foregoing, from the resources then existing on the Leased Premises, and shall thereafter reseed the surface with a seed mixture approved by Lessor. Notwithstanding the foregoing, in no event shall Lessee be required to import any Materials, including but not limited to, sand, clay, or topsoil from off-site for purposes of complying with its restoration obligations in this Section 15. Should this obligation not be met by the end of the term of this Lease Agreement, it shall nevertheless survive and continue beyond the term of this Lease Agreement and shall be an obligation owed by Lessee to Lessor. This obligation is owed by Lessee in addition to any other obligation imposed upon Lessee by this Lease Agreement.
Abandonment of Premises If the property becomes vacant during the term of this lease, and if at the time of the vacancy Tenant are in default in the payment of any installment of rent, then the rent for the entire term shall become at once due and payable and Landlord may proceed to collect rent for said entire premises, with or without process of law, to take possession thereof, to remove any and all property there from and store as required by law, to lease the premises as agent of Tenant, and to apply the proceeds received from such letting toward the payment of Tenant' rent under this lease; such re-entry and re-letting shall not discharge Tenant from liability for rent, nor from any other obligation under the terms of this lease.
Condition of Premises Lessor makes no warranty or representation as to the Premises. Lessee acknowledges and agrees that it has occupied and familiarized itself with the Premises and has had adequate opportunity to investigate and inspect the condition of the Premises, and enters into this Lease upon the basis of its own review, and is leasing the Premises in their “AS IS, WHERE IS” CONDITION WITH ALL FAULTS, WHETHER PREVIOUSLY EXISTING OR ARISING FROM OR PERTAINING TO ANY CONSTRUCTION, RENOVATION, RELOCATION OR IMPROVEMENT OF ANY PORTION OF THE PREMISES PERFORMED BY LESSOR OR OTHERS, INCLUDING BUT NOT LIMITED TO BOTH LATENT AND PATENT DEFECTS. EXCEPT AS EXPRESSLY SET FORTH TO THE CONTRARY IN THIS LEASE, NO WARRANTIES, EXPRESS OR IMPLIED, ARE MADE BY LESSOR OR ANY OF ITS AFFILIATES CONCERNING SUCH ITEMS, INCLUDING BUT NOT LIMITED TO, WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE. LESSEE HEREBY WAIVES AND DISCLAIMS ANY WARRANTIES THAT MAY ARISE BY OPERATION OF LAW. Lessee further acknowledges and agrees that it has had an opportunity to review and to discuss with various agents and/or representatives of Lessor the environmental condition of the Premises. Lessee has investigated and has knowledge of operative or proposed governmental laws and regulations including, without limitation, environmental laws and regulations to which the Premises are or may be subject and enters into this Lease upon the basis of its review and determination of the applicability and effect of such laws and regulations. Lessee acknowledges that Lessor expressly disclaims any representations or warranties of any kind or nature, express or implied, as to the condition (financial or otherwise), value or quality of the products, assets or properties of the Premises. Lessee hereby accepts the Premises in their condition existing as of the date hereof, subject to all applicable zoning, municipal, county and state laws, ordinances and regulations governing and regulating the use of the Premises, and accepts this Lease subject thereto and to all matters disclosed thereby and by any exhibits attached hereto. Lessee hereby agrees that all furniture, equipment, machinery and all other personal property, excepting any computers, that are located on or in the Premises as of the date hereof shall remain on the Premises as and when Lessee evacuates the Premises on the Termination Date or any extension thereof.
Inspection of Premises Landlord and Landlord's agents shall have the right at all reasonable times during the term of this Agreement and any renewal thereof to enter the Premises for the purpose of inspecting the Premises and all buildings and improvements thereon. And for the purposes of making any repairs, additions or alterations as may be deemed appropriate by Landlord for the preservation of the Premises or the building. Landlord and its agents shall further have the right to exhibit the Premises and to display the usual "for sale", "for rent" or "vacancy" signs on the Premises at any time within forty-five (45) days before the expiration of this Lease. The right of entry shall likewise exist for the purpose of removing placards, signs, fixtures, alterations or additions, that do not conform to this Agreement or to any restrictions, rules or regulations affecting the Premises.
DESTRUCTION OF PREMISES (A) If, during the term of this Lease, the Leased Premises are totally or partially destroyed by fire or the elements, so as to render the premises wholly unfit for occupancy, or make it impossible in the opinion of a licensed third party arbitrator knowledgeable in the child care business reasonably acceptable to Lessee and Lessor, for Lessee to conduct its business therein, then either Lessor or Lessee shall have the right to terminate this Lease from the date of such damage or destruction by giving written notice. The parties agree to use reasonable promptness to obtain the opinion of such licensed third party arbitrator. Upon the giving of such notice, Lessee shall immediately surrender the Leased Premises and all interest therein to Lessor, and in case of any such termination, Lessor may re-enter and repossess the Leased Premises and may dispossess all parties then in possession thereof. If not otherwise terminated, in the event the Leased Premises shall be repaired, restored, and rebuilt by Lessee with the use of insurance proceeds (which Lessor shall cooperate to make available), but otherwise at its own sole cost and expense, within one hundred eighty (180) days from the date of destruction (subject to force majuere as set forth in paragraph C hereof, then all rents payable by Lessee shall be abated during the period of repair and restoration to the extent Lessor shall be compensated by the proceeds of rents loss insurance. In no event shall Lessor be required to provide its own money for the repair or restoration of the Leased Premises other than the net proceeds of moneys received by it from any insurance policy or policies covering such loss or damages. Lessee shall be liable for repair of the Leased Premises with all reasonable speed, and the rents shall recommence on the date that the repairs are completed. Lessee shall be under no obligation to so repair during the last five (5) years of the term of the Lease, or as extended, but if Lessee shall desire to rebuild during the last 12 months of the Lease term, Lessor will make insurance proceeds available to rebuild the Leased Premises conditioned upon Lessee then exercising its next renewal option under the Lease. Lessor will make insurance proceeds available to rebuild the Leased Premises in the event Lessee rebuilds, except as stated above.
(B) If the damage does not, in the opinion of a licensed third party arbitrator reasonably acceptable to Lessee and Lessor, render the Leased Premises unfit for occupancy, then Lessor agrees that the damage shall be repaired as soon as practicable and in that case, Lessee shall pay full rent during the repair period. All repairs shall be paid for by Lessee out of any insurance proceeds received (which Lessor shall cooperate to make available), but if the insurance proceeds are insufficient to rebuild or repair the Leased Premises according to the original plans and specifications, whether repair or restoration is commenced pursuant to paragraph A or B hereof, then Lessee agrees to pay all additional amounts that are required to rebuild the building in accordance with the original plans and specifications. All improvements or betterments placed by Lessee on the demised premises shall, however, in any event, be repaired and replaced by Lessee at its own expense and not at the expense of Lessor. The purpose of this Article is to require Lessee to carry insurance coverage on the Leased Premises sufficient to rebuild the improvements in the event of damage or destruction. Lessee shall be under no obligation to so rebuild during the last five (5) years of the term, as extended, as the case may be, but if Lessee shall desire to rebuild during the last 12 months of the Lease term, Lessor will make insurance proceeds available to rebuild the Leased Premises conditioned upon Lessee then exercising its next renewal option under the Lease. Lessor will make insurance proceeds available to rebuild the Leased Premises in the event Lessee rebuilds, except as stated above. Risk that the insurance company shall be insolvent or shall refuse to make insurance proceeds available shall be with Lessee. The Leased Premises shall be so restored or rebuilt so as to be of at least equal value and substantially the same character as prior to such damage or destruction. If the insurance proceeds are less than $100,000 they shall be paid to Lessee for such repair and restoration. If the insurance proceeds are greater than or equal to $100,000 they shall be deposited by Lessee and Lessor into a customary construction escrow at a nationally recognized title insurance company, or at Lessee's option, with Lessor ("Escrowee") and shall be made available from time to time to Lessee for such repair and restoration. Such proceeds shall be disbursed in conformity with the terms and conditions of a commercially reasonable construction loan agreement. Lessee shall, in either instance, deliver to Lessor or Escrowee (as the case may be) satisfactory evidence of the estimated cost of completion together with such architect's certificates, waivers of lien, contractor's sworn statements and other evidence of cost and of payments as the Lessor or Escrowee may reasonably require and approve. If the estimated cost of the work exceeds One Hundred Thousand Dollars ($100,000), all plans and specifications for such rebuilding or restoration shall be subject to the reasonable approval of Lessor.
(C) Lessee shall comply with the time period stated above for restoration of the Leased Premises as set forth in this Article; provided, however, that said period of time shall be extended for a period or periods of time equal to any period or periods of delay caused by strikes, lockouts, fire, or other casualty, the elements, acts of God, delay by or refusal or failure of governmental authorities to grant necessary permits and approvals for the reconstruction of the Leased Premises (Lessee agreeing to use reasonable diligence to procure the same), or other causes other than financial, beyond Lessee's reasonable control or the reasonable control of Lessee's contractor.
POSSESSION OF PREMISES Tenant shall not be entitled to possession of the premises designated for lease until the security deposit and first month’s rent (or prorated portion thereof), less any applicable promotional discount, is paid in full and the premises designated for lease is vacated by the prior tenant.
Tenant’s Compliance With Landlord’s Fire and Casualty Insurance Tenant shall, at Tenant’s expense, comply with all insurance company requirements pertaining to the use of the Premises. If Tenant’s conduct or use of the Premises causes any increase in the premium for such insurance policies then Tenant shall reimburse Landlord for any such increase. Tenant, at Tenant’s expense, shall comply with all rules, orders, regulations or requirements of the American Insurance Association (formerly the National Board of Fire Underwriters) and with any similar body.
Possession and Occupancy The Seller will deliver possession and occupancy of the Property to the Buyer at Closing. The Seller shall provide access to all locks, including keys, remote controls, and any security/access codes, necessary to operate all locks, mailboxes, and security systems.
