Order Acceptance Xxxxxxx’x acceptance of the Order and consequent agreement to the Contract by either: (a) delivering the Goods, Services, or Digital Services; or
Card Acceptance When accepting a Card, Xxxxxxxx will follow the steps provided by Servicer for accepting Cards and will: (a) determine in good faith and to the best of its ability that the Card is valid on its face; (b) obtain Authorization from the Card Issuer to charge the Cardholder's account; (c) unless the Sales Draft is electronically generated or is the result of a mail, internet, phone or preauthorized order, (i) obtain an Imprint of the Card including embossed data from the merchant imprinter plate; and (ii) obtain the Cardholder's signature on the Sales Draft and compare that signature to the signature on the Card; (d) enter a description of the goods or services sold and the price thereof (including any applicable taxes); (e) deliver a true and completed copy of the Sales Draft to the Cardholder at the time the goods are delivered or services performed, or, if the Sales Draft is prepared by a point-of-sale terminal, at the time of the sale; (f) offer the Sales Draft to Servicer for purchase according to Servicer's procedures and the terms of this Agreement; and (g) make a Card Imprint, if the Transaction is not based upon a mail, internet, phone or pre-authorized order.
Payment Does Not Imply Acceptance of Work The granting of any payment by City, or the receipt thereof by Contractor, shall in no way lessen the liability of Contractor to replace unsatisfactory work, equipment, or materials, although the unsatisfactory character of such work, equipment or materials may not have been apparent or detected at the time such payment was made. Materials, equipment, components, or workmanship that do not conform to the requirements of this Agreement may be rejected by City and in such case must be replaced by Contractor without delay.
PRODUCT ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor in the Authorized User Agreement, Authorized User(s) shall have sixty (60) days from the date of delivery to accept all Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Title or other property interest and risk of loss shall not pass from Contractor to the Authorized User until the Products have been accepted. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty
Purchase Order Duration Purchase orders issued pursuant to this State Term Contract must be received by the Contractor no later than close of business on the last day of the Contract’s term to be considered timely. The Contractor is obliged to fill those orders in accordance with the Contract’s terms and conditions. Purchase orders received by the Contractor after close of business on the last day of the State Term Contract’s term shall be considered void. Purchase orders for a one-time performance of contractual services shall be valid through the performance by the Contractor, and all terms and conditions of the State Term Contract shall apply to the single delivery/performance, and shall survive the termination of the Contract. Contractors are required to accept purchase orders specifying delivery schedules exceeding the contracted schedule even when such extended delivery will occur after expiration of the State Term Contract. For example, if a state term contract calls for delivery 30 days after receipt of order (ARO), and an order specifies delivery will occur both in excess of 30 days ARO and after expiration of the state term contract, the Contractor will accept the order. However, if the Contractor expressly and in writing notifies the ordering office within ten (10) calendar days of receipt of the purchase order that Contractor will not accept the extended delivery terms beyond the expiration of the state term contract, then the purchase order will either be amended in writing by the ordering entity within ten (10) calendar days of receipt of the contractor’s notice to reflect the state term contract delivery schedule, or it shall be considered withdrawn. The duration of purchase orders for recurring deliveries of commodities or performance of services shall not exceed the expiration of the State Term Contract by more than twelve months. However, if an extended pricing plan offered in the State Term Contract is selected by the Customer, the Contract terms on pricing plans shall govern the maximum duration of purchase orders reflecting such pricing plans. Timely purchase orders shall be valid through their specified term and performance by the Contractor, and all terms and conditions of the State Term Contract shall apply to the recurring delivery/performance as provided herein, and shall survive the termination of the Contract. Ordering offices shall not renew a purchase order issued pursuant to a State Term Contract if the underlying contract expires prior to the effective date of the renewal.
Inspection; Acceptance The Contractor (immixTechnology, Inc.) can only, and shall only tender for acceptance those items that substantially conform to the software manufacturer’s (“Qualtrics”) published specifications. Therefore, items delivered shall be considered accepted upon delivery. The Government reserves the right to inspect or test any supplies or services that have been delivered. The Government may require repair or replacement of nonconforming supplies or re-performance of nonconforming services at no increase in contract price. If repair/replacement or re-performance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights-(1) Within the warranty period; and (2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.
Purchase Order Number NETAPP's purchase order number must appear on all invoices, packing lists and bills of lading and shall appear on each package, container or envelope on each shipment made pursuant to such purchase order.
Deemed Acceptance You are required to accept the terms and conditions set forth in this Agreement prior to the first vest date in order for you to receive the Award granted to you hereunder. If you wish to decline this Award, you must reject this Agreement prior to the first vest date. For your benefit, if you have not rejected the Agreement prior to the first vest date, you will be deemed to have automatically accepted this Award and all the terms and conditions set forth in this Agreement. Deemed acceptance will allow the shares to be released to you in a timely manner and once released, you waive any right to assert that you have not accepted the terms hereof.
Purchase Order A Customer may use purchase orders to buy commodities or contractual services pursuant to the Contract and, if applicable, the Contractor must provide commodities or contractual services pursuant to purchase orders. Purchase orders issued pursuant to the Contract must be received by the Contractor no later than the close of business on the last day of the Contract’s term. The Contractor is required to accept timely purchase orders specifying delivery schedules that extend beyond the Contract term even when such extended delivery will occur after expiration of the Contract. Purchase orders shall be valid through their specified term and performance by the Contractor, and all terms and conditions of the Contract shall survive the termination or expiration of the Contract and apply to the Contractor’s performance. The duration of purchase orders for recurring deliverables shall not exceed the expiration of the Contract by more than twelve months. Any purchase order terms and conditions conflicting with these Special Contract Conditions shall not become a part of the Contract.
Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.
