Change Order as full payment and final settlement Sample Clauses

Change Order as full payment and final settlement. If Owner and Design-Builder reach agreement on the terms of any change in the Work, including any adjustment in the Contract Sum or Guaranteed Completion Date(s), such agreement shall be incorporated in a Change Order. The Change Order shall constitute full payment and final settlement of all claims for time and for direct, indirect, and consequential costs, including costs of delays, inconvenience, disruption of schedule, or loss of efficiency or productivity, related to any Work either covered or affected by the Change Order, or related to the events giving rise to the request for equitable adjustment.
AutoNDA by SimpleDocs

Related to Change Order as full payment and final settlement

  • Full and Final Settlement 21.1 This agreement is in full and final settlement of all Union or employee claims relating to employee rights and entitlements. Accordingly, the Union or employees shall not pursue any extra claims, nor take any industrial or protest action concerning any matter explicitly or implicitly dealt with in this agreement. 21.2 In any event: (a) Any work that commences or resumes on a day or shift following a stoppage of work not authorised by management, shall attract ordinary time rates of pay until the full duration of the normal ordinary time period has actually been worked, so that employees shall not be over compensated for work that would have been done in ordinary time but for the stoppage. (b) The Union or employees under this agreement shall not encourage or incite employees (or other persons) not covered by this agreement to take industrial or protest action of any kind.

  • Final Settlement The Parties agree and acknowledge that this Compromise Agreement shall constitute a final settlement between the Parties. This Compromise Agreement resolves only issues addressed in the Compromise Agreement.

  • Final Settlement Statement (a) As soon as practical and, in any event, no later than ninety (90) calendar days after the Closing Date, Sellers shall prepare and deliver to Buyer a statement (the “Final Settlement Statement”) setting forth Sellers’ calculation of the adjustments to the Purchase Price in accordance with Section 2.04. The Final Settlement Statement shall be prepared in accordance with this Agreement and on a basis consistent with the preparation of the Closing Statement as described in Section 2.04(d), and shall set forth Sellers’ calculation of the Adjusted Purchase Price. (b) Following the delivery of the Final Settlement Statement, Sellers shall afford Buyer the opportunity to examine the Final Settlement Statement and Sellers’ calculation of the Adjusted Purchase Price, and such supporting schedules and analyses as are reasonably necessary and appropriate in connection with such review. Sellers shall cooperate with Buyer in such examination, including responding to questions asked by Buyer, and Sellers shall make available to Buyer any records under Sellers’ control that are requested by Buyer in connection with such review. (c) If, within thirty (30) calendar days following delivery of the Final Settlement Statement to Buyer, Buyer has not delivered to Sellers written notice (the “Objection Notice”) of Buyer’s objections to the Final Settlement Statement or Sellers’ calculation of the Adjusted Purchase Price (which Objection Notice in order to be valid must contain a statement describing in reasonable detail the items objected to, the basis of such objections and Buyer’s calculation of the amount(s) for the items objected to that Buyer asserts should be used for purposes of the Final Settlement Statement), then the Adjusted Purchase Price as set forth in such Final Settlement Statement shall be deemed final and conclusive. In addition, any of Sellers’ calculations of the Adjusted Purchase Price as set forth in the Final Settlement Statement which are not objected to in the Objection Notice shall be deemed final and conclusive. (d) If Buyer delivers the Objection Notice satisfying Section 2.06(c) above, within such thirty (30)-day period, then Sellers and Buyer shall endeavor in good faith to resolve the objections of Buyer set forth in the Objection Notice for a period not to exceed fifteen (15) calendar days from the date of delivery of the Objection Notice. If at the end of such fifteen (15)-day period there are any objections that remain in dispute, then either Buyer or Sellers may require by written notice to the other that the remaining objections in dispute be submitted for resolution to the Dallas, Texas office of Xxxxx Xxxxxxxx LLP or to such other independent accounting firm as may be selected jointly by Buyer and Sellers within the ten (10) calendar days following a written request by Buyer or Sellers (Xxxxx Xxxxxxxx LLP or such jointly selected accounting firm, the “Referee”). The Referee’s engagement shall be limited to the resolution of disputed amounts set forth in the Final Settlement Statement that have been identified by Buyer in the Objection Notice, which resolution shall be in accordance with this Agreement and no other matter relating to the Final Settlement Statement shall be subject to determination by the Referee except to the extent affected by resolution of the disputed amounts. In connection with the engagement of the Referee, each of Buyer and Sellers shall execute any engagement, indemnity and other agreement as the Referee shall require as a condition to such engagement. If Xxxxx Xxxxxxxx LLP is unable or unwilling to serve as the Referee and Buyer and Sellers are unable to agree upon the designation of a Person as substitute arbitrator, then Buyer or Sellers, or either of them, may in writing request the Bankruptcy Court to appoint the substitute referee; provided that such Person so appointed shall be a national or regional accounting firm with no prior material relationships with Buyer or Sellers or their respective Affiliates and shall have experience in auditing companies engaged in oil and gas wellsite service activities. (e) The Referee shall determine such items of the calculation of the Adjusted Purchase Price as are disputed within thirty (30) calendar days after the objections that remain in dispute are submitted to it. (f) If any disputed items are submitted to the Referee for resolution, (i) each of Buyer and Sellers shall furnish to the Referee such workpapers and other documents and information relating to such disputed items as the Referee may request and are available to that Party or its Affiliates (or its independent public accountants) and will be afforded the opportunity to present to the Referee any materials relating to the determination of the matters in dispute and to discuss such determination with the Referee prior to any written notice of determination hereunder being delivered by the Referee; (ii) the Referee shall not assign a value to such objection that is greater than the greatest value for such objection claimed by either Party or less than the smallest value for such objection claimed by either Party; (iii) the determination by the Referee of items of the calculation of the Adjusted Purchase Price, as applicable, as set forth in a written notice delivered to Sellers and Buyer by the Referee, shall be made in accordance with this Agreement and shall be binding and conclusive on the Parties and shall constitute an arbitral award that is final, binding and unappealable (absent manifest error or fraud) and upon which a judgment may be entered by a court having jurisdiction thereof; and (iv) the fees and expenses of the Referee (the “Audit Fees”) shall be paid by and apportioned between Buyer and Sellers based on the aggregate dollar amount in dispute and the relative recovery as determined by the Referee or Sellers and Buyer, respectively (such that, by way of example, if the amount in dispute is $100 and it is resolved $70 in favor of Buyer and $30 in favor of Sellers, then Sellers would bear 70% of the Audit Fees and Buyer would bear 30% of the Audit Fees).

  • Price Schedule, Payment Terms and Billing, and Price Adjustments (a) Price Schedule: Price Schedule under this Contract is set forth in Exhibit B.

  • Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.

  • Payment of Settlement Amount (1) Within thirty (30) days of the Execution Date, the Settling Defendants shall pay the Settlement Amount to Siskinds LLP for deposit into the Trust Account. The Settlement Amount shall be converted into Canadian currency upon deposit into the Trust Account. (2) The Settling Defendants shall deposit the Settlement Amount into the Trust Account by wire transfer. Siskinds LLP shall provide the necessary wire transfer information to Counsel for the Settling Defendants with reasonable advance notice so that the Settling Defendants have a reasonable period of time to comply with section 3.1(1) of this Settlement Agreement. (3) The Settlement Amount and other consideration to be provided in accordance with the terms of this Settlement Agreement shall be provided in full satisfaction of the Released Claims against the Releasees. (4) The Settlement Amount shall be all-inclusive of all amounts, including without limitation, interest, costs, Class Counsel Fees and Class Counsel Disbursements. (5) The Releasees shall have no obligation to pay any amount in addition to the Settlement Amount, for any reason, pursuant to or in furtherance of this Settlement Agreement or the Proceedings or any Other Actions. (6) Once a Claims Administrator has been appointed, Siskinds LLP shall transfer control of the Trust Account to the Claims Administrator. (7) Siskinds LLP and the Claims Administrator shall maintain the Trust Account as provided for in this Settlement Agreement. While in control of the Trust Account, Siskinds LLP and the Claims Administrator shall not pay out all or part of the monies in the Trust Account, except in accordance with this Settlement Agreement, or in accordance with an order of the Courts obtained after notice to the Parties.

  • C1 Contract Price In consideration of the Contractor’s performance of its obligations under the Contract, the Authority shall pay the Contract Price in accordance with clause C2 (Payment and VAT).

  • Net Out of Settlement Amounts The Non-Defaulting Party shall calculate a Termination Payment by aggregating all Settlement Amounts due under this Agreement or any other agreement(s) between the Company and the BGS-RSCP Supplier for the provision of BGS Supply into a single amount: by netting out (a) all Settlement Amounts that are due or will become due to the Defaulting Party, plus at the option of the Non-Defaulting Party, any cash or other form of security then available to the Non- Defaulting Party and actually received, liquidated and retained by the Non-Defaulting Party, plus any or all other amounts due to the Defaulting Party under this Agreement or any other agreement(s) between the Company and the BGS-RSCP Supplier for the provision of BGS Supply against (b) all Settlement Amounts that are due or will become due to the Non-Defaulting Party, plus any or all other amounts due to the Non-Defaulting Party under this Agreement or any other agreement(s) between the Company and the BGS- RSCP Supplier for the provision of BGS Supply, so that all such amounts shall be netted out to a single liquidated amount; provided, however, that if the BGS-RSCP Supplier is the Defaulting Party and the Termination Payment is due to the BGS-RSCP Supplier, the Company shall be entitled to retain a commercially reasonable portion of the Termination Payment, which may be equal to the entire amount of the Termination Payment, as security for additional amounts that may be determined to be due and owing by the BGS-RSCP Supplier as Damages and further provided that any previously attached security interest of the Company in such retained amounts shall continue. The Termination Payment shall be due to or due from the Non-Defaulting Party as appropriate. If the Termination Payment has been retained by the Company as security for additional amounts that may be determined to be due and owing by the BGS-RSCP Supplier, and if, upon making a final determination of Damages, the Termination Payment, or any portion thereof, is to be made to the BGS-RSCP Supplier, the Company will pay simple interest on the Termination Payment amount being made to the BGS-RSCP Supplier. Simple interest will be calculated at the lower of the Interest Index or six (6) percent per annum.

  • Contract Price and Payment In consideration of the Contractor's due and proper performance of its obligations under the Contract, the Contractor may charge the Authority or, as the case may be, any Beneficiary the Contract Price in accordance with this Clause 6. The only sums payable by the Authority or any Beneficiary to the Contractor for the provision of the Services shall be the Contract Price. All other costs, charges, fees and expenses of whatever kind arising out of or in connection with the Contract shall be the responsibility of the Contractor. In accordance with the Contract, where the Contractor is required to provide Deliverables, the Authority or any Beneficiary shall be entitled to withhold payment of the Contract Price pending receipt and acceptance of the Deliverables in accordance with the Specification. Unless otherwise agreed in writing by the Authority or any Beneficiary and the Contractor, within 15 days of the end of each calendar month, the Contractor shall invoice the Authority or, as the case may be, any Beneficiary for any Services provided by the Contractor in that calendar month. Such invoice shall be rendered on the Contractor's own invoice form clearly marked with the Authority’s or the Beneficiary's order number (if any). Invoices must show the period to which they relate and the aspects of the Services for which payment is claimed together with the agreed charging rates and any other details the Authority or the Beneficiary may require. Failure to provide such information will entitle the Authority or the Beneficiary to delay payment of the Contract Price until such information is provided. Subject to Clauses 6.3 and 6.6, the Authority or any Beneficiary shall pay any invoice submitted by the Contractor in accordance with Clause 6.4 within 30 days of receipt by the Authority or the Beneficiary of such invoice. The Authority or the Beneficiary shall pay such invoice(s) by BACS (Bank Automated Clearing System) if it so chooses or any alternate means as agreed between the Authority or the Beneficiary and the Contractor. The Authority and any Beneficiary shall be entitled to deduct from any monies due or to become due to the Contractor any monies owing to the Authority or the Beneficiary from the Contractor. Where the performance of the Contractor does not meet the required standard then a deduction as set out in the Specification or as agreed by the Parties may be made. Except where otherwise stated in the Order, the Contract Price is exclusive of VAT which shall be payable, if applicable, by the Authority or any Beneficiary in addition to such Contract Price. The invoice provided to the Authority or any Beneficiary by the Contractor in accordance with Clause 6.4 shall show the VAT calculations separately. The Contractor will keep accurate books and records in relation to the provision of the Services in accordance with sound and prudent financial management. All such books and records shall be made available to the Authority at regular intervals of not less than quarterly. In the event of the Authority or any Beneficiary breaching Clause 6.5, the Contractor shall be entitled to charge interest on the outstanding amount owed by the Authority or such Beneficiary in accordance with the Late Payment of Commercial Debts (Interest) Act 1998. Subject to Clauses 6.12 and 6.13, the Contract Price shall not be subject to any increase whatsoever by the Contractor during the Contract Period. In the event that the Contract is varied under Clauses 22 or 23 in such a way as to affect the Contract Price and if agreement between the Parties cannot be reached on the adjustment to the Contract Price within 3 months both Parties shall jointly act to resolve the dispute in accordance with Clause 24. If the adjusted Contract Price is not so agreed or certified until after such variation has taken effect, the Authority or any Beneficiary shall continue to pay the Contractor at the rate current prior to the variation but shall pay to the Contractor or be entitled to recover from the Contractor as the case may be such sum if any as is equal to the difference between the amount which should have been paid in accordance with the adjusted Contract Price and the amount which was actually paid. In the event that the Contract ends or is terminated otherwise than at the end of a complete year, the sum payable by the Authority or any Beneficiary under Clause 6 shall be one twelfth of the annual sum which would otherwise have been payable for the complete year for each completed month.

  • Purchase Price Adjustments (a) Schedule 2.4 sets forth the Seller’s good faith estimate of the Net Working Capital (the “Estimated Net Working Capital”) as of September 30, 2013, together with a calculation of the Closing Purchase Price based on such estimate. The Estimated Net Working Capital shall be determined in accordance with Section 2.6 and the other terms of this Agreement. (b) As promptly as possible, but in any event within forty five (45) days after the Closing Date, the Buyer will deliver to the Seller a balance sheet of the Company (the “Closing Balance Sheet”) and a statement showing the calculation of the Net Working Capital derived from the Closing Balance Sheet (together with the Closing Balance Sheet, the “Preliminary Closing Statement”), in each case as of the Reference Time. The Closing Balance Sheet shall be prepared, and the Net Working Capital and the Preliminary Closing Statement shall be determined, in accordance with Section 2.6 and the definitions and other terms set forth in this Agreement. The Preliminary Closing Statement shall contain line item detail comparable to the Balance Sheet with respect to the components of Net Working Capital of the Company as of the Reference Time. After delivery of the Preliminary Closing Statement, the Buyer shall give the Seller and its accountants and representatives reasonable access at reasonable times to review the Company’s books and records and work papers related to the preparation of the Preliminary Closing Statement subject to customary confidentiality restrictions. The Seller and its accountants and representatives may make inquiries of the Buyer and its accountants regarding questions concerning or disagreements with the Preliminary Closing Statement arising in the course of its review thereof, and the Buyer shall use its commercially reasonable efforts to cause any such accountants to cooperate with and respond to such inquiries. If the Seller has any objections to the Preliminary Closing Statement, the Seller shall deliver to the Buyer a statement setting forth its objections thereto (an “Objections Statement”). If an Objections Statement is not delivered by the Seller to the Buyer within twenty (20) days after delivery of the Preliminary Closing Statement, the Preliminary Closing Statement shall be final, binding and non-appealable by the Parties hereto. The Seller and the Buyer shall negotiate in good faith to resolve any such objections for fifteen (15) days after the delivery of the Objections Statement, but if they do not reach a final resolution, the Seller and the Buyer shall submit such dispute to PricewaterhouseCoopers, or if they are not independent pursuant to the rules and regulations of the Securities and Exchange Commission at the time, another nationally recognized independent accounting firm reasonably acceptable to the Buyer and the Seller (the “Dispute Resolution Firm”) within three (3) Business Days following the end of the fifteen (15)-day period from the date of the delivery of the Objections Statement. Any further submissions to the Dispute Resolution Firm must be written and delivered to each party to the dispute. The Dispute Resolution Firm shall consider work papers and other documents and information related to those items and amounts which are identified in the Objections Statement as being items which the Seller and the Buyer are unable to resolve. The Dispute Resolution Firm’s determination will be based on the definition of Net Working Capital and the other definitions and terms contained herein and shall be in amounts between the disputed amounts set forth in the Preliminary Closing Statement and the Objections Statement. The Seller and the Buyer shall use their commercially reasonable efforts to cause the Dispute Resolution Firm to resolve all disagreements as soon as practicable and in any event within thirty (30) days after the submission of any dispute. Further, the Dispute Resolution Firm’s determination shall be based solely on the presentations by the Buyer and the Seller which are in accordance with the terms and procedures set forth in this Agreement (i.e., not on the basis of an independent review). The resolution of the dispute by the Dispute Resolution Firm shall be, absent manifest error, final, binding and non-appealable on the Parties hereto. The costs and expenses of the Dispute Resolution Firm shall be allocated fifty percent (50%) to the Buyer and fifty percent (50%) to the Seller. (c) If the Net Working Capital as finally determined pursuant to Section 2.4(b) above is greater than the Target Working Capital, the Buyer shall promptly pay to the Seller the amount of such excess in cash. If the Net Working Capital as finally determined pursuant to Section 2.4(b) above is less than the Target Working Capital (such amount, the “Working Capital Deficiency”), the Seller and the Buyer shall promptly cause an amount equal to the Working Capital Deficiency to be paid to the Buyer from the Working Capital Escrow Amount; provided, however, that if the Working Capital Deficiency is in excess of the Working Capital Escrow Amount (such excess amount, the “Working Capital Indemnity Amount”), then the Buyer may elect to seek indemnification for the Working Capital Indemnity Amount either (i) from the Indemnity Escrow Amount or (ii) directly from the Seller. The net adjustment amount payable to the Seller or the Buyer under this Section 2.4(c) (such amount, the “Net Adjustment Amount”) shall be paid in accordance with Section 2.5.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!