Limitations on Liability of Xxxxxxx Mac and Others Neither Xxxxxxx Mac nor any of its directors, officers, employees or agents shall be under any liability to the Holders or Beneficial Owners for any action taken, or not taken, by them in good faith under this Agreement or for errors in judgment. This provision will not protect Xxxxxxx Mac or any other related person against any liability which would otherwise be imposed by reason of willful misfeasance, bad faith or gross negligence or by reason of reckless disregard of obligations and duties under this Agreement. Xxxxxxx Mac and such related persons shall have no liability of whatever nature for special, indirect or consequential damages, lost profits or business, or any other liability or claim (other than for direct damages), even if reasonably foreseeable, or Xxxxxxx Mac has been advised of the possibility of such loss, damage, liability or claim. Xxxxxxx Mac and such related persons may rely in good faith on any document or other communication of any kind properly submitted by any person (in writing or electronically) with respect to any matter arising under this Agreement. In performing its responsibilities under this Agreement, Xxxxxxx Mac may employ agents or independent contractors. Except upon an Event of Default, Xxxxxxx Mac shall not be subject to the control of Holders in any manner in the discharge of its responsibilities pursuant to this Agreement. Xxxxxxx Mac shall be under no obligation to appear in, prosecute or defend any legal action that is not incidental to its responsibilities under this Agreement and which in its opinion may involve it in any expense or liability. However, Xxxxxxx Mac may in its discretion undertake any such legal action which it may deem necessary or desirable in the interests of the Holders. In such event, the legal expenses and costs of such action shall be expenses and costs of Xxxxxxx Mac.
RECORDS USAGE, DUPLICATION AND REDISCLOSURE RESTRICTIONS USAC and the Department agree to these restrictions on use, duplication, and disclosure of information furnished by the other Party:
ROOM CONSOLIDATION Residence assignments shall be consolidated when vacancies occur in any residence facility, to minimize the number of rooms, suites, and/or apartments not at full occupancy. The Student may be required to change residence assignment and move to facilitate room consolidation. Residents in rooms/apartments/suites not at full capacity may be charged additional rent as determined by UCF DHRL.
Prior Written Permission and Tripartite Agreement In respect of any nomination, the Allottee shall obtain prior permission of the Promoter and the Allottee and the nominee shall be bound to enter into a tripartite agreement with the Promoter and the Allottee.
COMPLETENESS OF AGREEMENT This Agreement constitutes the entire understanding of the parties. There are no representations or promises other than those expressly included in this Agreement. Each party hereby states under oath that the financial representations in this Agreement are accurate and complete, to the best of that party’s information, knowledge and belief.
DISCHARGE, SUSPENSION AND WARNING 21.01 When the attitude or performance of an employee calls for a warning by the Employer, such a warning shall be documented, and a copy of this warning will be forwarded immediately to the regional office of the Union.
Statement of Rights Under the Newborns’ and Mothers Health Protection Act Under federal law, group health plans and health insurance issuers offering group healthcare coverage generally may not restrict benefits for any hospital length of stay in connection with childbirth for the mother or newborn child to less than forty-eight (48) hours following a vaginal delivery, or less than ninety-six (96) hours following a delivery by cesarean section. However, the plan or issuer may pay for a shorter stay if the attending provider (e.g., your physician, nurse midwife, or physician assistant), after consultation with the mother, discharges the mother or newborn earlier. Also, under federal law, plans and issuers may not set the level of benefits or out-of- pocket costs so that any later portion of the 48-hour (or 96-hour) stay is treated in a manner less favorable to the mother or newborn than any earlier portion of the stay. In addition, a plan or issuer may not, under federal law, require that a physician or other healthcare provider obtain authorization for prescribing a length of stay of up to 48 hours (or 96 hours). In accordance with R.I. General Law §27-20-17.1, this plan covers a minimum inpatient hospital stay of forty-eight (48) hours from the time of a vaginal delivery and ninety-six
No Restriction on Existing Examination and Investigative Authority That this Agreement shall in no way preclude any State Mortgage Regulator from exercising its examination or investigative authority authorized under the laws of the corresponding Participating State in the instance a determination is made wherein Respondent is found not to be adhering to the requirements of the Agreement, other than inadvertent and isolated errors that are promptly corrected by Respondent, or involving any unrelated matter not subject to the terms of this Agreement. The Parties agree that the failure of Respondent to comply with any term or condition of this Agreement with respect to a particular State shall be treated as a violation of an Order of the State and may be enforced as such. Moreover, Respondent acknowledges and agrees that this Agreement is only binding on the State Mortgage Regulators and not any other Local, State or Federal Agency, Department or Office.
Obligation to Notify Owner of Existing Hazardous Materials The Contractor shall immediately notify the Owner and the Design Professional, both orally and in writing, of the presence and location of any physical evidence of, or information regarding the presence of Hazardous Materials at the Site of which it becomes aware. If the Contractor encounters Hazardous Materials on the Site the Contractor shall (i) immediately stop performance of Work or that portion of the Work affected by or affecting such Hazardous Materials; (ii) secure the contaminated area against intrusion; (iii) not disturb or remove the Hazardous Materials; (iv) not proceed, or allow any subcontractor or supplier to proceed, with any Work or other activities in the area affected by such Hazardous Materials until such materials have been properly remediated and until directed in writing to do so by the Owner; and, (v) take any other steps necessary to protect life and health and the surrounding environment. The Contractor shall be entitled to adjustment of the Contract Time and the Contract Sum pursuant to Section 5, Part 2 of these General Conditions in order to compensate for the impact of any required demolition, re-work, shutdown, delay, protection of work, disruption, and start-up resulting from the encountering of such Hazardous Materials on the Site for which the Contractor is not responsible.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2