Change Order (5) The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.
Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).
Owner-Requested Changes If the Owner requests changes in the Contract Documents that would materially affect the completion of the Work by lengthening the critical path of the Overall Project Schedule, the Design Professional shall determine the appropriate number of days and thereby extend the Material Completion and Occupancy Date. The Contractor expressly agrees that the Contractor’s sole monetary remedy for such extensions of Contract Time shall be calculated at the daily rate established for Time Dependent Overhead Costs in the Contract.
Bidding and Proposal Phase 1.5.1 In conjunction with the development of the Guaranteed Maximum Price and at other times as appropriate to the Project, the Architect/Engineer shall assist the Owner and Construction Manager by receiving and recording requests for Bid and Request for Proposal (“RFP”) Documents, receiving and resolving questions about Bid and RFP Documents; preparing addenda, issuing addenda, and accounting for addenda issued; attending pre-bid and pre-proposal conferences and HUB meetings; evaluating bids and proposals; and assisting in preparing and awarding multiple contracts for construction. Architect/Engineer shall answer inquiries from bidders and proposers at Owner’s request, and shall prepare and issue any necessary addenda to the bidding or proposal documents.
CLEC Requested Changes 58.9.1 CLEC may submit a request to negotiate and pay for changes in the content and format of the usage data transmitted by CenturyLink.
The Change Order The Change Order is the instrument by which adjustments in the Contract Sum and the Contract Time are effected. The Change Order shall be accompanied by a breakdown as set forth in Paragraph 3.2.7.4. The breakdown is for the purpose of enabling the Design Professional and the Owner to make a judgment on the dollar amount of the adjustment in the Contract Sum and is not a part of the Change Order. No condition, term, qualification, limitation, exception, exemption, modification, or proviso, except as set forth in this Part, shall appear in the breakdown. Only such conditions, terms, qualifications, limitations, exceptions, exemptions, modifications, and provisos as are permitted under this Part are valid. The Design Professional shall certify to the dollar amount and description of the adjustments permitted by the Change Order.
Technical Proposal The technical proposal may be presented in free format. It shall not exceed ten pages, not counting the CVs. It shall respect the following page limit and structure: • Technical methodology (max. 7 pages) • Quality management (max. 1 page) • Project management (max. 1 page) • Resource management (proposal (max. 1 page) + CVs of experts)
Cost Proposal After the Approved Working Drawings are approved by Landlord and Tenant, and the Contractor and subcontractors have been selected pursuant to Section 4.1 above, Landlord shall provide Tenant with a cost proposal in accordance with the Approved Working Drawings setting forth the reconciled bids and copies of all sub-bids, which cost proposal shall include, as nearly as possible, the cost of all Tenant Improvement Allowance Items to be incurred in connection with the construction of the Tenant Improvements (the "COST PROPOSAL"). The Cost Proposal shall reflect bids that will be priced by Contractor on an individual item-by-item or trade-by-trade basis. Landlord and Tenant shall work together in good faith in an attempt to agree upon a mutually acceptable Cost Proposal as soon as reasonably possible. Notwithstanding the foregoing, portions of the cost of the Tenant Improvements may be delivered to Tenant as such portions of the Tenant Improvements are priced by Contractor (on an individual item-by-item or trade-by-trade basis), even before the Approved Working Drawings are completed (the "PARTIAL COST PROPOSAL") for purposes of facilitating the early purchase of items and construction of the same. Tenant shall approve and deliver the Cost Proposal to Landlord within seven (7) business days of the receipt of the same, or, as to a Partial Cost Proposal within five (5) business days of receipt of the same, and upon receipt of the same by Landlord, Landlord shall be released by Tenant to purchase the items set forth in the Cost Proposal or Partial Cost Proposal, as the case may be, and to commence the construction relating to such items. If Tenant disapproves the Cost Proposal or Partial Cost Proposal, Tenant shall provide Landlord with a reasonably sufficient explanation, and in such event, Landlord and Tenant shall use good faith, diligent efforts to work with each other and Contractor to address Tenant's reasons for disapproving the Cost Proposal or Partial Cost Proposal, whichever is the case and a new Cost Proposal (or Partial Cost Proposal, as applicable) shall be prepared and the process described in this Section 4.2 shall be repeated. The date by which Tenant must approve and deliver the Cost Proposal or the last Partial Cost Proposal to Landlord, as the case may be, shall be known hereafter as the "COST PROPOSAL DELIVERY DATE". The total of all Partial Cost Proposals, if any, shall be known as the Cost Proposal.
Effect of GMP Change Order The Preconstruction Phase cannot extend beyond the execution of the GMP Change Order. By definition, all services provided after the execution of the GMP Change Order are Construction Phase Services and are included in the GMP.
For Lump Sum Change Order The payment and extension of time (if any) provided by this Change Order constitutes compensation in full to the Contractor and its Subcontractors and Suppliers for all costs and markups directly and indirectly attributable to the Change Order herein, for all delays related thereto and for performance of changes within the time stated.
