Proposed Change Order definition

Proposed Change Order. (PCO) means a document that informs Contractor of a proposed change in the Work and appropriately describes or otherwise documents such change including Contractor’s response of pricing for the proposed change.
Sample 1Sample 2Sample 3
Proposed Change Order. As defined in Section 3.08(b).
Sample 1Sample 2Sample 3
Proposed Change Order has the meaning set forth in Section 3.1 (c). ---------------------
Sample 1Sample 2

Examples of Proposed Change Order in a sentence

  • The State will prescribe a Proposed Change Order form for use by the Contractor.

  • A Proposed Change Order (PCO) is a written request submitted to the Architect by either the Contractor or the State requesting a change to the contract price and / or schedule.

  • If unit prices are stated in the Contract Documents or subsequently agreed upon, and if the quantities originally contemplated are so changed in a Proposed Change Order that application of the agreed unit prices to the quantities of work proposed will cause substantial inequity to Owner or Contractor, the applicable unit prices shall be equitably adjusted as provided in the Supplementary General Conditions or Special Conditions or as agreed to by the parties and incorporated into a Change Order.

  • Such Proposed Change Order shall contain a description of the proposed change and shall set forth the Contractor's estimate of the increase or decrease, if any, in the contract sum and the change, if any, in the schedule of values and the final completion date attributable to such change.

  • Upon receipt of such notice initiated by Fort Bend County, the Contractor shall within a reasonable period of time advise Fort Bend County of the Contractor's proposal for the adjustments, if any, in the contract sum, the schedule of values, and the final completion date attributable to such change by delivering a written notice thereof (the "Proposed Change Order") to Fort Bend County.

  • If the Contractor desires to make a change in the Project requiring the issuance of a change order, the Contractor shall deliver to Fort Bend County a Proposed Change Order.

  • Upon execution by Fort Bend County, a Proposed Change Order shall constitute (and be defined herein as) a "Change Order" for purposes of this Contract.

  • If unit prices are stated in the Contract Documents or subsequently agreed upon and if the quantities originally contemplated in setting the unit prices are so changed in a Proposed Change Order that application of the agreed unit prices to the quantities of work proposed will cause substantial inequity to Owner or Contractor, the applicable unit prices shall be equitably adjusted as provided in the Owner’s Special Conditions or as agreed to by the parties and incorporated into a Change Order.

  • The County need not consider any time extensions for Changes in the Work not included in the Proposed Change Order.

  • In the event of Changes in the Work, the Contractor must identify any additional time required in the Proposed Change Order.


More Definitions of Proposed Change Order

Proposed Change Order or “PCO” means a written request prepared by the Contractor requesting that the District and the Architect issue a Change Order based upon a proposed change to the Work.
Sample 1
Proposed Change Order means a written request for a Change Order submitted by either City or Developer for review, discussion and approval prior to its becoming agreed upon and executed by both City and Developer. At the time a Proposed Change Order is agreed upon and executed by City and Developer, it shall be deemed to be a Change Order.
Sample 1
Proposed Change Order. (PCO) means a formal request for change initiated by the District or the Contractor that has not yet been approved or denied.
Sample 1
Proposed Change Order means a document that informs Agency of a proposed change in the Work and appropriately describes or otherwise documents such change including Construction Contractor(s)’s response of pricing for the proposed change.
Sample 1

Related to Proposed Change Order

  • Proposed Change has the meaning assigned to such term in Section 9.02(c).

  • Change Order means a written order to the Contractor signed by the Contracting Officer, issued after execu- tion of the Contract, authorizing a change in the term or scope of the Contract.

  • Proposed Charter means the proposed second amended and restated certificate of incorporation of Hennessy Capital, which will become the Company’s certificate of incorporation upon the approval of the Charter Proposals and the Business Combination Proposal and the consummation of the Business Combination. A copy of the proposed charter is attached hereto as Annex C .

  • Change Orders mean changes or modifications to any Construction Contract or any other contract with labor or material suppliers.

  • Proposed decision means the presiding officer’s recommended findings of fact, conclusions of law, decision, and order in a contested case in which the administrator did not preside.

  • Project Proposal has the meaning set forth in Section 2.2(b).

  • Change Order Request means a written request or proposal for a Change Order submitted by either Company or Contractor and including:

  • approved proposal means a proposal approved or deemed to be approved under this Agreement;

  • Scope Change means any change to the scope of a contract to accommodate a need not originally provided for in the contract and which may include the acquisition of additional deliverables or the extension of the term of the contract and which may require an adjustment to the contract price;

  • Proposed Works means the sewage works described in the Owner's application, this Certificate and in the supporting documentation referred to herein, to the extent approved by this Certificate;

  • Technical Proposal means the Contractor’s Technical Proposal dated (Technical Proposal date).

  • Proposed Contract means the agreement including any other terms and conditions contained in or referred to in this RFP that may be executed between the DBSA and the successful Bidder.

  • Change of Scope Order shall have the meaning set forth in Clause 13.2 (iv); “Completion Certificate” shall have the meaning set forth in Clause 12.2; “Construction” shall have the meaning set forth in Clause 1.2 (f);

  • Proposed Project SCHEDULE: (edit schedule below as appropriate) Pre-bid Meeting Questions Due Proposals Due Begin Work Programming Phase Permitting Phase Schematic Design Phase Construction Documents Phase Bidding or Negotiation Phase Construction Administration 1-Year Warranty

  • Environmental impact statement means a detailed written statement as required by section 102(2)(C) of the Act.

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • Proposal means the Technical Proposal and the Financial Proposal of the Consultant.

  • Superior Proposal Notice has the meaning specified in Section 5.4(1)(c).

  • Proposed Amendments means any consequential or related amendments to certain terms of the Note Standard Conditions (as defined in the Note Programme Memorandum), the Series Specific Provisions (as defined in the Standard Interpretation Provision (being Clause 1 of the Standard Provisions Document)), as set out in the Note Issue Supplement in relation to the Series Portfolio Services Agreement and the Series Liquidity Facility Agreement, certain other terms of the Series Liquidity Facility Agreement, the Series Mortgage LIBOR Hedge Agreement, the Series Currency Ab Hedge Agreement, the Series Currency Ac Hedge Agreement, the Series Currency Cb Hedge Agreement, the Series Currency Db Hedge Agreement and the Series Currency Eb Hedge Agreement (each as defined in the Note Issue Supplement), to effect the transition from LIBOR to Compounded Daily SONIA as more fully described in the Amendment Deed; and 11. agree that capitalised terms in this document where not defined herein shall have the meanings given to them in the Consent Solicitation Memorandum (a copy of which is available for inspection as referred to in the Notice)." In Respect of the EUR 28,000,000 Class Db Notes due June 2039

  • Specification Schedule means the Schedule containing details of the Specification.

  • Adverse decision means any decision by a review agent not to certify an admission,

  • Approved/Approval means the approval in writing.

  • Proposed Plan As defined in Section 3.17(a)(iii).

  • Alternative Proposal has the meaning set forth in Section 6.2(b).

  • Acquisition Proposal has the meaning set forth in Section 5.03(a).

  • Proposed Transaction is defined in Section 6.2(a).