Claims for Adjustment to the Contract Sample Clauses

Claims for Adjustment to the Contract. Time -- If the Contractor is delayed in performance of any Work activity, which at the time of the delay is critical to completing the Work within the Contract Time or which during the delay becomes critical, as the sole result of any act or neglect to act by the City or someone acting in the City’s behalf, or by changes ordered in the Work, or any causes beyond the Contractor’s control, then the Contract Time shall be extended upon the written notice and claim of the Contractor to the City, for such reasonable time as the City may determine. Upon encountering such critical delay, Contractor shall provide written notice to the City of the delay no later than seven (7) days after the event or first appearance of the condition giving rise to the delay. After giving such notice, no later than seven (7) days after the completion or cessation of the event or condition that gave rise to such delay, Contractor shall submit to the City a written claim detailing Contractor’s request for adjustment to the Contract Time. Contractor’s written claim shall be in such form and include such backup and supporting documentation as the City may request. An adjustment to the Contract Time, as provided for hereunder, shall be Contractor’s sole and exclusive remedy for any delay to or impact upon the performance of the Work caused by any act or neglect to act by the City or someone acting in the City’s behalf, or by changes ordered in the Work, or any causes beyond the Contractor’s control. In no event shall Contractor be entitled to an adjustment in the Contract Price for any costs, expenses or damages incurred by Contractor arising out of or resulting from any such delay or impact to its performance of the Work. Failure by the Contractor to give the City written notice or to submit its written claim in accordance with the requirements of this provision shall result in waiver and release of any claim Contractor may have for any adjustment to the Contract Time. In the event the delay to the Contractor is a continuing one, only one notice and claim for adjustment to the Contract Time shall be necessary.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to Claims for Adjustment to the Contract

  • Claims for Additional Time § 14.1.6.1 If the Design-Builder intends to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Design-Builder’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary.

  • Claims for Additional Costs 11.3.1 If the Contractor wishes to make a claim for an increase in the Contract Sum not related to a requested change, it shall give the Owner and the A/E written notice thereof within twenty-one (21) days after the occurrence of the event giving rise to such claim, but, in any case before proceeding to execute the work considered to give rise to the additional cost or time, except in an emergency endangering life or property in which case the Contractor shall act in accordance with Article 7.2.1. No such claim shall be valid unless so made. If the Owner and the Contractor cannot agree on the amount of the adjustment in the Contract Sum, it shall be determined as set forth under Article 15. Any change in the Contract Sum resulting from such claim shall be authorized by Change Order.

  • CLAIMS FOR ADDITIONAL COST 12.3.1 If the Contractor wishes to make a claim for an increase in the Contract Sum, he shall give the Architect written notice thereof within twenty days after the occurrence of the event giving rise to such claim. This notice shall be given by the Contractor before proceeding to execute the Work, except in an emergency endangering life or property in which case the Contractor shall proceed in accordance with Paragraph 10.3 of these General Conditions. No such claim shall be valid unless so made. If the State and the Contractor cannot agree on the amount of the adjustment in the Contract Sum, it shall be determined by the Architect. Any change in the Contract Sum resulting from such claim shall be authorized by Change Order.

  • CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.

  • Disputes and Adjustments of Invoices In the event an invoice or portion thereof or any other claim or adjustments arising hereunder, is disputed, payment of the undisputed portion of the invoice shall be required to be made when due, with Notice of the objection given to the other Party. Any invoice dispute or invoice adjustment shall be in writing and shall state the basis for the dispute or adjustment. Payment of the disputed amount shall not be required until the dispute is resolved. The Parties agree to use good faith efforts to resolve the dispute or identify the adjustment as soon as possible in accordance with the provisions of Article Eighteen (Dispute Resolution). Upon resolution of the dispute or calculation of the adjustment, any required payment shall be made within fifteen (15) calendar days of such resolution along with interest accrued at the Interest Rate from and including the due date, but excluding the date on which the payment is made. Inadvertent overpayments shall be returned upon request or deducted by the Party receiving such overpayment from subsequent invoices, with interest accrued at the Interest Rate from and including the date of such overpayment to but excluding the date repaid or deducted by the Party receiving such overpayment. Any dispute with respect to an invoice is waived unless the other Party is Notified in accordance with this Section 9.4 within twelve (12) months after the invoice is rendered or any specific adjustment to the invoice is made. If an invoice is not rendered within twelve (12) months after the close of the month during which performance giving rise to the payment obligation occurred (or in the case of amounts based on CAISO invoices within twelve (12) months after the close of the month during which such invoice or revised invoice giving rise to the payment obligation was rendered), the right to payment for such performance is waived.

  • Settlement of Disputes between the Contracting Parties 1. Disputes between the Contracting Parties concerning the interpretation or application of this Agreement should, if possible, be settled through diplomatic channels.

  • Invoice Disputes If you believe any delivered software or service does not conform to the warranties in this Agreement, you will provide us with written notice within thirty (30) days of your receipt of the applicable invoice. The written notice must contain reasonable detail of the issues you contend are in dispute so that we can confirm the issue and respond to your notice with either a justification of the invoice, an adjustment to the invoice, or a proposal addressing the issues presented in your notice. We will work with you as may be necessary to develop an action plan that outlines reasonable steps to be taken by each of us to resolve any issues presented in your notice. You may withhold payment of the amount(s) actually in dispute, and only those amounts, until we complete the action items outlined in the plan. If we are unable to complete the action items outlined in the action plan because of your failure to complete the items agreed to be done by you, then you will remit full payment of the invoice. We reserve the right to suspend delivery of all SaaS Services, including maintenance and support services, if you fail to pay an invoice not disputed as described above within fifteen (15) days of notice of our intent to do so.

  • Indemnity Limitation for TIPS Sales Texas and other jurisdictions restrict the ability of governmental entities to indemnify others. Vendor agrees that if any "Indemnity" provision which requires the TIPS Member to indemnify Vendor is included in any TIPS sales agreement/contract between Vendor and a TIPS Member, that clause must either be stricken or qualified by including that such indemnity is only permitted, "to the extent permitted by the laws and constitution of [TIPS Member's State]” unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing an "Indemnity" clause that conflicts with these terms is rendered void and unenforceable.

  • TERMS OF SETTLEMENT 26. The Respondent agrees to the following terms of settlement:

  • Contract Disputes The Parties shall deal in good faith and attempt to resolve potential disputes informally. If the dispute concerning a question of fact arising under the terms of this Contract is not disposed of in a reasonable period of time by the Contractor’s Supervisor and the County‘s project manager as specified in Article 25. Notices by way of the following process, such matter shall be brought to the attention of the County DPA by way of the following process:

Time is Money Join Law Insider Premium to draft better contracts faster.