CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.
Title Defects 9.1 Purchaser shall have until April 21, 1999 in which to examine the Commitment and the Surveys. If Purchaser finds title to be defective, Purchaser shall, no later than 5:00 p.m. Eastern time on April 21, 1999, notify Seller in writing, specifying the title defect(s). If Purchaser fails to give Seller written notice of any title defect(s) before 5:00 p.m. Eastern time on April 21, 1999, the defects shown in the Commitment or the Surveys shall be deemed to be waived as title objections to closing this transaction.
9.2 If Purchaser has given Seller timely written notice of defect(s) and the defect(s) render the title other than as represented in this Agreement or if any new defects appear from the date of the Commitment through the Closing Date, Seller shall use commercially reasonable efforts to cause only those defects recorded after October 7, 1997 to be cured by the Closing Date. Seller agrees to remove, by payment, bonding or otherwise, any such lien (other than environmental liens) against the Property capable of removal by the payment of money or bonding. Seller shall not be obligated to (but may, in its sole and absolute discretion) cure any other defect or to buyout or settle any other claim or lien against the Property. At Seller's option, the Closing Date may be extended for a period not to exceed sixty (60) days for purposes of eliminating such title defects. If such additional time is reasonably required by Seller to cure such title defects, Seller's failure to extend the Closing Date shall be commercially unreasonable.
9.3 If Seller does not eliminate such defects as of the Closing Date, as the same may be extended under the preceding sentence, or if any new "title defects" appear between the date of the Commitment through the Closing Date which Seller does not eliminate as of the Closing Date, Purchaser shall have the option to:
9.3.1 Close and accept the title "as is," without reduction in the Purchase Price and without claim against Seller for such title defects (except for any lien that Seller is required to cure pursuant to Section 9.2 that can be removed by the payment of money or bonding, for which credit shall be given Purchaser at the Closing unless Seller pays the same at the Closing) (and in such event, the Closing shall take place on the Closing Date); or
9.3.2 Cancel this Agreement, whereupon Escrow Agent, subject to the provisions of Section 11.3, shall return the Deposit, together with all interest earned thereon, to Purchaser, and both parties shall be released from all further obligations under this Agreement, except for those which expressly survive such termination, unless such title defects were caused by Seller's willful act or willful omission, in which event Seller shall remain liable to Purchaser for damages caused by such title defects.
Claims for Additional Time If the Contractor wishes to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Contractor’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary.
CLAIMS FOR ADDITIONAL COST 12.3.1 If the Contractor wishes to make a claim for an increase in the Contract Sum, he shall give the Architect written notice thereof within twenty days after the occurrence of the event giving rise to such claim. This notice shall be given by the Contractor before proceeding to execute the Work, except in an emergency endangering life or property in which case the Contractor shall proceed in accordance with Paragraph 10.3 of these General Conditions. No such claim shall be valid unless so made. If the State and the Contractor cannot agree on the amount of the adjustment in the Contract Sum, it shall be determined by the Architect. Any change in the Contract Sum resulting from such claim shall be authorized by Change Order.
12.3.2 If the Contractor claims that additional cost is involved because of, but not limited to, (1) any order by the State to stop the Work pursuant to Paragraph 3.3 of these General Conditions where the Contractor was not at fault, or (2) failure of payment by the State pursuant to Paragraph 9.7(of these General Conditions), the Contractor shall make such claim as provided in Subparagraph 12.3.1 of this agreement.
12.3.3 The Architect will have authority to order minor changes in the Work not involving an adjustment in the Contract Sum or an extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes shall be effected by written order and shall be binding on the State and Contractor within 10 days unless the Contractor or the State objects to the change in writing.
Environmental Defects If Buyer determines that with respect to the Asset there exists an Environmental Condition (other than with respect to asbestos, asbestos containing materials, or NORM, and excluding any matter set forth on Schedule 6.10) (in each case, an “Environmental Defect”), then on or prior to the Defect Claim Date, Buyer may give Seller a written notice of such Environmental Defect that sets forth the information required by this Section 3.17 (an “Environmental Defect Notice”). For all purposes of this Agreement and notwithstanding anything herein to the contrary, Buyer shall be deemed to have waived any Environmental Defect that Buyer fails to timely and properly assert as an Environmental Defect by an Environmental Defect Notice received by Seller on or before the Defect Claim Date. To be effective, an Environmental Defect Notice must set forth (a) a clear description of the matter constituting the alleged Environmental Defect, (b) a description of each Asset (or portion thereof) affected by the alleged Environmental Defect, (c) the estimated proportionate share attributable to the Assets of the estimated Lowest Cost Response to eliminate the alleged Environmental Defect (the “Environmental Defect Amount”), and (d) supporting documents and reasonably necessary for Seller to verify the existence of the alleged Environmental Defect and the Environmental Defect Amount. Buyer shall furnish Seller, on or before the end of each calendar week prior to the Defect Claim Date, Environmental Defect Notices with respect to any Environmental Defects that any of Buyer’s or any of its Affiliate’s employees, representatives, attorneys, or other environmental personnel or contractors discover or become aware of during the preceding calendar week, which notice may be preliminary in nature and supplemented prior to the Defect Claim Date; provided that notwithstanding this sentence, any Environmental Defect Notice shall be deemed timely if received by Seller prior to the Defect Claim Date.
Latent Defects Notwithstanding anything to the contrary set forth herein, no acceptance, or deemed acceptance, by City pursuant to this Section shall be applicable with respect to any Latent Defects. An acceptance, or deemed acceptance, by City pursuant to this Section shall not mean that City has accepted, or the other party has been relieved of, responsibility for: (i) compliance with the Laws; (ii) the proper application of construction means or methods; or (iii) correcting any portion of the Project if it later is determined that any portion of the Project is inconsistent with the Final Documents and Drawings.
Errors, Questions, and Complaints a. In case of errors or questions about your transactions, you should as soon as possible contact us as set forth in Section 6 of the General Terms above.
b. If you think your periodic statement for your account is incorrect or you need more information about a transaction listed in the periodic statement for your account, we must hear from you no later than sixty (60) days after we send you the applicable periodic statement for your account that identifies the error. You must:
1. Tell us your name;
2. Describe the error or the transaction in question, and explain as clearly as possible why you believe it is an error or why you need more information; and,
3. Tell us the dollar amount of the suspected error.
c. If you tell us orally, we may require that you send your complaint in writing within ten (10) Business Days after your oral notification. Except as described below, we will determine whether an error occurred within ten (10) Business Days after you notify us of the error. We will tell you the results of our investigation within three (3) Business Days after we complete our investigation of the error, and will correct any error promptly. However, if we require more time to confirm the nature of your complaint or question, we reserve the right to take up to forty-five (45) days to complete our investigation. If we decide to do this, we will provisionally credit your Eligible Transaction Account within ten (10) Business Days for the amount you think is in error. If we ask you to submit your complaint or question in writing and we do not receive it within ten (10) Business Days, we may not provisionally credit your Eligible Transaction Account. If it is determined there was no error we will mail you a written explanation within three (3) Business Days after completion of our investigation. You may ask for copies of documents used in our investigation. We may revoke any provisional credit provided to you if we find an error did not occur.
Claims Process We intend to appoint the senior trustee as the authorized representative to take action on behalf of holders of each series of the notes under the guarantee. The authorized representative will agree to make a demand of the FDIC upon our failure to pay interest or principal on any series of the notes when due. As provided in the FDIC’s regulations, a holder will also have the option to elect not to be represented by the authorized representative. Upon our failure to pay interest or principal, the authorized representative and a holder that has elected not to be so represented must follow the FDIC’s required procedures for making a demand under the guarantee. In addition to the procedures described below, the authorized representative will be required when making a demand, to the extent not previously provided in the master agreement, to provide the FDIC with information regarding its authority, including: its financial and organizational capacity to act as representative, its exclusive authority to act on behalf of each noteholder and its fiduciary responsibility to the noteholders when acting as such, as established by the senior indenture, and its authority to make the assignment of each noteholder’s right, title, and interest in the notes to the FDIC. Any demand under the guarantee must be accompanied by a proof of claim, satisfactory in form and content to the FDIC, which includes evidence of the occurrence of a payment default and the claimant’s ownership of the applicable notes. The claimant must provide to the FDIC an assignment, satisfactory in form and content to the FDIC, of the noteholder’s right, title and interest in the notes to the FDIC and the transfer to the FDIC of any claim in any insolvency proceeding against us. The assignment must also grant to the FDIC the right to receive any and all distributions on the note from the proceeds of any bankruptcy. If a holder receives a payment on a note from a bankruptcy, any obligation of the FDIC under the guarantee would be reduced proportionally. Demands must be made by the authorized representative or by a holder that elects not to be represented by the authorized representative within 60 days of the occurrence of the payment default. Upon payment by the FDIC of any amount under the guarantee, the FDIC will be subrogated to the rights of the recipient noteholder against us, including in respect of any insolvency proceeding, to the extent of such payment.
Technical Objections to Grievances It is the intent of both Parties of this Agreement that no grievance shall be defeated merely because of a technical error, other than time limitations in processing the grievance through the grievance procedure. To this end, an arbitration board shall have the power to allow all necessary amendments to the grievance and the power to waive formal procedural irregularities in the processing of a grievance, in order to determine the real matter in dispute and to render a decision according to equitable principles and the justice of the case.
Correction of Defects 35.1 The Engineer shall give notice to the Contractor of any Defects before the end of the Defects Liability Period, which begins at Completion and is defined in the Contract Data. The Defects Liability Period shall be extended for as long as Defects remain to be corrected.
35.2 Every time notice of a Defect is given, the Contractor shall correct the notified Defect within the length of time specified by the Engineer’s notice.
