Time Requirements The Independent Contractor will not be required to follow or establish a regular or daily work schedule, but shall devote during the term of this Agreement the time, energy and skill as necessary to perform the services of this engagement and shall, periodically or at any time upon the request of the Company, submit information as to the amount of time worked and scope of work performed.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Schedule Requirements The Contractor shall submit an electronic and a paper copy of the initial Work Progress Schedule reflecting accurate and reliable representations of the planned progress of the Work, the Work to date if any, and of the Contractor’s actual plans for its completion. The Contractor shall organize and provide adequate detail so the Work Progress Schedule is capable of measuring and forecasting the effect of delaying events on completed and uncompleted activities.
TITLE VI REQUIREMENTS H-GAC in accordance with the provisions of Title VI of the Civil Rights Act of 1964 (78 Xxxx. 000, 00 X.X.X. §§ 0000x to 2000d-4) and the Regulations, hereby notifies all bidders that it will affirmatively ensure that any disadvantaged business enterprises will be afforded full and fair opportunity to submit in response to this Agreement and will not be discriminated against on the grounds of race, color, or national origin in consideration for an award.
SPECIAL CONTRACT REQUIREMENTS The Special Contract Requirements are provisions that relate directly to the performance of this contract.
DATA ESCROW REQUIREMENTS Registry Operator will engage an independent entity to act as data escrow agent (“Escrow Agent”) for the provision of data escrow services related to the Registry Agreement. The following Technical Specifications set forth in Part A, and Legal Requirements set forth in Part B, will be included in any data escrow agreement between Registry Operator and the Escrow Agent, under which ICANN must be named a third-‐party beneficiary. In addition to the following requirements, the data escrow agreement may contain other provisions that are not contradictory or intended to subvert the required terms provided below.
Check Requirements Any image of a check that I transmit to you must accurately and legibly provide all the information on the front and back of the check at the time presented to me by the drawer. Prior to capturing the original check, I will indorse the back of the original check. My endorsement will include "For Directions E- Deposit Only" in addition to my signature. The image of the check transmitted to you must accurately and legibly provide, among other things, the following information: (1) the information identifying the drawer and the paying bank that is preprinted on the check, including complete and accurate MICR information and the signature(s); and (2) other information placed on the check prior to the time an image of the check is captured, such as any required identification written on the front of the check and any endorsements applied to the back of the check. The image quality for the check will meet the standards for image quality established by the American National Standards Institute ("ANSI"), the Board of Governors of the Federal Reserve, and any other regulatory agency, clearing house or association. Rejection of Deposit. You are not liable for any service or late charges levied against me due to your rejection of any item. In all cases, I am responsible for any loss or overdraft plus any applicable fees to my Account due to an item being returned. Items Returned Unpaid. A written notice will be sent to me of transactions you are unable to process because of returned items. With respect to any item that I transmit to you for remote deposit that you credit to my Account, in the event such item is dishonored, I authorize you to debit the amount of such item from the Account. Email Address. I agree to notify you immediately if I change my email address, as this is the email address where you will send me notification of receipt of remote deposit items.
Invoice Requirements Contractor hereby waives the right to enforce any term which contradicts or modifies any term of the solicitation or any Contract that may result, including subsequent amendments to the Contract, or would result in an unencumbered expense if enforced against the state. Contract quote and invoice must contain, at a minimum: o Customer name o State Purchase Order number field o Item/service description o Item quantity
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Overtime requirements No contractor or subcontractor contracting for any part of the contract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek.
