Compensation for Convenience Termination If City shall terminate for its convenience as herein provided, City shall compensate Consulting Engineer/Architect for all Engineering/Architectural Services satisfactorily completed to date of its receipt of the termination notice and any additional Engineering/Architectural Services requested by City to bring the Project to reasonable termination. Compensation shall not include anticipatory profit or consequential damages, neither of which will be allowed.
Cancellation of Services (a) ARTC will request the HVCCC to inform ARTC on a weekly basis of the total number of cancelled services assigned to the Access Holder in the previous week by the Live Run Superintendent Group, as collated and reported by the HVCCC, and whether the total number of cancellations assigned to the Access Holder in that week has had, in the reasonable opinion of the HVCCC, an impact on Capacity, Coal Chain Capacity or the Capacity entitlement of another access holder in that week.
CANCELLATION OF AGREEMENT In the event that prior to the Closing Date (a) trading in securities on the New York Stock Exchange generally, or in securities of the Bank in particular, shall have been suspended, or minimum prices established by the New York Stock Exchange, or any new restrictions on transactions in securities shall have been established by the New York Stock Exchange or by the Commission or by any other United States Federal or State agency or by any action of the United States Congress or by executive order to such a degree as, in your judgment as the Representatives, to affect materially and adversely the marketing of the Securities or (b) existing financial, political or economic conditions in Europe, the United States or elsewhere shall have undergone any change which, in your judgment as the Representatives, would materially and adversely affect the market for the Securities, this Agreement and all obligations of the Underwriters hereunder may be canceled at, or at any time prior to, the Closing Date by you, as the Representatives, without liability on the part of any Underwriter to the Bank or of the Bank to any Underwriter, subject to Section 11(e). Notice of such cancellation shall be given to the Bank in writing, or by cable or telephone confirmed in writing.
Compensation for Delay The time allowed for carrying out the work, as entered in the tender form, shall be strictly observed by the contractor and shall be deemed to be the essence of the contract and shall be reckoned from the fifteenth day after the date on which the order to commence the work is issued to the contractor, for a work where completion is up to 6 months For works, for which the completion period is beyond six months: - The period will be reckoned from the thirtieth day after the date on which the order to commence the work is issued to contractor .The work shall throughout the stipulated period of contract be proceeded with all due diligence, keeping in view that time is the essence of the contract. The contractor shall be bound in all cases, in which the time allowed for any work exceeds one month, to complete 1/8th of the whole work before 1/4th of the whole time allowed under the contract has elapsed, 3/8th of the work before 1/2 of such time has elapsed and 3/4th of the work before 3/4th of such time has elapsed. In the event of the contractor failing to comply with the above conditions, the Commissionor/CMO shall levy on the contractor, as compensation an amount equal to: 0.5% (zero point five percent) of the value of work (contract sum) for each week of delay, provided that the total amount of compensation under this provision of the clause shall be limited to 6% (six percent) of the value of work. (Contract sum) Provided further that if the contractor fails to achieve 30% (thirty percent) progress in half (1/2) of original or validly extended period of time (reference clause 5 below) the contract shall stand terminated after due notice to the contractor and his contract finallised, with xxxxxxx money and or security deposit forfeited and levy of further compensation at the rate of 10% of the balance amount of contract left incomplete, either from the bill, and or from available security/performance guarantee or shall be recovered as "Arrears of land revenue". The decision of the Competent Authority in the matter of grant of extension of time only (reference clause 5 below) shall be final, binding and conclusive. But he has no right to change either the rate of compensation or reduce and or condone the period of delay- once such an order is passed by him (on each extension application of the contractor). It shall not be open for a revision. Where the Commissioner/CMO or Competent Authority or Commissioner/CMO as the case may decides that the contractor is liable to pay compensation for not giving proportionate progress under this clause and the compensation is recommended during the intermediate period, such compensation shall be kept in deposit and shall be refunded if the contractor subsequently makes up the progress for the lost time, within the period of contract including extension granted, if any. failing which the compensation amount shall be forfeited in favour of the Nagar Xxxxx/Nagar Palika Parishad/Nagar Panchayat Clause 3 -:Action when the work is left incomplete abandoned or delayed beyond the time limit permitted by the Commissioner/CMO or Competent Authority: -
Compensation for Mandatory Assistance City will compensate Contractor for fees incurred for providing Mandatory Assistance. If, however, the fees incurred for the Mandatory Assistance are determined, through resolution of the third party dispute or litigation, or both, to be attributable in whole, or in part, to the acts or omissions of Contractor, its agents, officers, and employees, Contractor shall reimburse City for all fees paid to Contractor, its agents, officers, and employees for Mandatory Assistance.
Service Cancellation You may cancel the EM Service at any time by providing us thirty (30) calendar days prior written notice. In the event you wish to cancel your EM Service, you may do so by calling 0-000-000-0000 if associated with Basic Internet Service or 0-000-000-0000 for Fios Service. If you cancel during your Term Plan, you agree to pay us: (a) all Service fees accrued as of the cancellation date and (b) a termination charge equal to thirty-five percent (35%) of the applicable monthly rate times the number of months remaining in your Term Plan. You are responsible in all cases for the full amount of telephone company circuit cancellation charges incurred by you as a result of your cancellation.
Cancellation/Termination EY may terminate this Purchase Order in whole or in part, with or without cause, at any time and without liability, upon written notice to Supplier. In the event of any termination, Supplier shall promptly refund to EY any fees paid for Services or Work Product(s) that have not been provided as at the effective date of termination, and no further fees shall be due from EY in respect of the Services or Work Product(s). Termination or expiry of this Purchase Order for any reason shall not affect the accrued rights and obligations of the parties at the date of termination or expiry (as applicable).
Cancellation of Service You have the right to cancel this Agreement with NEC Co-op Energy without penalty or fee of any kind within three (3) federal business days after you receive your Terms of Service Agreement. NEC Co-op Energy will provide you with 45 calendar days advance written notice of any material change in the Terms of Service, either in your bill or in a separate mailing. The changes will become effective on the date stated in the notice unless you cancel your Agreement. You may cancel your Agreement no later than 10 calendar days before the effective date of the material change. In the event of cancellation, if you request a specific date to switch your service other than your next meter read date, you may incur a cost for this switch. Service Protections: NEC Co-op Energy will not terminate a customer's service for (1) delinquency of payment by a previous occupant, (2) failure to pay charges not related to electric service, (3) failure to pay for a different class of electric service, (4) failure to pay an under billing, other than for theft of service, more than 6 months old, (5) failure to pay for a disputed charge until a determination as to the accuracy is made,
Termination of Agreement If this Agreement is terminated by the Representatives in accordance with the provisions of Section 5 or Section 9(a)(i) hereof, the Company shall reimburse the Underwriters for all of their out-of-pocket expenses, including the reasonable fees and disbursements of counsel for the Underwriters.
Modification of Services Credit Union reserves the right to modify the Service from time to time without making prior notice to Member, provided, however, that Credit Union will give you at least thirty (30) days notice prior to making any modifications to the Service that would materially alter their functionality.
