Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Payment of Reimbursement Amount To effect the expense reimbursement provided for in this Agreement, the Fund may offset the appropriate Reimbursement Amount against the management fees, Rule 12b-1 fees and/or shareholder servicing fees payable under the Investment Management Agreement, Rule 12b-1 Plan and/or the Shareholder Servicing Agreement. Alternatively, the Reimbursement Amount shall be paid directly by IICO, IDI and/or WISC. Such offset shall be taken, or such direct payment shall be paid, two times per year within 30 days following the date of a Fund’s applicable semi-annual or annual reporting period.
Up-Front Payment Connetics shall issue to Genentech upon the Original Closing Date (as defined in the Stock Agreement) shares of Connetics Common Stock (“Original Issuance Shares” as defined in the Stock Agreement) with a fair market value equal to two million dollars ($2,000,000), on the terms and conditions set forth in the Stock Agreement. If, on the Second Closing Date (as defined in the Stock Agreement), the aggregate market value of the Original Issuance Shares (based on the Second Issuance Price (as defined in the Stock Agreement)) is less than four million dollars ($4,000,000), Connetics shall issue to Genentech upon the Second Closing Date the number of additional shares of Connetics Common Stock (the “Second Issuance Shares,” as defined in the Stock Agreement) equal to the lesser of: (i) the number of shares necessary to increase the aggregate market value of the Original Issuance Shares (based on the Second Issuance Price) plus the Second Issuance Shares (based on the Second Issuance Price) to four million dollars ($4,000,000) or (ii) the number of shares necessary to increase the aggregate number of the Company’s shares of Common Stock held by Genentech (exclusive of any shares that Genentech has purchased from parties other than the Company) to 9.9% of the Company’s total outstanding shares of Common Stock as of the close of business on the third trading day before the Second Closing Date, on the terms and conditions set forth in the Stock Agreement. In lieu of all or any portion of the Second Issuance Shares that the Company is obligated to issue to Genentech on the Second Closing Date, the Company may elect to pay Genentech the cash value of such Second Issuance Shares (based on the Second Issuance Price). The Original Closing and the Second Closing of the stock issuances shall take place as described in the Stock Agreement. In the event that Connetics does not issue to Genentech all of the Second Issuance Shares or the cash value of the Second Issuance Shares, Genentech may, in addition to other remedies available to it by law or in equity, immediately terminate this Agreement and the licenses granted to Connetics hereunder. Such termination by Genentech of the Agreement and the licenses hereunder does not discharge Connetics’ obligation to issue all of the Second Issuance Shares or to pay to Genentech the cash value of the Second Issuance Shares. The up-front payment shall not be creditable against any royalty payments owed by Connetics under Sections 8.3 and 8.4 below.
Final Payment The Final Payment, when due hereunder, to be shared between the Lenders in accordance with their respective Pro Rata Shares;
Delivery Condition Subtenant acknowledges that it takes possession of the Subdemised Premises in its “as is” condition, and further acknowledges that Sublandlord has made no representations or warranties of any kind or nature, whether express or implied, with respect to the Subdemised Premises, the remainder of the Premises, the common areas, or the Building, nor has Sublandlord agreed to undertake or perform any modifications, alterations, or improvements to the Subdemised Premises, the remainder of the Premises, the common areas or the Building which would inure to Subtenant’s benefit.
Severability; Maximum Payment Amounts If any provision of this Agreement is prohibited by law or otherwise determined to be invalid or unenforceable by a court of competent jurisdiction, the provision that would otherwise be prohibited, invalid or unenforceable shall be deemed amended to apply to the broadest extent that it would be valid and enforceable, and the invalidity or unenforceability of such provision shall not affect the validity of the remaining provisions of this Agreement so long as this Agreement as so modified continues to express, without material change, the original intentions of the parties as to the subject matter hereof and the prohibited nature, invalidity or unenforceability of the provision(s) in question does not substantially impair the respective expectations or reciprocal obligations of the parties or the practical realization of the benefits that would otherwise be conferred upon the parties. The parties will endeavor in good faith negotiations to replace the prohibited, invalid or unenforceable provision(s) with a valid provision(s), the effect of which comes as close as possible to that of the prohibited, invalid or unenforceable provision(s). Notwithstanding anything to the contrary contained in this Agreement or any other Transaction Document (and without implication that the following is required or applicable), it is the intention of the parties that in no event shall amounts and value paid by the Company and/or any of its Subsidiaries (as the case may be), or payable to or received by any of the Buyers, under the Transaction Documents (including without limitation, any amounts that would be characterized as “interest” under applicable law) exceed amounts permitted under any applicable law. Accordingly, if any obligation to pay, payment made to any Buyer, or collection by any Buyer pursuant the Transaction Documents is finally judicially determined to be contrary to any such applicable law, such obligation to pay, payment or collection shall be deemed to have been made by mutual mistake of such Buyer, the Company and its Subsidiaries and such amount shall be deemed to have been adjusted with retroactive effect to the maximum amount or rate of interest, as the case may be, as would not be so prohibited by the applicable law. Such adjustment shall be effected, to the extent necessary, by reducing or refunding, at the option of such Buyer, the amount of interest or any other amounts which would constitute unlawful amounts required to be paid or actually paid to such Buyer under the Transaction Documents. For greater certainty, to the extent that any interest, charges, fees, expenses or other amounts required to be paid to or received by such Buyer under any of the Transaction Documents or related thereto are held to be within the meaning of “interest” or another applicable term to otherwise be violative of applicable law, such amounts shall be pro-rated over the period of time to which they relate.
Final Completion 6.5.1 Final Completion of the Work shall be achieved within ninety (90) Days after the earlier of the actual date of Substantial Completion or the Scheduled Substantial Completion Date (the “Final Completion Date”).