BILLING AND PAYMENT OF CHARGES 8.1 Unless otherwise stated, each Party will render monthly bill(s) to the other for Interconnection, Resale Services, Lawful Unbundled Network Elements, Collocation, functions, facilities, products and services provided hereunder at the rates set forth in the applicable Appendix Pricing, as set forth in applicable tariffs or other documents specifically referenced herein and, as applicable, as agreed upon by the Parties or authorized by a Party.
8.1.1 Remittance in full of all bills rendered by SBC-10STATE and SBC CALIFORNIA is due within thirty (30) calendar days of each bill date (the “Bill Due Date”). Payment must be made in accordance with the terms set forth in Section 8.3 of this Agreement.
8.1.2 Remittance in full of all bills rendered by SBC NEVADA is due in accordance with the terms set forth in the Commission C2-A Tariff, with the date on which amounts are due referred to herein as the “Bill Due Date.”
8.1.3 Remittance in full of all bills rendered by SBC CONNECTICUT is due in accordance with the terms set forth in the Connecticut Access Service Tariff approved by the DPUC, with the date on which amounts are due referred to herein as the “Bill Due Date.”
8.1.4 Remittance in full of all bills rendered by CLEC is due within thirty (30) calendar days of each bill date (the “Bill Due Date”).
8.1.5 If CLEC fails to remit payment for any charges by the Bill Due Date, or if payment for any portion of the charges is received from CLEC after the Bill Due Date, or if payment for any portion of the charges is received in funds which are not immediately available to SBC-12STATE as of the Bill Due Date (individually and collectively, “Past Due”), then a late payment charge will be assessed as provided in Sections 8.1.5.1 through 8.1.5.3, as applicable.
8.1.5.1 If any charge incurred under this Agreement that is billed out of any SBC-8STATE billing system other than the SBC SOUTHWEST REGION 5-STATE Customer Records Information System (XXXX) is Past Due, the unpaid amounts will accrue interest from the day following the Bill Due Date until paid at the lesser of (i) the rate used to compute the Late Payment Charge in the applicable SBC-8STATE intrastate access services tariff for that state and (ii) the highest rate of interest that may be charged under Applicable Law. The method and timing for application of interest to any charge incurred under this Agreement that is billed out of any SBC-8STATE billing system other than SBC SOUTHWEST REGION 5-STATE's XXXX will comply with the process set forth in the applicable SBC-8STATE intrastate access services tariff for that state.
8.1.5.2 If any charge incurred under this Agreement that is billed out of SBC SOUTHWEST REGION 5-STATE's XXXX is Past Due, the unpaid amounts will accrue interest from the day following the Bill Due Date until paid. The interest rate applied to SBC SOUTHWEST REGION 5-STATE XXXX-billed Past Due unpaid amounts will be the lesser of (i) the rate used to compute the Late Payment Charge contained in the applicable SBC SOUTHWEST REGION 5-STATE intrastate retail tariff governing Late Payment Charges to SBC SOUTHWEST REGION 5-STATE's retail End Users that are business End Users in that state and (ii) the highest rate of interest that may be charged under Applicable Law. The method and timing for application of interest to any charge incurred under this Agreement that is billed out of SBC SOUTHWEST REGION 5- STATE's XXXX will be governed by the SBC SOUTHWEST REGION 5-STATE intrastate retail tariff governing Late Payment Charges to SBC SOUTHWEST REGION 5-STATE's retail End Users that are business End Users in that state.
8.1.5.3 If any charge incurred under this Agreement that is billed out of any SBC MIDWEST REGION 5-STATE billing system is Past Due, the unpaid amounts will accrue interest from the Bill Due Date at the lesser of (i) one and one-half percent (1 ½%) per month and (ii) the highest rate of interest that may be charged under Applicable Law, compounded daily from the day following the Bill Due Date to and including the date that the payment is actually made and available.
Reimbursement of Costs City may reimburse Consultant’s out-of-pocket costs incurred by Consultant in the performance of the Required Services if negotiated in advance and included in Exhibit A. Unless specifically provided in Exhibit A, Consultant shall be responsible for any and all out-of-pocket costs incurred by Consultant in the performance of the Required Services.
Ordering and Maintenance CBB shall use Verizon’s electronic Operations Support System access platforms to submit Orders and requests for maintenance and repair of Services, and to engage in other pre-ordering, ordering, provisioning, maintenance and repair transactions. If Verizon has not yet deployed an electronic capability for CBB to perform a pre-ordering, ordering, provisioning, maintenance or repair, transaction offered by Verizon, CBB shall use such other processes as Verizon has made available for performing such transaction (including, but not limited, to submission of Orders by telephonic facsimile transmission and placing trouble reports by voice telephone transmission).
Documentation of Costs All costs shall be supported by properly executed payrolls, time records, invoices, contracts, or vouchers or other official documentation evidencing in proper detail the nature and propriety of charges. All checks, payrolls, invoices, contracts, vouchers, orders, or other accounting documents pertaining in whole or in part to this Agreement shall be clearly identified and readily accessible.
Operating and Maintenance Costs The Participating Generator shall be responsible for all its costs incurred in connection with operating and maintaining the Generating Units identified in Schedule 1 for the purpose of meeting its obligations under this Agreement.
Payment of Costs and Fees The Borrower shall pay to the Administrative Agent all reasonable costs, out-of-pocket expenses, and fees and charges of every kind in connection with the preparation, negotiation, execution and delivery of this Amendment and any documents and instruments relating hereto (which costs include, without limitation, the reasonable fees and expenses of any attorneys retained by the Administrative Agent) to the extent provided in Section 10.5 of the Credit Agreement.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Payment of Costs Each party to a hearing before an arbitrator shall bear his/her own expenses in connection therewith. All fees and expenses of the arbitrator and of a reporter shall be borne one-half by the County and one-half by the grievant.
Operating and Maintenance Expenses Subject to the provisions herein addressing the use of facilities by others, and except for operations and maintenance expenses associated with modifications made for providing interconnection or transmission service to a third party and such third party pays for such expenses, Developer shall be responsible for all reasonable expenses including overheads, associated with: (1) owning, operating, maintaining, repairing, and replacing Developer Attachment Facilities; and (2) operation, maintenance, repair and replacement of Connecting Transmission Owner’s Attachment Facilities. The Connecting Transmission Owner shall be entitled to the recovery of incremental operating and maintenance expenses that it incurs associated with System Upgrade Facilities and System Deliverability Upgrades if and to the extent provided for under Attachment S to the NYISO OATT.
Maintenance of Primary Insurance Policies; Collections Thereunder The Master Servicer shall use commercially reasonable efforts to keep, and to cause the Servicers to keep, in full force and effect each Primary Insurance Policy (except any Special Primary Insurance Policy) required with respect to a Mortgage Loan, in the manner set forth in the applicable Selling and Servicing Contract, until no longer required, and the Master Servicer shall use commercially reasonable efforts to keep in full force and effect each Special Primary Insurance Policy, if any. Notwithstanding the foregoing, the Master Servicer shall have no obligation to maintain any Primary Insurance Policy for a Mortgage Loan for which the outstanding Principal Balance thereof at any time subsequent to origination was 80% or less of the Appraised Value of the related Mortgaged Property, unless required by applicable law. Unless required by applicable law, the Master Servicer shall not cancel or refuse to renew, or allow any Servicer under its supervision to cancel or refuse to renew, any Primary Insurance Policy in effect at the date of the initial issuance of the Certificates that is required to be kept in force hereunder; provided, however, that neither the Master Servicer nor any Servicer shall advance funds for the payment of any premium due under (i) any Primary Insurance Policy (other than a Special Primary Insurance Policy) if it shall determine that such an advance would be a Nonrecoverable Advance or (ii) any Special Primary Insurance Policy.
