Compliance with Project Budget; Cost Overruns Sample Clauses

Compliance with Project Budget; Cost Overruns. All Advances made under Construction Loan #2 shall be made in accordance with the Project
Sample 1
AutoNDA by SimpleDocs
Compliance with Project Budget; Cost Overruns. All Advances made under Construction Loan #2 shall be made in accordance with the Project Budget. Any increase in the Project Budget or projected cost of construction which, when added to all previous increases, would cause the aggregate increases to exceed five (5%) of the original cost of construction shown in the Project Budget, must be approved by the Agent prior to implementation or incorporation into construction of the Distribution Facility. In the event the Agent determines at any time, in its reasonable judgment, that the total cost of completing the Distribution Facility free of liens and encumbrances, other than those in favor of the Agent contemplated hereby, will exceed the undisbursed balance of Construction Loan #2, the Agent may require further security for the payment of the Construction Notes #2 by (i) requiring the Borrower to grant the Agent additional collateral, satisfactory to the Agent, and/or (ii) requiring the Borrower to make cash deposits with the Agent sufficient in amount to cover such estimated excess cost of completing the Distribution Facility, which cash deposits will be disbursed on a first-out basis prior to further Advances by the Banks under Construction Loan #2.
Sample 1

Related to Compliance with Project Budget; Cost Overruns

  • Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2

  • Project Budget The budget approved by Member Consent for the acquisition, construction, development, marketing and financing of the Project. The initial Project Budget is attached hereto as Exhibit G.

  • Construction Budget Administrative Agent shall have received each of the Construction Budget in form and substance reasonably satisfactory to Administrative Agent (in consultation with the Independent Engineer).

  • Project Costs The Project costs are true and accurate estimates of the costs necessary to complete the Improvements in a good and workmanlike manner according to the Plans and Specifications presented by Borrower to Lender, and Borrower shall take all steps necessary to prevent the actual cost of the Improvements from exceeding the Project costs.

  • Development Budget Attached hereto as Exhibit "B" and incorporated herein by this reference is the Development Budget in an amount equal to $_____________. Owner acknowledges and represents that the attached Development Budget includes the total costs and expenses to acquire, develop, renovate and construct the Real Property and the Apartment Housing.

  • Cost Overruns In the event that the costs and expenses incurred by Borrower in completing any work which is the subject of this Agreement exceed the respective amounts allocated by Lender for such items of expense, Borrower shall be responsible for the payment (from sources other than the Property Reserves) of such excess costs and expenses.

  • Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.

  • Tenant Improvement Costs The Tenant Improvements’ cost (the “Tenant Improvement Costs”) shall mean and include any and all costs and expenses of the Work, including, without limitation, all of the following:

  • Approved Budget The Manager shall use its commercially reasonable efforts to prepare and deliver to the Company a revised budget that has been approved by the Board of Directors (the “Approved Budget”) by December 31 of the preceding Fiscal Year. However, the Company acknowledges that the Approved Budget is only an estimate of the performance of the Vessels and the Manager makes no assurance, representation or warranty that the actual performance of the Vessels in the applicable Fiscal Year will correspond to the estimates contained in the Approved Budget for such Fiscal Year. The Parties acknowledge that any projections contained in the Approved Budget are subject to and may be affected by changes in financial, economic and other conditions and circumstances beyond the control of the Parties.

  • Periodic Review of Costs of Environmental Compliance In the ordinary course of its business, the Company conducts a periodic review of the effect of Environmental Laws on the business, operations and properties of the Company and its subsidiaries, in the course of which it identifies and evaluates associated costs and liabilities (including, without limitation, any capital or operating expenditures required for clean-up, closure of properties or compliance with Environmental Laws or any permit, license or approval, any related constraints on operating activities and any potential liabilities to third parties). On the basis of such review and the amount of its established reserves, the Company has reasonably concluded that such associated costs and liabilities would not, individually or in the aggregate, result in a Material Adverse Change.

Time is Money Join Law Insider Premium to draft better contracts faster.