Construction Debt means debt incurred to fund (a) all or a portion of a Capital Improvement, (b) interest payments (including periodic net payments under related interest rate swap agreements) and related fees on other Construction Debt or (c) distributions (including incremental Incentive Distributions) on Construction Equity.
Construction Completion Certificate means the certificate issued under ARTICLE 14.
Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.
Construction Contracts means the contracts between Lessee and Contractors for the furnishing of labor, services or materials to the Leased Premises in connection with the construction of the Improvements.
Construction Completion Date means date of the completion of the Construction Period, which shall be at the expiry of a period of 24 (Twenty Four) months from the Compliance Date or such other date (with the consent of the Authority) by which the overall development of the Project is completed in accordance with the provisions of this Concession Agreement and when the Construction Completion Certificate is issued by Authority as per Article 14.1.
Construction Contract or “contract” means a written agreement between a contractor and a public agency for the construction, alteration, demolition, or repair of a facility, other than a contract having a dollar value of less than $30,000.00 or a contract that provides for 3 or fewer payments.
Construction Agreements means agreements to which Tenant is a party for Construction Work, rehabilitation, alteration, repair, replacement or demolition performed pursuant to this Lease.
construction site means a workplace where construction work is being performed;
Construction sign means a sign which identifies the architect, engineers, contractors and other individuals or firms involved with the construction of a building, or announces the character of the building or enterprise, which is erected during the building construction period.
Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;
Construction Agreement as used in this subsection means an agreement between Seller and any contractor or subcontractor to install the System;
Construction Documents means the plans, specifications, approved change orders, revisions, addenda and other information approved by the City, which set forth in detail the Work to be performed for a construction Project.
Construction project means the same as that term is defined in Section 38-1a-102.
Construction and Demolition Debris means and includes:
Construction Loan Agreement means the Loan Agreement to be entered into by and between the Construction Lender and the Partnership, as amended.
Construction Contractor means a person who undertakes to or offers to undertake to, or purports to have the capacity to undertake to, or submits a bid to, or does himself or by or through others, construct, alter, repair, add to, subtract from, improve, move, wreck, or demolish any building, highway, road, railroad, excavation, or other structure, project, development, or improvement to real property, or to do any part thereof. "Construction contractor" includes subcontractors, specialty contractors, prime contractors, and any person receiving consideration for the general supervision and/or coordination of such a construction project except for remediation contracting. This definition shall govern without regard to whether or not the construction contractor is acting in fulfillment of a contract.
Project Completion Date means the date on which the Completion Certificate is issued;
Construction Budget means the cost of acquisition, installation, testing, constructing and developing any Property as determined by the Construction Agent in its reasonable, good faith judgment.
Construction Work means any work in connection with⎯
Construction waste means solid waste which is produced or generated during construction, remodeling, or repair of pavements, houses, commercial buildings, and other structures. Construction wastes include, but are not limited to lumber, wire, sheetrock, broken brick, shingles, glass, pipes, concrete, paving materials, and metal and plastics if the metal or plastics are a part of the materials of construction or empty containers for such materials. Paints, coatings, solvents, asbestos, any liquid, compressed gases or semi-liquids and garbage are not construction wastes.
Constructional Plant means all appliances or things whatever nature required in or about the execution, completion or maintenance of the works or temporary works (as hereinafter defined) but does not include materials or other things intended to form or forming part of the permanent work or temporary housing, hutting, office, stores, etc.,
Construction Phase means that Phase of the Project which shall commence after the Authority provides the Trade Contractor with written Notice to Proceed with the Construction Phase.
Construction Plans means plans, drawings, specifications and related documents, and construction schedules for the construction of the Project, together with all supplements, amendments or corrections, submitted by the Developer and approved by the City in accordance with this Agreement.
Construction Management Agreement means the Construction Management Agreement, dated as of the date of the Common Agreement, between Construction Manager and the Project Company.
Construction Parties means all of the Parties to a Construction Service Agreement.
Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;