ENVIRONMENTAL PROTECTION STANDARDS CONTRACTOR shall be in compliance with the Clean Air Act (Title 42 USC Section 7401 et seq.), the Clean Water Act (Title 33 USC Section 1251 et seq.), Executive Order 11738 and Environmental Protection Agency, hereinafter referred to as “EPA,” regulations (Title 40 CFR), as any may now exist or be hereafter amended. Under these laws and regulations, CONTRACTOR assures that:
Environmental Protection Except as set forth in Schedule 5.13 annexed hereto:
ENVIRONMENT, SAFETY AND HEALTH PROTECTION (a) Seller shall perform this Agreement in a manner that ensures adequate protection for workers, the public, and the environment, and shall be accountable for actions of itself and its lower-tier subcontractors, agents and employees. Seller shall exercise a degree of care commensurate with the work and the associated hazards. Seller shall ensure that management of environment, safety and health (ES&H) functions and activities is an integral and visible part of Seller’s work planning and execution process. In the event that Xxxxxx fails to comply with this Agreement, Company may, without prejudice to any other legal or contractual rights, issue an order stopping all or any part of the work; thereafter a start order for resumption of work may be issued at Company’s discretion. Seller shall make no claim for an extension of time or for compensation or damages by reason of or in connection with such work stoppage. In addition, Company may require, in writing, that Seller remove from the work any employee the Company deems unsafe, incompetent, careless, or otherwise objectionable.
National Environmental Policy Act All subrecipients must comply with the requirements of the National Environmental Policy Act (NEPA) 42 U.S.C. 4321 et seq., and the Council on Environmental Quality (CEQ) Regulations (40 C.F.R. Parts 1500-1508) for Implementing the Procedural Provisions of NEPA, which requires Subrecipients to use all practicable means within their authority, and consistent with other essential considerations of national policy, to create and maintain conditions under which people and nature can exist in productive harmony and fulfill the social, economic, and other needs of present and future generations of Americans.
COMPLIANCE WITH HEALTH, SAFETY, AND ENVIRONMENTAL REGULATIONS The Contractor, it’s Subcontractors, and their respective employees, shall comply fully with all applicable federal, state, and local health, safety, and environmental laws, ordinances, rules and regulations in the performance of the services, including but not limited to those promulgated by the City and by the Occupational Safety and Health Administration (OSHA). In case of conflict, the most stringent safety requirement shall govern. The Contractor shall indemnify and hold the City harmless from and against all claims, demands, suits, actions, judgments, fines, penalties and liability of every kind arising from the breach of the Contractor’s obligations under this paragraph.
Joint Funded Project with the Ohio Department of Transportation In the event that the Recipient does not have contracting authority over project engineering, construction, or right-of- way, the Recipient and the OPWC hereby assign certain responsibilities to the Ohio Department of Transportation, an authorized representative of the State of Ohio. Notwithstanding Sections IV, VI.A., VI.B., VI.C., and VII of the Project Agreement, Recipient hereby acknowledges that upon notification by the Ohio Department of Transportation, all payments for eligible project costs will be disbursed by the Grantor directly to the Ohio Department of Transportation. A Memorandum of Funds issued by the Ohio Department of Transportation shall be used to certify the estimated project costs. Upon receipt of a Memorandum of Funds from the Ohio Department of Transportation, the OPWC shall transfer funds directly to the Ohio Department of Transportation via an Intra-State Transfer Voucher. The amount or amounts transferred shall be determined by applying the Participation Percentages defined in Appendix D to those eligible project costs within the Memorandum of Funds. In the event that the Project Scope is for right-of-way only, notwithstanding Appendix D, the OPWC shall pay for 100% of the right-of-way costs not to exceed the total financial assistance provided in Appendix C. APPENDIX D LOCAL SUBDIVISION CONTRIBUTION, PROJECT FINANCING AND EXPENSES SCHEME AND DISBURSEMENT RATIO
HEALTH, SAFETY AND ENVIRONMENT 41.1 In the performance of this Contract, Contractor and Operator shall conduct Petroleum Operations with due regard to health, safety and the protection of the environment (“HSE”) and the conservation of natural resources, and shall in particular:
Occupational Safety and Health Acts Contractor(s) who perform any work under this contract shall fully comply with the provisions of the Federal Occupational Safety and Health Act of 1970 and any amendments thereto and regulations pursuant to the act. Any Contractor who fails to do so may be terminated for cause as set forth below.
COMPLIANCE WITH OCCUPATIONAL SAFETY AND HEALTH By submission of a bid in response to this solicitation, the Bidder certifies that all material, equipment, etc., contained in their bid meets all OSHA requirements. Bidder further certifies that if they are the awarded Contractor, and the material, equipment, etc., delivered is subsequently found to be deficient in any OSHA requirements in effect on date of delivery, all costs necessary to bring the material, equipment, etc., into compliance with the aforementioned requirements shall be borne by the Contractor.
OCCUPATIONAL SAFETY AND HEALTH The parties desire to deal with safety and health complaints, and to attempt to correct any health or safety violations, internally. Accordingly, neither the Association nor an employee may file a complaint alleging a health or safety violation with the Ohio Department of Industrial Relations pursuant to R.C. §4167.10 until the following process has been completely exhausted:
