Final Completion The full and final completion of all Work in accordance with the Contract Documents.
COMMENCEMENT AND COMPLETION OF THE PROJECT Section 3.01 The Project
(a) The Company intends and expects, together with any Sponsor Affiliate, to (i) construct and acquire the Project, and (ii) meet the Contract Minimum Investment Requirement within the Investment Period. The Company anticipates that the first Phase of the Project will be placed in service during the calendar year ending December 31, 2020.
(b) Pursuant to the FILOT Act and subject to Section 4.03 hereof, the Company and the County hereby agree that the Company and any Sponsor Affiliates shall identify annually those assets which are eligible for FILOT payments under the FILOT Act and which the Company or any Sponsor Affiliate selects for such treatment by listing such assets in its annual PT-300S form (or comparable form) to be filed with the Department (as such may be amended from time to time) and that by listing such assets, such assets shall automatically become Economic Development Property and therefore be exempt from all ad valorem taxation during the Exemption Period. Anything contained in this Fee Agreement to the contrary notwithstanding, the Company and any Sponsor Affiliates shall not be obligated to complete the acquisition of the Project. However, if the Company, together with any Sponsor Affiliates, does not meet the Contract Minimum Investment Requirement within the Investment Period, the provisions of Section 4.03 hereof shall control.
(c) The Company may add to the Land such real property, located in the same taxing District in the County as the original Land, as the Company, in its discretion, deems useful or desirable. In such event, the Company, at its expense, shall deliver an appropriately revised Exhibit A to this Fee Agreement, in form reasonably acceptable to the County.
Substantial Completion Date Substantial Completion of the Work as defined in Article 6.1.2 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by July 31, 2022.
Substantial Completion 9.8.1 When the Contractor considers that the Work, or a designated portion thereof which has been accepted in writing to by the State, is substantially complete as defined in Subparagraph
Commencement and Completion of Work The professional services to be performed pursuant to this Agreement shall commence within five (5) days from the Effective Date of this Agreement. Failure to commence work in a timely manner and/or diligently pursue work to completion may be grounds for termination of this Agreement.
Final Completion Date Final Completion for the Work as defined in Article 6.1.3 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by October 31, 2024.
Upon Substantial Completion of the Work or designated portion thereof and upon application by the Contractor and certification by the Architect, the State shall make payment, reflecting adjustment in retainage, if any, for such Work or portion thereof, as provided in the Contract Documents.
Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.
Service Conditions Customer acknowledges that in the event of a service issue, Customer is responsible for on-site cooperative testing with LightEdge Technical Support to assist in the diagnosis of the trouble. Customer agrees to be bound to current terms of LightEdge Acceptable Use Policy. Terms of the Acceptable Use Policy are subject to change without notice. Current Acceptable Use Policy can be found here: xxxx://xxx.xxxxxxxxx.xxx/legal Customer agrees that any service complaints including concerns regarding level of support, products, service reliability, or any other concerns related to LightEdge or Services being provided by LIghtEdge will be communicated to LightEdge by sending an email to xx@xxxxxxxxx.xxx.
Termination Conditions Such license shall not be terminated or its exploitation enjoined, until and unless: (i) Hitachi has committed a material breach of its obligations under this IP License Agreement, Opto-Device has given written notice of such breach to Hitachi and such breach remains uncured after the Cure Period, or, in the case of a breach, which cannot be cured within such Cure Period, Hitachi has not instituted within such Cure Period steps necessary to remedy the default and/or thereafter has not diligently pursued the same to completion; or (ii) such a material breach is incurable. In the event the breach is a curable breach that cannot be cured within the Cure Period but with respect to which Hitachi has instituted steps necessary to remedy the default and is thereafter diligently pursuing such cure, both parties shall negotiate to determine whether further pursuit of such cure is reasonable. If the parties cannot agree on a resolution in such negotiations, then this issue shall be referred to arbitration pursuant to the arbitration procedures set forth in Exhibit B hereto to decide whether such breach can be cured or any other alternative remedy should be adopted. In the event the breach is an incurable breach, the parties agree that the matter shall be referred to arbitration pursuant to the arbitration procedures set forth in Exhibit B hereto to determine the appropriate remedy. In the event that either party submits the dispute to arbitration, both parties shall cooperate in such binding arbitration in accordance with Exhibit B.
