Conformance with Sample(s Submission of a sample (whether or not such sample is tested by, or for, the Commissioner) and approval thereof shall not relieve the Contractor from full compliance with all terms and conditions, performance related and otherwise, specified in the Bid Specifications. If in the judgment of the Commissioner the sample or product submitted is not in accordance with the specifications or testing requirements prescribed in the Bid Specifications, the Commissioner may reject the Bid. If an award has been made, the Commissioner may cancel the Contract at the expense of the Contractor.
CONFORMANCE WITH CONTRACT No alteration of the terms, conditions, delivery, price, quality, quantities, or specifications of the contract shall be granted without the Department’s Contracts Management Bureau’s prior written consent. Product or services provided that do not conform to the contract terms, conditions, and specifications may be rejected and returned at Contractor’s expense.
Project Implementation Manual The Recipient, through the PCU, shall: (i) take all action required to carry out Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4 (ii) of the Project in accordance with the provisions and requirements set forth or referred to in the Project Implementation Manual; (ii) submit recommendations to the Association for its consideration for changes and updates of the Project Implementation Manual as they may become necessary or advisable during Project implementation in order to achieve the objective of Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4(ii) of the Project; and (iii) not assign, amend, abrogate or waive the Project Implementation Manual or any of its provisions without the Association’s prior agreement. Notwithstanding the foregoing, if any of the provisions of the Project Implementation Manual is inconsistent with the provisions of this Agreement, the provisions of this Agreement shall prevail and govern.
CONTRACTOR’S SUBMISSION OF CONTRACT MODIFICATIONS In connection with any Contract modification, OGS reserves the right to: request additional information reject Contract modifications remove Products from Contract modification requests request additional discounts for new or existing Products
Change Orders and Contract Amendments 33.1 The Procuring Entity may at any time order the Supplier through notice in accordance GCC Clause 8, to make changes within the general scope of the Contract in any one or more of the following:
Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.
Milestone schedule Please state the status and progress of each Milestone and identify any completed Milestone(s) for the previous calendar quarter.
Project Plan Development of Project Plan Upon the Authorized User’s request, the Contractor must develop a Project Plan. This Project Plan may include Implementation personnel, installation timeframes, escalation procedures and an acceptance plan as appropriate for the Services requested. Specific requirements of the plan will be defined in the RFQ. In response to the RFQ, the Contractor must agree to furnish all labor and supervision necessary to successfully perform Services procured from this Lot. Project Plan Document The Contractor will provide to the Authorized User, a Project Plan that may contain the following items: • Name of the Project Manager, Contact Phone Numbers and E-Mail Address; • Names of the Project Team Members, Contact Phone Numbers and E-Mail Address; • A list of Implementation milestones based on the Authorized User’s desired installation date; • A list of responsibilities of the Authorized User during system Implementation; • A list of designated Contractor Authorized Personnel; • Escalation procedures including management personnel contact numbers; • Full and complete documentation of all Implementation work; • Samples of knowledge transfer documentation; and • When applicable, a list of all materials and supplies required to complete the Implementation described in the RFQ. Materials and Supplies Required to Complete Implementation In the event that there are items required to complete an Implementation, the Contractor may request the items be added to its Contract if the items meet the scope of the Contract. Negotiation of Final Project Plan If the Authorized User chooses to require a full Project Plan, the State further reserves the right for Authorized Users to negotiate the final Project Plan with the apparent RFQ awardee. Such negotiation must not substantively change the scope of the RFQ plan, but can alter timeframes or other incidental factors of the final Project Plan. The Authorized User will provide the Contractor a minimum of five (5) business days’ notice of the final negotiation date. The Authorized User reserves the right to move to the next responsible and responsive bidder if Contractor negotiations are unsuccessful.
Development Schedule The Project shall substantially comply with the specific timetables and triggers for action set forth in Article 5 of this Agreement. The parties acknowledge that, as provided in G.S. 160A-400.25(b), the failure to meet a commencement or completion date shall not, in and of itself, constitute a material breach of this Agreement pursuant to G.S. 160A-400.27 but must be judged based upon the totality of the circumstances.
Development Plan document specifying the work program, schedule, and relevant investments required for the Development and the Production of a Discovery or set of Discoveries of Oil and Gas in the Contract Area, including its abandonment.
