PROMPT PAYMENT DISCOUNTS If a Contractor offers a discount for prompt payment, the Contractor shall include the terms of the discount on all invoices, the amounts which are due if the Authorized User meets the terms, and the number of days for which the prompt payment discount offer applies.
Average Log Length and Payment Reduction If the average log length for all logs delivered under this contract is less than the average log length specified in the table in clause G-024.2, The amount of allowable payment reduction shall be calculated by multiplying the payment rate in P-028.2 by the total volume delivered, and the difference between the average length of logs delivered and the average log length specified in G-024.2, times 1% as follows: Log Length Payment Reduction = (B x V x L) x (.01) Where: B = Bid rate from P-028.2 clause V = total delivered log Volume L = Length in feet below specified average (rounded to nearest Average log length payment reductions calculated by the Purchaser must be approved by the State, prior to payment for the final billing period. Third-party scaling organization information is required to determine Xxxxxxxx mbf and Average log length for payment reduction purposes. Average log length is determined on a piece count basis. Value of log length price reduction will be derived from the applicable sort value as described in this contract. Scale information for determining Average log length for payment reduction eligibility must be obtained from roll-out scale. Truck-ramp, sample scaling, and/or bundle scaling information is not acceptable for determining eligibility. Purchaser’s exclusive remedy for below average log lengths shall be the payment reduction described in this clause, notwithstanding other provisions in the Uniform Commercial Code.
Thirty Day Payments Upon receipt of a billing statement that complies with all invoice requirements set forth in this Article, the State shall make a good faith effort to pay the amount which is due and payable within thirty
PRE-PAYMENT The Tenant shall: (check one)
Prepayment Fee The Prepayment Fee, when due hereunder, to be shared between the Lenders in accordance with their respective Pro Rata Shares; and
Annual Payment During each calendar year, an employee may choose to receive payment for up to twenty (20) hours of accrued vacation leave or compensatory time. Request for payment may be made in November or December of each year. Such payment shall be made during the month of November or December and will be granted only if the employee has taken at least forty (40) hours of vacation/compensatory time during the calendar year. Such payment shall be at the base hourly rate only, no add-ons.
Incentive Payment 11.3.1 An employer may offer and an employee may accept an early retirement incentive based on the age at retirement to be paid in the following amounts Age at Retirement % of Annual Salary at Time of Retirement 11.3.2 An employer may opt to pay the early retirement incentive in three equal annual payments over a thirty-six (36) month period. 11.3.3 Eligible bargaining unit members may opt for a partial early retirement with a pro- rated incentive.
Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
Progressive Payment For Property in which there is / are outstanding progressive payment(s) due to the Developer:- a. In the event that the Purchaser shall require a loan/financing to enable the completion of the purchase herein, the Purchaser shall notify the Assignee within thirty (30) days from the date of successful sale the details of the loan/financing and the Purchaser’s Financier by providing the Assignee a copy of the letter of offer for financing and on or before the Completion Date, the Purchaser shall cause the Purchaser’s Financier to issue a letter of undertaking to pay the balance progressive payment according to the schedule of the Sale and Purchase Agreement in favour of the Developer and to release the Assignee from its original undertaking. b. In the event that the Purchaser shall not require a loan/financing to enable the completion of the purchase herein, on or before the Completion Date, the Purchaser shall procure a letter of undertaking (acceptable to the Assignee) to pay the balance progressive payment according to the schedule of the Sale and Purchase Agreement in favour of the Developer and to release the Assignee from its original undertaking. c. Any outstanding progressive payment, charges, interests and/or penalty imposed as a result of the delay in settlement of the balance progressive payment or caused by the delay in the issuance of a letter of undertaking as stated above shall be solely borne and paid by the Purchaser.
Prepayment Fees Borrower agrees to pay to each New Term Loan Lender the following prepayment fees, if any: [ ].