Right to Subcontract The Carrier at its discretion may subcontract on any terms the whole or any part of the Carriage.
Payment to Subcontractors (If applicable) As required by Minnesota Statute § 16A.1245, the prime Contractor must pay all subContractors, less any retainage, within 10 calendar days of the prime Contractor’s receipt of payment from the State for undisputed services provided by the subContractor(s) and must pay interest at the rate of one and one-half percent per month or any part of a month to the subContractor(s) on any undisputed amount not paid on time to the subContractor(s).
Consent to Suit In the case of any dispute under or in connection with this Agreement, the Indemnitee may only bring suit against the Corporation in the Court of Chancery of the State of Delaware. The Indemnitee hereby consents to the exclusive jurisdiction and venue of the courts of the State of Delaware, and the Indemnitee hereby waives any claim the Indemnitee may have at any time as to forum non conveniens with respect to such venue. The Corporation shall have the right to institute any legal action arising out of or relating to this Agreement in any court of competent jurisdiction. Any judgment entered against either of the parties in any proceeding hereunder may be entered and enforced by any court of competent jurisdiction.
No Right to Subcontracting Subcontractor may not subcontract, either part or in whole, the Services authorized under this Agreement.
PAYMENT TO SUB-CONTRACTORS 12.1 Transnet reserves the right, in its sole discretion, to make payment directly to the sub-contractor of the Supplier/Service Provider, subject to the following conditions:
a) Receipt of an undisputed invoice from the sub-contractor; and
b) Receipt of written confirmation from the Supplier/Service Provider that the amounts claimed by the sub-contractor are correct and that the services for which the sub- contractor has requested payment were rendered to the satisfaction of the Supplier/Service Provider, against the required standards.
12.2 Nothing contained in this clause must be interpreted as bestowing on any sub-contractor a right or legitimate expectation to be paid directly by Transnet. Furthermore, this clause does not bestow any right or legitimate expectation on the Supplier/Service provider to demand that Transnet pay its sub-contractor directly. The decision to pay any sub-contractor directly, remains that of Transnet alone.
Prompt Payment to Subcontractors (a) Within 7 days of receipt by the Contractor of each payment from the City under this contract, the Contractor shall pay all Subcontractors (which term includes subconsultants and suppliers) based on work completed or service provided under the subcontract. Should any payment to the Subcontractor be delayed by more than 7 days after receipt of payment by the Contractor from the City under this contract, the Contractor shall pay the Subcontractor interest, beginning on the 8th day, at the rate of 1% per month or fraction thereof on such unpaid balance as may be due. By appropriate litigation, Subcontractors shall have the right to enforce this subsection (a) directly against the Contractor, but not against the City of Durham.
(b) If the individual assigned to administer this contract for the City (in this section, titled “Prompt Payment to Subcontractors,” he or she will be referred to as the “Project Manager”) determines that it is appropriate to enforce subsection (a) in this manner, the City may withhold from progress or final payments to the Contractor the sums estimated by the Project Manager to be
(i) the amount of interest due to the Subcontractor under subsection (a), and/or
(ii) the amounts past-due under subsection (a) to the Subcontractor but not exceeding 5% of the payment(s) due from the City to the Contractor. This subsection (b) does not limit any other rights to withhold payments that the City may have.
(c) Nothing in this section (titled “Prompt Payment to Subcontractors”) shall prevent the Contractor at the time of invoicing, application, and certification to the City from withholding invoicing, application, and certification to the City for payment to the Subcontractor for unsatisfactory job progress; defective goods, services, or construction not remedied; disputed work; third-party claims filed or reasonable evidence that such a claim will be filed; failure of the subcontractor to make timely payments for labor, equipment, and materials; damage to the Contractor or another subcontractor; reasonable evidence that the subcontract cannot be completed for the unpaid balance of the subcontract sum; or a reasonable amount for retainage not to exceed 10%.
(d) The Project Manager may require, as a prerequisite to making progress or final payments, that the Contractor provide statements from any Subcontractors designated by the Project Manager regarding the status of their accounts with the Contractor. The statements shall be in such format as the Project Manager reasonably requires, including notarization if so specified.
APPLICABILITY TO SUBCONTRACTORS Respondent agrees that all contracts it awards pursuant to the contract awarded as a result of this Agreement will be bound by the foregoing terms and conditions.
Consent to Service Each party irrevocably consents to the service of process by registered or certified mail, postage prepaid, to it at its address given pursuant to Article XVIII hereof.
Payments to Subcontractors Develop and implement a procedure for the review, processing and payment of applications by subcontractors for progress and final payments.
AUTHORIZATION TO SUPPLEMENT If any Grantor shall obtain rights to any new trademarks, the provisions of this Trademark Security Agreement shall automatically apply thereto. Grantors shall give prompt notice in writing to Agent with respect to any such new trademarks or renewal or extension of any trademark registration. Without limiting Grantors’ obligations under this Section, Grantors hereby authorize Agent unilaterally to modify this Trademark Security Agreement by amending Schedule I to include any such new trademark rights of each Grantor. Notwithstanding the foregoing, no failure to so modify this Trademark Security Agreement or amend Schedule I shall in any way affect, invalidate or detract from Agent’s continuing security interest in all Collateral, whether or not listed on Schedule I.
