Construction and Term Loans Sample Clauses

Construction and Term Loans. Prior to the Repayment Period, interest on the Construction and Term Loans shall accrue at the Variable Rate, as determined on the applicable Determination Date. During the Repayment Period, Borrower may elect (an “Interest Election”), from time to time, any one or more (as limited by Section 2.07(c)) of the variable, adjustable or fixed interest rates to be applied to amounts of not less than $1,000,000 owing on the Construction and Term Loans, as set forth in (i) and (ii) below, and interest on such amounts shall accrue at such rate selected by Borrower during the related Interest Period. Interest shall accrue at the Term Variable Rate for such portion of the Construction and Term Loans for which no Interest Election shall be in effect. (i) the per annum floating rate of interest equal to LIBOR, as determined on the applicable Determination Date, plus 400 basis points (4.00%) during the related Interest Period (the “Term Variable Rate”); or (ii) the per annum rate of interest equal to the Base Rate as determined on the applicable Determination Date plus 400 basis points (4.00%) during the period commencing on the effective date of the applicable Interest Election and continuing thereafter until the date three (3) years following such date (the “Three-Year Adjustable Rate”), and thereafter at the Term Variable Rate; (iii) the per annum rate of interest equal to the Base Rate as determined on the applicable Determination Date plus 400 basis points (4.00%) during the period commencing on the effective date of the applicable Interest Election and continuing thereafter until the date five (5) years following such date (the “Five-Year Adjustable Rate”), and thereafter at the Term Variable Rate; (iv) the per annum rate of interest equal to the Base Rate as determined on the applicable Determination Date plus 400 basis points (4.00%) during the period commencing on the effective date of the applicable Interest Election and continuing thereafter until the date ten (10) years following such date (the “Ten-Year Adjustable Rate”), and thereafter at the Term Variable Rate; (v) the per annum rate of interest equal to the Fixed Base Rate as determined on the applicable Determination Date plus 400 basis points (4.00%) during the period commencing on the Closing Date and continuing thereafter until the date ten (10) years following the Closing Date (the “Fixed Rate”), and thereafter at the Term Variable Rate. The interest rate applicable to the Construction and Term Loan...
Sample 1
AutoNDA by SimpleDocs
Construction and Term Loans. During the Construction Funding Period, Borrower shall pay in arrears, not later than the first day of each month, interest at the rate in effect from time to time pursuant to Section 2.07(a) based on the daily balance of the Construction and Term Loans outstanding during the related monthly period. During the Repayment Period, Borrower shall pay, on the first day of each calendar quarter, 40 payments of $550,000 (reduced to account for the Revolving Conversion Amount if and at such time Borrower makes a Revolving Conversion Election pursuant to Section 2.05) in reduction of the principal amount of the Construction and Term Loans, plus all accrued and unpaid interest based on the applicable interest rate in effect from time to time pursuant to Section 2.07(b). All remaining principal and accrued and unpaid interest outstanding on the Construction and Term Loans shall be due and payable on the Maturity Date.
Sample 1
Construction and Term Loans. Prior to the Construction and Term Loan Amortization Period, interest on the Construction and Term Loans shall accrue at the per annum rate of interest equal to the greater of (i) 5.50%, and (ii) the Prime Rate as determined on the applicable Determination Date plus 100 basis points (1.00%). During the Construction and Term Loan Amortization Period, interest on the Construction and Term Loans shall accrue at the per annum rate of interest equal to the greater of (i) 5.00%, and (ii) the Prime Rate as determined on the applicable Determination Date plus 100 basis points (1.00%); provided, this rate shall not exceed 8.00% during the first 36 months of the Construction and Term Loan Amortization Period or 10.0% at any time thereafter.
Sample 1
Construction and Term Loans. During the Construction Funding Period, Borrower shall pay interest at the rate in effect from time to time pursuant to Section 2.07(a) based on the daily balance of the Construction and Term Loans outstanding during the related monthly period. Borrower shall not be required to make payments of principal on the Construction and Term Loans during the Construction Funding Period. During the Construction and Term Loan Amortization Period, Borrower shall pay, 120 level amortized payments of principal and interest based on the applicable interest rate in effect pursuant to Section 2.07(b). The amount of such monthly amortized payments shall be adjusted from time to time as the interest rate is adjusted pursuant to Section 2.07(b). All amounts due and owing pursuant to this Section 2.09(a) shall be paid not later than the first day of each month. All remaining principal and accrued interest outstanding on the Construction and Term Loans shall be due and payable on the Maturity Date.
Sample 1
Construction and Term Loans 
Sample 1

Related to Construction and Term Loans

  • Amounts and Terms of the Loans 33 2.1. The Revolving Credit Loans............................................................................ 33 2.2. Making the Loans...................................................................................... 33 2.3. Fees ................................................................................................ 35 2.4. Reduction and Termination of the Commitments.......................................................... 36 2.5. Repayment............................................................................................. 36 2.6. Prepayments........................................................................................... 37 2.7. Conversion/Continuation Option........................................................................ 38 2.8. Interest.............................................................................................. 39 2.9. Interest Rate Determination and Protection............................................................ 40 2.10.

  • Amounts and Terms of the Advances and Letters of Credit SECTION 2.01. The Advances and Letters of Credit.

  • Amounts and Terms of the Advances SECTION 2.01. The A Advances. (a) Each Lender severally agrees, on the terms and conditions hereinafter set forth, to make A Advances to the Borrower from time to time on any Business Day during the period from the Closing until the Termination Date in an aggregate outstanding amount not to exceed at any time such Lender's Available Commitment, provided that the aggregate amount of the Commitments of the Lenders shall be deemed used from time to time to the extent of the aggregate amount of the B Advances then outstanding and such deemed use of the aggregate amount of the Commitments shall be applied to the Lenders ratably according to their respective Percentages (such deemed use of the aggregate amount of the Commitments being a "B Reduction"). Each A Borrowing shall be in an aggregate amount not less than $10,000,000 (or, if lower, the amount of the Available Commitments) or an integral multiple of $1,000,000 in excess thereof and shall consist of A Advances of the same Type made on the same day by the Lenders ratably according to their respective Percentages. Within the limits of each Lender's Commitment and as hereinabove and hereinafter provided, the Borrower may request Extensions of Credit hereunder, and repay or prepay Advances pursuant to Section 2.11 and utilize the resulting increase in the Available Commitments for further Extensions of Credit in accordance with the terms hereof. (b) In no event shall the Borrower be entitled to request or receive any Extensions of Credit that would cause the principal amount outstanding hereunder to exceed the Commitments.

  • Amounts and Terms of Commitments (a) The Term Credit. Each Bank severally agrees, on the terms and conditions set forth herein, to make a single loan to the Company (each such loan, a "Term Loan") on the Closing Date in a principal amount not to exceed such Bank's Pro Rata Share of the Term Commitment. Amounts borrowed as Term Loans which are repaid or prepaid by the Company may not be reborrowed. Term Loans shall be denominated in Dollars and shall not be available in, or convertible into, Offshore Currencies. (b) The Revolving Credit. Each Bank severally agrees, on the terms and conditions set forth herein, to make loans to the Borrowers (each such loan, a "Revolving Loan") from time to time on any Business Day during the period from the Closing Date to the Revolving Termination Date, in an aggregate principal Dollar Equivalent amount not to exceed at any time outstanding, together with the principal amount of Term Loans outstanding in favor of such Bank at such time, the amount set forth on Schedule 2.01 under the heading "Commitment" (such amount, together with such Bank's Pro Rata Share of the Term Commitment, as the same may be reduced under Section 2.08 or as a result of one or more assignments under Section 11.08, the Bank's "Commitment"); provided, however, that, after giving effect to any Committed Borrowing of Revolving Loans, the Effective Amount of all outstanding Revolving Loans, Term Loans, Bid Loans and L/C Obligations shall not at any time exceed the combined Commitments; and provided further that, (i) after giving effect to any Borrowing of Offshore Currency Loans, the aggregate principal Dollar Equivalent amount of all Offshore Currency Loans shall not exceed the Offshore Currency Loan Sublimit, and (ii) the Effective Amount of the Revolving Loans and Term Loans of any Bank plus the participation of such Bank in the Effective Amount of all L/C Obligations shall not exceed such Bank's Commitment. Within the limits of each Bank's Commitment, and subject to the other terms and conditions hereof, the Borrowers may borrow under this subsection 2.01(b), prepay under Section 2.09 and reborrow under this subsection 2.01(b).

  • AMOUNTS AND TERMS OF THE ADVANCES AND THE LETTERS OF CREDIT SECTION 2.01. The Advances and the Letters of Credit.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Amounts and Terms of Loans 2 1.1 Loans...........................................................................................2 1.2

  • Amounts and Terms of the Purchases SECTION 2.01.

  • CONSTRUCTION AND RENOVATION Construction and renovation projects for a state, local, territorial, or Tribal government’s principal Emergency Operations Center (EOC) as defined by the State Administrative Agency are allowable under the EMPG Program. Written approval must be provided by FEMA prior to the use of any EMPG Program funds for construction or renovation. Requests for EMPG Program funds for construction of an EOC must be accompanied by an EOC Investment Justification (located in the Related Documents tab of the EMPG xxxxxx.xxx posting) to their Regional EMPG Manager for review. Additionally, recipients are required to submit a SF-424C Form and Budget detail citing the project costs. When applying for funds to construct communication towers Sub-Recipients must submit evidence that the Federal Communication Commission’s (FCC) Section 106 review process has been completed and submit all documentation resulting from that review to Grants Program Directorate (GPD) prior to submitting materials for EHP review. Sub-Recipients are also encouraged to have completed as many steps as possible for a successful EHP review in support of their proposal for funding (e.g., coordination with their State Historic Preservation Office to identify potential historic preservation issues and to discuss the potential for project effects, compliance with all state and EHP laws and requirements). Projects for which the Sub-Recipient believes an Environmental Assessment (EA) may be needed, as defined in as defined in DHS Instruction Manual 023-01-001-01, Revision 01, FEMA Directive 108-1 and FEMA Instruction 108-1-1, must also be identified to the FEMA EMPG Regional Program Manager within six months of the award, and completed EHP review materials must be submitted no later than 12 months before the end of the period of performance. EHP review packets should be sent to xxxxxxxxxx@xxxx.xxx. EMPG Program Sub-Recipients using funds for construction projects must comply with the Xxxxx-Xxxxx Act (40 U.S.C. §§ 3141 et seq.). Grant Sub-Recipients must ensure that their contractors or subcontractors for construction projects pay workers no less than the prevailing wages for laborers and mechanics employed on projects of a character similar to the contract work in the civil subdivision of the state in which the work is to be performed. Additional information regarding compliance with the Xxxxx- Xxxxx Act, including Department of Labor (DOL) wage determinations, is available from the following website: xxxxx://xxx.xxx.xxx/whd/govcontracts/dbra.htm In general, Sub-Recipients should consult with their Grant Manager prior to making any investment that does not clearly meet the allowable expense criteria established in this Guidance.

  • Amount and Terms of the Loans 2.1 Commitments 25 2.2 Borrowings 26 2.3 Disbursements; Funding Reliance; Domicile of Loans 29 2.4 Evidence of Debt; Notes 30

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!