Construction of Ambiguities Sample Clauses

Construction of Ambiguities. This Agreement is the result of negotiations between, and has been reviewed by, each of the parties hereto and their respective counsel, if any; accordingly, this Agreement shall be deemed to be the product of all of the parties hereto, and no ambiguity shall be construed in favor of or against any one of the parties hereto.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Construction of Ambiguities. Because all Parties have participated in drafting, reviewing, and editing the language of this Agreement, no presumption for or against any Party arising out of drafting all or any part of this contract shall be applied in any action whatsoever.
Sample 1Sample 2
Construction of Ambiguities. You and the Company agree that neither party shall be considered the “drafter” of this Agreement. If any term(s) or provision(s) are ever deemed to be ambiguous, it/they shall not be construed against either party because of that party’s role in drafting this Agreement.
Sample 1Sample 2
Construction of Ambiguities. Each party hereto and its counsel have reviewed and revised (or requested revisions of) this Supplemental Agreement and have participated in the drafting hereof; accordingly, the normal rule of construction that any ambiguities are to be resolved against the drafting party shall not be applicable in the construction and interpretation of this Supplemental Agreement or any amendments hereof or exhibits hereto.
Sample 1
Construction of Ambiguities. The parties acknowledge that each of them has been represented by counsel of their choice in the negotiation of this Agreement and in connection with the negotiation of the other Transaction Documents and that the terms of this Agreement and the other Transaction Documents are the product of such negotiations. Accordingly, the parties agree that this Agreement and the other Transaction Documents shall be construed without regard to any rule or presumption requiring construction against the party causing same to be drafted.
Sample 1
Construction of Ambiguities. The parties hereto acknowledge and agree that each party has reviewed and negotiated the terms and provisions of this Agreement and has had the opportunity to contribute to its revision. Accordingly, the rule of construction to the effect that ambiguities are resolved against the drafting party shall not be employed in the interpretation of this Agreement. Rather, the terms of this Agreement shall be construed fairly as to both parties hereto and not in favor or against either party.
Sample 1
Construction of Ambiguities. The Parties to this Agreement hereby recite that each has been provided an opportunity to seek the advice of legal counsel in connection with this Agreement and, therefore, that the rule of construction that ambiguities shall be construed against the drafter shall not be applicable.
Sample 1
AutoNDA by SimpleDocs
Construction of Ambiguities. The Company has requested, on behalf --------------------------- of itself and the Designated Subsidiaries, that Agent and the other Banks complete, approve and execute this Agreement as quickly as possible and in the shortest feasible time. Agent and Banks have agreed to this request and, accordingly, have exerted every effort to close on this Agreement in the shortest possible time, foregoing the careful and extensive (and therefore time- consuming) review of the documentation that is their normal practice in order to accommodate the needs of the Company and the Designated Subsidiaries. Further, this Agreement and the related Loan Documents have been the subject of extensive negotiations and numerous revisions at the request of all parties. Accordingly, the parties agree that any ambiguity in any of the Loan Documents shall be construed in favor of the Agent and the Banks. Further, the Company agrees that the Agent, notwithstanding that such document has already been executed by all the parties, may correct any obvious error and complete any blank in any Loan Document, and the Agent shall not be liable to the Company or any Designated Subsidiary for any such action unless in taking such action the Agent acts in bad faith or gross negligence or with a wilful disregard for the interests of the Company or such Designated Subsidiary.
Sample 1

Related to Construction of Ambiguities

  • Ambiguities Each Party has had the opportunity to seek the advice of counsel or has refused to seek the advice of counsel. Each Party and its counsel, if appropriate, have participated fully in the negotiation, drafting, review, and revision of this Agreement. Any rule of construction to the effect that ambiguities are to be resolved against the drafting Party shall not apply in interpreting this Agreement. The language in this Agreement shall be interpreted as to its fair meaning and not strictly for or against any Party.

  • Resolution of Drafting Ambiguities Each Loan Party acknowledges and agrees that it was represented by counsel in connection with the execution and delivery of the Loan Documents to which it is a party, that it and its counsel reviewed and participated in the preparation and negotiation hereof and thereof and that any rule of construction to the effect that ambiguities are to be resolved against the drafting party shall not be employed in the interpretation hereof or thereof.

  • Drafting Ambiguities Each party to this Agreement and their legal counsel have reviewed and revised this Agreement. The rule of construction that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this Agreement or any amendments or exhibits to this Agreement.

  • Construction; Interpretation The headings herein are for convenience only, do not constitute a part of this Agreement and shall not be deemed to limit or affect any of the provisions hereof. The language used in this Agreement will be deemed to be the language chosen by the parties to express their mutual intent, and no rules of strict construction will be applied against any party. This Agreement shall be construed as if drafted jointly by the parties, and no presumption or burden of proof shall arise favoring or disfavoring any party by virtue of the authorship of any provisions of this Agreement. Unless otherwise indicated to the contrary herein by the context or use thereof: (i) the words, “herein,” “hereto,” “hereof” and words of similar import refer to this Agreement as a whole, including the Schedules and exhibits, and not to any particular section, subsection, paragraph, subparagraph or clause contained in this Agreement; (ii) masculine gender shall also include the feminine and neutral genders, and vice versa; (iii) words importing the singular shall also include the plural, and vice versa; (iv) the words “include,” “includes” or “including” shall be deemed to be followed by the words “without limitation”; (v) financial terms shall have the meanings given to such terms under GAAP unless otherwise specified herein; (vi) references to “$” or “dollar” or “US$” shall be references to United States dollars; (vii) where the context permits, the use of the term “or” will be non-exclusive and equivalent to the use of the term “and/or”; (viii) the word “extent” in the phrase “to the extent” shall mean the degree to which a subject or other thing extends, and such phrase shall not mean simply “if”; and (ix) if any action under this Agreement is required to be done or taken on a day that is not a Business Day or on which a government office is not open with respect to which a filing must be made, then such action shall be required to be done or taken not on such day but on the first succeeding Business Day thereafter.

  • Construction The parties agree that each of them and/or their respective counsel have reviewed and had an opportunity to revise the Transaction Documents and, therefore, the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of the Transaction Documents or any amendments thereto. In addition, each and every reference to share prices and shares of Common Stock in any Transaction Document shall be subject to adjustment for reverse and forward stock splits, stock dividends, stock combinations and other similar transactions of the Common Stock that occur after the date of this Agreement.

  • Construction of Project 11.1.1 Developer agrees to cause the Project to be developed, constructed, and installed in accordance with the terms hereof and the Construction Provisions set forth in Exhibit D, including those things reasonably inferred from the Contract Documents as being within the scope of the Project and necessary to produce the stated result even though no mention is made in the Contract Documents.

  • Construction and Interpretation Should any provision of this Agreement require judicial interpretation, the parties hereto agree that the court interpreting or construing the same shall not apply a presumption that the terms hereof shall be more strictly construed against one party by reason of the rule of construction that a document is to be more strictly construed against the party that itself, or through its agent, prepared the same, and it is expressly agreed and acknowledged that Company and Executive and each of his and its representatives, legal and otherwise, have participated in the preparation hereof.

  • Construction; Governing Law The headings used in this Agreement are for convenience only and shall not be deemed to constitute a part hereof. Whenever the context requires, words denoting singular shall be read to include the plural. This Agreement and the rights and obligations of the parties hereunder, shall be construed and interpreted in accordance with the laws of the State of Kansas, except to the extent that the laws of the State of Maryland apply with respect to share transactions.

  • Interpretation Nothing herein contained shall be deemed to require the Trust or the Fund to take any action contrary to the Trust’s Declaration of Trust or Bylaws, or any applicable statutory or regulatory requirement to which it is subject or by which it is bound, or to relieve or deprive the Trust’s Board of Trustees of its responsibility for and control of the conduct of the affairs of the Trust or the Fund.

  • Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!