Construction Liens (1) If any lien under the Construction Act, R.S.O. 1990, c. C30, or any like statute shall at any time be registered against the Demised Premises by reason of work done or materials supplied for or to the Tenant or for or to anyone holding an interest in the Demised Premises through the Tenant or if the Landlord is given notice of any such lien, the lien shall be discharged or vacated from the title to the Demised Premises by the Tenant within ninety (90) days after the lien is filed or sooner if the Demised Premises are in jeopardy of forfeiture or sale by the party performing the Work in respect of which the lien was filed even if the validity of the lien is being contested, if requested by the Landlord, or by a Leasehold Mortgagee. If the Tenant wishes to contest the amount or validity of any lien and has so notified the Landlord and if the Tenant has deposited with the Landlord or paid into court to the credit of the lien action the amount of the lien plus a reasonable amount for costs and has registered a discharge of such lien, the Tenant may defer payment of such lien for a period of time sufficient to enable the Tenant to contest the lien with due diligence, provided always that the Demised Premises shall not thereby become liable to forfeiture or sale.
(2) The Landlord may, but shall not be obligated to, discharge or vacate any construction lien if in the Landlord's judgment, exercised reasonably, the Demised Premises become liable to immediate forfeiture or sale or the Demised Premises is otherwise in jeopardy, and any amount paid by the Landlord in so doing, shall be reimbursed to the Landlord by the Tenant as Additional Rent within thirty (30) days after demand. If a construction lien is not discharged and vacated within three (3) months of registration, notwithstanding that the lien may be contested, the Landlord shall have the right, on written notice to the Tenant, to terminate the Lease.
(3) Nothing herein contained shall authorize Tenant, or imply any consent or agreement or request on the part of the Landlord to subject the Landlord's estate or interest in the Demised Premises and/or the Building to any construction lien or any other lien of any nature or kind whatsoever. Notice is hereby given to all parties that the Landlord expressly refuses and denies any consent or agreement or request to permit their estate or interest in the Demised Premises and/or the Building to be subject to any construction lien or other lien of any nature or kind whatsoever without the express written agreement of the Landlord to this effect. Tenant acknowledges that the Landlord is not, and should not be held to be, an owner as that term is defined in the Construction Act with respect to the construction of any work on the Demised Premises by, or on behalf of Tenant.
No Mechanics' Liens There are no mechanics’ or similar liens or claims which have been filed for work, labor or material (and no rights are outstanding that under the law could give rise to such liens) affecting the related Mortgaged Property which are or may be liens prior to, or equal or coordinate with, the lien of the related Mortgage;
Mechanic’s Liens Tenant shall promptly pay any contractors and materialmen who supply labor, work or materials to Tenant at the Premises or the Property so as to avoid the possibility of a lien attaching to the Premises or the Property. Tenant shall take all steps permitted by law in order to avoid the imposition of any mechanics', laborer's or materialman's lien upon the Premises, the Property or the Lot. Should any such lien or notice of lien be filed, Tenant shall discharge the same within fifteen (15) days after the lien or claim is filed or formal notice of said lien or claim has been issued, and shall also indemnify Landlord and hold it harmless from any and all claims, losses, damages, judgments, settlements, costs and expense (including attorneys' fees) resulting therefrom or by reason thereof. If Tenant has not removed such lien or claim within such fifteen (15) day period, Landlord may, but shall not be obligated to, pay the amount necessary to remove such lien, without being responsible for making any investigation as to the validity or accuracy thereof, and the amount so paid, together with all costs and expenses (including reasonable attorneys' fees) incurred by Landlord in connection therewith, shall be deemed additional rent reserved under this Lease due and payable forthwith. Nothing in this Lease is intended to authorize Tenant to do or cause any work or labor to be done or any materials to be supplied for the account of Landlord, all of the same to be solely for Tenant's account and at Tenant's risk and expense. Throughout this Lease the term "mechanics' lien" is used to include any lien, encumbrance or charge levied or imposed upon the Premises or the Property or any interest therein or income therefrom on account of any mechanics', laborer's or materialman's lien or arising out of any debt or liability to or any claim or demand of any contractor, mechanic, supplier, materialman or laborer and shall include without limitation any mechanics' notice of intention given to Landlord or Tenant, any stop order given to Landlord or Tenant, any notice or refusal to pay naming Landlord or Tenant or any injunctive or equitable action brought by any person entitled to any mechanics' lien.
Mechanics’ Lien Tenant understands and agrees that Tenant and anyone acting on Tenant’s behalf does not have the right to file for mechanic’s liens or any other kind of liens on the Premises. Tenant agrees to give actual advance notice to any contractors, subcontractors or suppliers of goods, labor or services that such liens are invalid. Tenant further agrees to take the additional steps necessary to keep the Premises free of any and all liens that may result from construction completed by or for Tenant.
Release of Encumbrances The Company shall have filed (where necessary) ----------------------- and delivered to Buyer all documents necessary to release the Assets from all Encumbrances which documents shall be in a form reasonably satisfactory to Buyer's counsel.
Construction or Rehabilitation of Mortgaged Property No Mortgage Loan was made in connection with the construction or rehabilitation of a Mortgaged Property or facilitating the trade-in or exchange of a Mortgaged Property;
TITLE TO COLLATERAL; PERMITTED LIENS Borrower is now, and will at all times in the future be, the sole owner of all the Collateral, except for items of Equipment which are leased by Borrower. The Collateral now is and will remain free and clear of any and all liens, charges, security interests, encumbrances and adverse claims, except for Permitted Liens. Silicon now has, and will continue to have, a first-priority perfected and enforceable security interest in all of the Collateral, subject only to the Permitted Liens, and Borrower will at all times defend Silicon and the Collateral against all claims of others. None of the Collateral now is or will be affixed to any real property in such a manner, or with such intent, as to become a fixture. Borrower is not and will not become a lessee under any real property lease pursuant to which the lessor may obtain any rights in any of the Collateral and no such lease now prohibits, restrains, impairs or will prohibit, restrain or impair Borrower's right to remove any Collateral from the leased premises. Whenever any Collateral is located upon premises in which any third party has an interest (whether as owner, mortgagee, beneficiary under a deed of trust, lien or otherwise), Borrower shall, whenever requested by Silicon, use its best efforts to cause such third party to execute and deliver to Silicon, in form acceptable to Silicon, such waivers and subordinations as Silicon shall specify, so as to ensure that Silicon's rights in the Collateral are, and will continue to be, superior to the rights of any such third party. Borrower will keep in full force and effect, and will comply with all the terms of, any lease of real property where any of the Collateral now or in the future may be located.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Title to Properties; Possession Under Leases (a) Each of the Borrower and the Subsidiaries has valid title in fee simple or equivalent to, or valid leasehold interests in, or easements or other limited property interests in, all its Real Properties (including all Mortgaged Properties) and has valid title to its personal property and assets, in each case, except for Permitted Liens and except for defects in title that do not materially interfere with its ability to conduct its business as currently conducted or to utilize such properties and assets for their intended purposes and except where the failure to have such title would not reasonably be expected to have, individually or in the aggregate, a Material Adverse Effect. All such properties and assets are free and clear of Liens, other than Permitted Liens or Liens arising by operation of law. The Equity Interests of the Borrower owned by Holdings (prior to a Qualified IPO) are free and clear of Liens, other than Liens permitted by Article VIA.
(b) The Borrower and each of the Subsidiaries has complied with all material obligations under all leases to which it is a party, except where the failure to comply would not reasonably be expected to have Material Adverse Effect, and all such leases are in full force and effect, except leases in respect of which the failure to be in full force and effect would not reasonably be expected to have a Material Adverse Effect.
(c) As of the Closing Date, none of the Borrower and the Subsidiaries has received any written notice of any pending or contemplated condemnation proceeding affecting any material portion of the Mortgaged Properties or any sale or disposition thereof in lieu of condemnation that remains unresolved as of the Closing Date, except as set forth on Schedule 3.07(c).
(d) As of the Closing Date, none of the Borrower and its Subsidiaries is obligated under any right of first refusal, option or other contractual right to sell, assign or otherwise Dispose of any Mortgaged Property or any interest therein, except as permitted under Section 6.02 or 6.05 or as would not reasonably be expected to have a Material Adverse Effect.
(e) Schedule 1.01(E) lists each Material Real Property owned by any Loan Party as of the Closing Date.
Construction of Improvements Lessee shall construct its planned facilities and install therein all necessary fixtures, equipment, and accessories, all of which shall be in accordance with the terms and conditions of this Lease and any applicable city code or FAA requirements. Lessee shall complete construction of the new improvements within one (1) year after the Effective Date of this Lease. Existing improvements shall be deemed to have been appropriately constructed so long as they are well-maintained and meet all applicable city code and FAA requirements. It is expressly understood that upon the expiration of the Lease, all hangar improvements shall become property of Lessor.
8.1 Lessee agrees to reimburse Lessor for the apportioned costs of roadway improvements including, but not limited to: excavation, paving, drainage, and fencing required for all extensions of the access road to the Leased Premises. Lessee shall be responsible for the cost of all extensions, as applicable, of all water, sewer, and other utilities to the Leased Premises, as well as any fees for obtaining service. Lessee shall be responsible for payment at the time improvements are completed. Lessee shall remit payment to Lessor within thirty (30) days from the date of invoice.
8.2 Lessee agrees to construct, at Lessee’s expense, aircraft access improvements, including without limitation driveways, taxi lanes, aprons, and ramps to its planned facility. Construction and location of the access improvements shall comply with specifications set forth by Lessor at the time of plan’s approval. Lessee understands that those portions of the constructed Airport access improvements situated outside the boundaries of the Leased Premises shall become, immediately upon their completion to Lessor’s satisfaction, the property of Lessor. All construction and any connections to the runway of any apron or taxi lane shall in addition be governed by any rules or regulations regarding Airport operations and must be approved of and overseen by Airport management. Constructed facilities shall not be occupied until access is completed and accepted by Lessor.
8.3 Upon completion of improvements, Lessee shall provide an 8 ½” x 11” site plan detailing a scaled drawing of the Leased Premises, hangar foot print, office area, parking, landscaping, and any other improvements.
8.4 The provisions provided above do not relieve Lessee from compliance with all applicable building code requirements and acquiring all necessary licenses and permits from any governmental authority.
8.5 If the aircraft hangar or other improvements on the Leased Premises are damaged or destroyed, Lessee shall do whatever is necessary to repair, rebuild, or restore the structure and other improvements to substantially the same condition existing prior to the damage or destruction within 180 days of the date of destruction. Upon written request from Lessee, Lessor may extend the 180-day timeline to the extent reasonably necessary due to conditions beyond the control of Lessee.
