Construction Warranty and Guarantee Sample Clauses

Construction Warranty and Guarantee. Any facilities to be dedicated to City shall have a contract warranty with a guarantee of 2 years, enforceable by City as both Owner’s assignee and as a third-party beneficiary. In addition, Owner’s contract(s) with its Contractor for the construction of any facilities to be dedicated to City (including the Offsite Facilities) shall: (i) state that the “OWNER” includes Owner and its permitted assigns, including City, and (ii) include the following provision: “Immediately before the expiration of the two-year guarantee period, the CONTRACTOR shall make an inspection of the Work in the company of the Engineer and Owner. The Engineer and Owner shall be given not less than 20 days’ notice prior to the anticipated date of Guarantee expiration and the inspection. Failure to comply with these requirements within the guarantee period shall extend the guarantee period until 20-days after the inspection is completed. During the guarantee period, where any portion of the Work is found to be defective and requires replacement, repair or adjustment (whether as a result of the foregoing inspection or otherwise), the CONTRACTOR shall immediately provide materials and labor necessary to remedy such defective work and shall prosecute such work without delay until completed to the satisfaction of the Engineer and Owner, even though the date of completion of the corrective work may extend beyond the expiration date of the guarantee period. The CONTRACTOR shall not be responsible for correction of work which has been damaged because of neglect or abuse.” Owner shall provide a copy of the contract to City upon execution, assign the contract to City and shall immediately advise City of any notice it receives under this provision, and send City a copy of the notice as provided in this Agreement.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Construction Warranty and Guarantee. Any facilities to be dedicated to the City shall have a contract warranty with a guarantee of at least 2 years, enforceable by the City as both Owner's assignee and as a third-party beneficiary. In addition, Owner's contract(s) with its Contractor for the construction of any facilities to be dedicated to the City (including the Offsite Facilities) shall:
Sample 1

Related to Construction Warranty and Guarantee

  • Warranty and Guarantee The Contractor shall warrant and guarantee the materials and work to be free of defects for a period of two (2) years after the City’s final acceptance of the entire Project. The Contractor shall be liable for any costs, losses, expenses, or damages, including consequential damages, suffered by the City resulting from defects in the Contractor’s work including, but not limited to, the cost of materials and labor expended by the City in making emergency repairs and the cost of engineering, inspection, and supervision by the City. The Contractor shall hold the City harmless from any and all claims, which may be made against the City as a result of any defective work, and the Contractor shall defend any claims at its own expense. Where materials or procedures are not specified in the Contract, the City will rely on the professional judgment of the Contractor to make the appropriate selections.

  • Warranties and Guarantees The Contractor warrants and guarantees that:

  • Contractor Warranties 14.1. The Contractor warrants, represents and undertakes that, throughout the Term:

  • Contractor Warranty The Contractor agrees to the following representation and warranty: Should any defect or deficiency in any deliverable, or the remedy of such defect or deficiency, cause incorrect data to be introduced into any Customer’s database or cause data to be lost, the Contractor shall be required to correct and reconstruct, within the timeframe established by the Customer, all production, test, acceptance, and training files or databases affected, at no additional cost to the Customer.

  • Construction Contract If federal funds are included as part of the financing of the non-OPWC portion of the Project, federal law may prevail, including, but not limited to, application of Xxxxx Xxxxx prevailing wage rates, the Xxxxxxxx “Anti-Kickback” Act, the Contract Work Hours and Safety Standards Act, and any federal environmental regulations. Recipient is solely responsible for ensuring compliance with federal requirements applicable to its Local Subdivision Contribution. Notwithstanding the above, the following provisions apply to construction contracts under this Agreement:

  • Authorization Warranty Contractor represents and warrants that the person executing this Contract on behalf of and for Contractor is an authorized agent who has actual authority to bind Contractor to each and every term, condition, and obligation of this Contract and that all requirements of Contractor have been fulfilled to provide such actual authority.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!