Substantial Completion 9.8.1 When the Contractor considers that the Work, or a designated portion thereof which has been accepted in writing to by the State, is substantially complete as defined in Subparagraph
Commencement and Completion The Work shall commence on _______________, 20__ and shall be complete in accordance with this Agreement without delay on ______________, 20__. The term “day”, used throughout this Agreement, refers to calendar days. Contractor shall not be entitled to any additional compensation for any Permitted Delays. If this Agreement is not signed and returned to the Owner before any work commences, this Agreement will be considered as accepted as presented to the Contractor.
TIME OF COMPLETION This project’s start date is scheduled for June 15, 2015 and completion date is July 31, 2015. The Contractor agrees to proceed with the work expeditiously without any delay or cessation, except such as may reasonably be beyond his control, and to employ a force of workmen sufficient so to perform the work covered by this Contract in such manner as to expedite the work of such other Contractors as may be engaged upon the work, as further provided in the Instructions to Bidders, to the end that the work to be performed by the Contractor shall be fully completed on or before the 31st day of July, 2015, subject to such adjustment of said date as may be made in accordance with this Contract. It is specifically agreed that the Contractor shall be bounden for damages, as hereinafter provided, for each and every day's delay which may be due or traceable to the Contract. In case the Contractor shall fail to perform fully the Contract within the agreed time limit, he shall pay to the City of Milwaukee, as liquidated damages for such default, the sum of $250.00 per day for each and every day's delay in completing the performance thereof after such time limit.
COMMENCEMENT AND COMPLETION OF THE PROJECT Section 3.01 The Project
(a) The Company intends and expects, together with any Sponsor Affiliate, to (i) construct and acquire the Project, and (ii) meet the Contract Minimum Investment Requirement within the Investment Period. The Company anticipates that the first Phase of the Project will be placed in service during the calendar year ending December 31, 2020.
(b) Pursuant to the FILOT Act and subject to Section 4.03 hereof, the Company and the County hereby agree that the Company and any Sponsor Affiliates shall identify annually those assets which are eligible for FILOT payments under the FILOT Act and which the Company or any Sponsor Affiliate selects for such treatment by listing such assets in its annual PT-300S form (or comparable form) to be filed with the Department (as such may be amended from time to time) and that by listing such assets, such assets shall automatically become Economic Development Property and therefore be exempt from all ad valorem taxation during the Exemption Period. Anything contained in this Fee Agreement to the contrary notwithstanding, the Company and any Sponsor Affiliates shall not be obligated to complete the acquisition of the Project. However, if the Company, together with any Sponsor Affiliates, does not meet the Contract Minimum Investment Requirement within the Investment Period, the provisions of Section 4.03 hereof shall control.
(c) The Company may add to the Land such real property, located in the same taxing District in the County as the original Land, as the Company, in its discretion, deems useful or desirable. In such event, the Company, at its expense, shall deliver an appropriately revised Exhibit A to this Fee Agreement, in form reasonably acceptable to the County.
Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:
At Completion all (but not some only, unless the Subscriber so agrees) of the following business shall be transacted:
(a) the Issuer shall issue the Subscription Shares to the Subscriber (or its nominee) free and clear of all Encumbrances and credited as fully paid on terms that they rank pari passu in all respects with the existing issued Shares (including the right to rank in full for all distributions declared, paid or made by the Issuer after the Completion Date) and shall promptly thereafter register (or procure the share registrar to register) the Subscriber as a registered shareholder of the Issuer in respect of the Subscription Shares in the branch register of members of the Issuer maintained by Computershare;
(b) the Issuer shall deliver to the Subscriber, each in form and substance to the reasonable satisfaction of the Subscriber:
(i) a certified true copy of the Board resolutions approving and/or ratifying the matters below:
(A) approving the terms of, and the transactions contemplated by, this Agreement and resolving that the Issuer executes this Agreement;
(B) authorising a specified person or persons to execute this Agreement on the Issuer’s behalf;
(C) authorising a specified person or persons, on behalf of the Issuer, to sign, execute and/or despatch all documents and notices to be signed, executed and/or despatched by it under or in connection with this Agreement; and
(D) a specimen of the signature of each person authorised by the resolution referred to in Clause 4.3(b)(i)(B) above;
(ii) the original definitive share certificates in respect of the Subscription Shares in the name of the Subscriber (or its nominee);
(iii) a certified true copy of the confirmation letter issued by Computershare confirming that the Subscriber (or its nominee) is the registered holder of the Subscription Shares;
(iv) a copy of the approval from the HKSE for the listing of, and permission to deal in, all the Subscription Shares; and
(v) a closing certificate, dated as at the Completion Date and addressed to the Subscriber from the Issuer, executed by a Director (or another duly authorised signatory) and substantially in the form set out in Schedule 2, and attaching thereto as exhibits all supporting documents, showing such fulfilment.
Effectiveness and Events Requiring Notice to the Representatives The Company will use its best efforts to cause the Registration Statement to remain effective and will notify the Representatives immediately and confirm the notice in writing: (i) of the effectiveness of the Registration Statement and any amendment thereto; (ii) of the issuance by the Commission of any stop order suspending the effectiveness of the Registration Statement or any post-effective amendment thereto or preventing or suspending the use of any Preliminary Prospectus or the Prospectus or of the initiation, or the threatening, of any proceeding for that purpose; (iii) of the issuance by any foreign or state securities commission of any proceedings for the suspension of the qualification of the Public Securities for offering or sale in any jurisdiction or of the initiation, or the threatening, of any proceeding for that purpose; (iv) of the mailing and delivery to the Commission for filing of any amendment or supplement to the Registration Statement or Prospectus; (v) of the receipt of any comments or request for any additional information from the Commission; and (vi) of the happening of any event that, in the reasonable judgment of the Company, makes any statement of a material fact made in the Registration Statement or the Prospectus untrue or that requires the making of any changes in the Registration Statement or the Prospectus in order to make the statements therein, and in light of the circumstances under which they were made, not misleading. If the Commission or any foreign or state securities commission shall enter a stop order or suspend such qualification at any time, the Company will make every reasonable effort to obtain promptly the lifting of such order.
Conditions Precedent/Effectiveness Conditions This Amendment shall be effective upon the date of satisfaction of all of the following conditions precedent (the “Effective Date”):
(a) Agent shall have received this Amendment fully executed by the Borrowers;
(b) Agent shall have received updated schedule to the Loan Agreement, if any;
(c) Agent shall have received a Guaranty, fully executed by the New Guarantor;
(d) Agent shall have received a Pledge Agreement, fully executed by the New Guarantor;
(e) Agent shall have received a copy of the Asset Transfer Agreement;
(f) Agent shall have received a copy of the resolutions in form and substance reasonably satisfactory to Agent, of the board of directors or managers of New Guarantor, authorizing the execution, delivery and performance of this Amendment, the Guaranty, and any related agreements, instruments, or documents to which New Guarantor is a party, certified by the Secretary or an Assistant Secretary of New Guarantor;
(g) Agent shall have received a certificate of the Secretary or an Assistant Secretary of New Guarantor as to the incumbency and signature of the officers of New Guarantor executing this Amendment the Guaranty, and any related agreements, instruments, or documents to which New Guarantor is a party, together with evidence of the incumbency of such Secretary or Assistant Secretary;
(h) Agent shall have received an incumbency certificate for each Borrower identifying all authorized officers with specimen signatures, certified by the Secretary of such Borrower;
(i) Agent shall have received copies of the bylaws and memorandum of association of New Guarantor, together with a certificate of good standing or equivalent certification in the jurisdiction of formation of New Guarantor;
(j) Agent shall have received the results of UCC, tax lien, and judgment searches against New Guarantor;
(k) Agent shall have received an opinion of counsel of New Guarantor;
(l) Agent shall have received updated certificates of insurance naming New Guarantor as an additional insured with respect to liability insurance and lender loss payee with respect to property insurance;
(m) Agent shall have received reasonably satisfactory evidence that the Guarantor Restructuring shall be consummated; and
(n) No Default or Event of Default shall have occurred and be continuing under the Loan Agreement.
Construction Completion The related Construction shall have been completed substantially in accordance with the related Plans and Specifications, the related Deed and all Applicable Laws, and such Leased Property shall be ready for occupancy and operation. All fixtures, equipment and other property contemplated under the Plans and Specifications to be incorporated into or installed in such Leased Property shall have been substantially incorporated or installed, free and clear of all Liens except for Permitted Liens.
Upon Substantial Completion of the Work or designated portion thereof and upon application by the Contractor and certification by the Architect, the State shall make payment, reflecting adjustment in retainage, if any, for such Work or portion thereof, as provided in the Contract Documents.
