CONTRACTING OFFICER’S REPRESENTATIVE AND TECHNICAL Sample Clauses

CONTRACTING OFFICER’S REPRESENTATIVE AND TECHNICAL. LEAD (a) The Contracting Officer may designate other Government personnel (known as the Contracting Officer’s Representative) to act as his or her authorized representative for agreement administration functions, which do not involve changes to the scope, price, schedule, or terms and conditions of the agreement. The designation will be in writing, signed by the Contracting Officer, and will set forth the authorities and limitations of the representative(s) under the agreement. Such designation will not contain authority to sign Contractual documents, order agreement changes, modify agreement terms, or create any commitment or liability on the part of the Government different from that set forth in the agreement. The Technical Lead will serve as the chief daily point of contact with the Contractor, will receive deliverables and recommend approval or disapproval of deliverables to the Contracting Officer’s Representative. (b) The Contractor shall immediately contact the Contracting Officer if there is any question regarding the authority of an individual to act on behalf of the Contracting Officer under this agreement.
Sample 1
AutoNDA by SimpleDocs

Related to CONTRACTING OFFICER’S REPRESENTATIVE AND TECHNICAL

  • Contractor’s Representative Contractor hereby designates [***INSERT NAME OR TITLE***], or his or her designee, to act as its representative for the performance of this Agreement (“Contractor’s Representative”). Contractor’s Representative shall have full authority to represent and act on behalf of the Contractor for all purposes under this Agreement. The Contractor’s Representative shall supervise and direct the Services, using his best skill and attention, and shall be responsible for all means, methods, techniques, sequences and procedures and for the satisfactory coordination of all portions of the Services under this Agreement.

  • Contracting Officer The person authorized to administer and make written determinations for the Commonwealth with respect to the Prime Contract. Department – The Department of General Services of the Commonwealth of Pennsylvania. Issuing Office – The department, board, commission or other agency of the Commonwealth of Pennsylvania that issued the Procurement. Procurement – The Invitation for Bids, Request for Quotes, Request for Proposals or other solicitation and all associated final procurement documentation issued by the Commonwealth to obtain proposals from firms for award of the Prime Contract.

  • Project Representatives The Contractor designates the following individual as project representative for all matters concerning this Agreement: Xxx Xxxxxxxxx, Principal 00000 Xxxxxx Xxxxxxxx Xxxxxxx, Xxxxx 000, Xxxxxxxx, Xxxxxxxx 00000 Phone: 000.000.0000 Email: Xxx@XXXX.xxx The Authority designates the following individual as Contract Administrator/project representative to be the initial point of contact for all matters concerning this Agreement: Xxxx Xxxxxxxxxxxxx, Authority Buyer 000 Xxxx Xxxxxxxx Xxxxxx, Xxxxxxx, Xxxxxxxx 00000 Phone: 000.000.0000 Email: XxxxxxxxxxxxxX0@xxxxxxxx.xxx Except for changes to the performance schedule (not including the project’s completion date), the designated project representatives shall have no authority to make promises or binding obligations on behalf of the Authority, as such authority rests with the duly authorized persons executing this Agreement.

  • Project Representative City shall designate a Project Manager to represent City in coordinating this Project with Consulting Engineer/Architect, with authority to transmit instructions and define policies and decisions of City.

  • CONTRACTOR CUSTOMER SERVICE REPRESENTATIVE Contractor shall designate a customer service representative (and inform Enterprise Services of the same) who shall be responsible for addressing Purchaser issues pertaining to this Master Contract.

  • Nurse Representatives The Employer agrees to recognize two (2) Nurse Representatives for the purpose of dealing with grievances and conducting Union interviews.

  • Contractor Project Manager The Contractor Project Manager shall serve, from the Effective Date, as the Contractor project manager and primary Contractor representative under this Agreement. The Contractor Project Manager shall (i) have overall responsibility for managing and coordinating the performance of Contractor’s obligations under this Agreement, including the performance of all Subcontractors; and (ii) be authorized to act for and bind Contractor and Subcontractors in connection with all aspects of this Agreement. The Contractor Project Manager shall respond promptly and fully to all inquiries from the JBE Project Manager.

  • Owner’s Representatives 9.1.1 Owner designates the individual listed below as its Senior Representative (“Owner Senior Representative”), which individual has the authority and responsibility for avoiding and resolving disputes under Section 10.2 of the General Conditions: 9.1.2 Owner designates the individual listed below as its Owner’s Representative, which individual has the authority and responsibility set forth in Section 3.3 of the General Conditions:

  • Contractor Representative The Contractor shall appoint a Contractor Representative fluent in English, who shall:

  • Contractor Personnel Contractor's staff is expected to present a professional appearance. All personnel of the Contractor will be neat, well groomed, properly uniformed in industry standard uniforms and are expected to conduct themselves at all times in a responsible and courteous manner while performing any work under this Agreement and/or whenever they are on District property. The following code of conduct will be adhered to by the Contractor, his agent(s) and/or his employees. If Contractor fails to ensure that its employees or other agents comply with these requirements, then Contractor may be terminated for cause under this Agreement: A. All employees of the Contractor shall wear a recognizable uniform. No hats will be worn inside the building. All of Contractor’s employees and agents performing work must carry a government-issued photo ID. Contractor’s employees and agents will present ID to District Staff upon request. This provision will be strictly enforced. B. The use of tobacco or tobacco products on Board property is prohibited by State law. C. The Contractor will not be permitted to utilize Day Labor or Temporary Workers to provide any services at any District facility. This includes any employees or agents that are hired prior to contract award. Failure to comply with this requirement could result in immediate termination of contract with the Contractor liable for any breach, including liquidated damages for delay damages and/or forfeiture of Performance Bond. D. The Contractor or employees or agents of the Contractor are not permitted to play loud music, to make unnecessary noises, or to use vulgar or inappropriate language that causes offense to others. E. The employment of unauthorized or illegal aliens by the Contractor is considered a violation of Section 247A (e) of the Immigration and Naturalization Act. If the Contractor knowingly employs unauthorized aliens, such a violation shall also be cause for termination of this Agreement. F. Possession of firearms will not be tolerated on Board property. No person who has a firearm in their vehicle will be permitted to park on District property. Any employee of the Contractor found in violation of this policy will be immediately asked to leave, and will not be allowed to return to perform further work without the consent of the District. G. The Contractor certifies that he/she will not engage in the unlawful manufacture, sale distribution, dispensation, possession, or use of a controlled substance or drug during the performance of the contract and that a drug-free workplace will be provided for the Contractor’s employees or agents during the performance of the contract. The Contractor also certifies that he will secure from any subcontractor who works on the contract, written certification of the same drug free workplace requirements. False certification or violation by failing to carry out requirements of O.C.G.A. § 50-24-3 may cause suspension, termination of contract, or debarment of such bidder Please Note: If any employee or agent of the Contractor or Sub-contractor is found to have brought a firearm on District property, the Contractor or Sub-contractor shall prohibit them from continuing to perform any work on District property. If the Contractor or Sub-contractor fails to do so, then the District may terminate this Agreement for cause as set forth below.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!