STATEWIDE CONTRACT MANAGEMENT SYSTEM If the maximum amount payable to Contractor under this Contract is $100,000 or greater, either on the Effective Date or at any time thereafter, this section shall apply. Contractor agrees to be governed by and comply with the provisions of §§00-000-000, 00-000-000, 00-000-000, and 00- 000-000, C.R.S. regarding the monitoring of vendor performance and the reporting of contract information in the State’s contract management system (“Contract Management System” or “CMS”). Contractor’s performance shall be subject to evaluation and review in accordance with the terms and conditions of this Contract, Colorado statutes governing CMS, and State Fiscal Rules and State Controller policies.
FRAMEWORK AGREEMENT MANAGEMENT The Parties shall manage this Framework Agreement in accordance with Schedule 14 (Framework Management).
Quality Management System Supplier hereby undertakes, warrants and confirms, and will ensue same for its subcontractors, to remain certified in accordance with ISO 9001 standard or equivalent. At any time during the term of this Agreement, the Supplier shall, if so instructed by ISR, provide evidence of such certifications. In any event, Supplier must notify ISR, in writing, in the event said certification is suspended and/or canceled and/or not continued.
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Document Management The Contractor must retain sufficient documentation to substantiate claims for payment under the Contract and all other records, electronic files, papers, and documents that were made in relation to this Contract. The Contractor must retain all documents related to the Contract for five (5) years after expiration of the Contract or, if longer, the period required by the General Records Schedules maintained by the Florida Department of State available at the Department of State’s Records Management website.
PERFORMANCE MANAGEMENT SYSTEM 6.1 The Performance Plan (Annexure A) to this Agreement sets out –
6.1.1 The standards and procedures for evaluating the Employee’s performance; and
6.1.2 The intervals for the evaluation of the Employee’s performance.
6.2 Despite the establishment of agreed intervals for evaluation, the Employer may in addition review the Employee’s performance at any stage while the contract of employment remains in force;
6.3 Personal growth and development needs identified during any performance review discussion must be documented in a Personal Development Plan as well as the actions agreed to and implementation must take place within set time frames;
6.4 The Employee’s performance will be measured in terms of contributions to the goals and strategies set out in the Employer’s Integrated Development Plan (IDP) as described in 6.6 – 6.12 below;
6.5 The Employee will submit quarterly performance reports (SDBIP) and a comprehensive annual performance report at least one week prior to the performance assessment meetings to the Evaluation Panel Chairperson for distribution to the panel members for preparation purposes;
6.6 Assessment of the achievement of results as outlined in the performance plan:
6.6.1 Each KPI or group of KPIs shall be assessed according to the extent to which the specified standards or performance targets have been met and with due regard to ad-hoc tasks that had to be performed under the KPI, and the score of the employer will be given to and explained to the Employee during the assessment interview.
6.6.2 A rating on the five-point scale shall be provided for each KPI or group of KPIs which will then be multiplied by the weighting to calculate the final score;
6.6.3 The Employee will submit his self-evaluation to the Employer prior to the formal assessment;
6.6.4 In the instance where the employee could not perform due to reasons outside the control of the employer and employee, the KPI will not be considered during the evaluation. The employee should provide sufficient evidence in such instances; and
6.6.5 An overall score will be calculated based on the total of the individual scores calculated above.
HHSC and Contractor Agreements HHSC and Contractor hereby agree:
A. That in the event any provision of this Contract becomes unenforceable or void all other provisions of this Contract will remain ineffect.
B. That the Contractor may not transfer or assign this Contract without the express prior written approval of HHSC.
C. That this Contract may be assigned to a state agency or agencies.
D. That HHSC may amend this Contract by written notice to the Contractor. HHSC reserves the right to amend this Contract through execution of a unilateral amendment signed by an HHSC person with delegated signature authority and provided to the Contractor under the following circumstances:
1. to correct an obvious clerical error in the Contract;
2. to incorporate new or revised federal or state statutes, rules or policies;
3. to comply with a court order or judgment; and
4. to change the name of the Contractor to reflect the Contractor's name as recorded by the Texas Secretary of State.
E. That nothing in this Contract or any conduct by a representative of HHSC relating to this Contract shall be construed as a waiver of the state's sovereign immunity to suit.
F. That neither party to this Contract waives its right to enforce a right under this Contract by failing to enforce or delaying the enforcement of any other right under this Contract.
G. That the Contractor is an independent contractor and not an employee of HHSC for any purpose. The Contractor and HHSC agreethat:
1. HHSC will not withhold or pay on behalf of the Contractor any sums for income tax, unemployment insurance, Social Security or any other withholding, or make available to the Contractor any of the benefits, including workers' compensation insurance coverage and health and retirement benefits, afforded to HHSC employees; and
2. the Contractor must indemnify HHSC from any liability, including attorneys' fees and legal expenses, incurred by HHSC with respect to claims that HHSC should have been withholding or making payments on behalf of the Contractor or providing benefits to the Contractor's employees.
H. That nothing in this Contract is intended to create a joint venture, a partnership or a principal-agent relationship.
I. That the Contractor assigns to HHSC all claims for overcharges associated with this Contract arising under the anti-trust laws of the United States, 15 U.S.C. §§ 1-38, or the anti-trust laws of the state of Texas, Tex. Bus. & Com. Code, §§ 15.01-.40.
J. That HHSC has authority to monitor and conduct fiscal and program compliance reviews of the Contractor and its subcontractor(s) to the extent of services provided under the terms of this Contract. The Contractor will grant on-site access at reasonable times to all records relating to services provided and payments received under the terms of this Contract to state and federal auditing agencies and personnel and representatives of HHSC and HHS when it is deemed necessary by such agencies for purposes of inspection, monitoring, auditing or evaluating Contractor's performance under this Contract and compliance with applicable state and federal laws, rules and regulations; the applicable HHSC provider handbook or manual; and this Contract. That for Title XX programs, HHSC shall, by Form 2029, Information Worksheet – POS Contract, set the rate or maximum amount of funds or both available to be paid to Contractor by HHSC. Form 2029 is incorporated into and made a part of this Contract and is effective for the time stated on the form. Form 2029 may be amended by HHSC as necessary to comply with state and federal laws and regulations or renewed by HHSC by a new Form 2029 and incorporated into and made part of this Contract.
K. That in compliance with §2262.003, Texas Government Code:
1. the state auditor may conduct an audit or investigation of any entity receiving funds from the state directly under the Contract or indirectly through a subcontract under the Contract;
2. acceptance of funds directly under the Contract or indirectly through a subcontract under the Contract acts as acceptance of the authority of the state auditor, under the direction of the legislative audit committee, to conduct an audit or investigation in connection with those funds; and
3. under the direction of the legislative audit committee, an entity that is the subject of an audit or investigation by the state auditor must provide the state auditor with access to any information the state auditor considers relevant to the investigation or audit.
L. That this Contract shall continue subject to the availability of appropriated funds or until the federal or state governments or both cease to participate in the program.
M. That any breach or violation of any of the provisions of this Contract or state or federal regulations shall make this entire Contract, at HHSC's option, subject to termination.
N. That if HHSC does not renew the Contractor's contract due to the Contractor's noncompliance with applicable federal or Texas statutes or rules, the Contractor cannot enter into another contract for a Community Services program until the application denial period established by HHSC expires.
O. That the venue for any lawsuit between HHSC and the Contractor shall be Travis County, Texas.
P. That this Contract may be terminated by:
AGREEMENT MANAGEMENT Pinellas Community Foundation designates the following person(s) as the liaison for the Xxxxxx Xxxxxx, CEO Pinellas Community Foundation
Project Management Plan 3.2.1 Developer is responsible for all quality assurance and quality control activities necessary to manage the Work, including the Utility Adjustment Work. Developer shall undertake all aspects of quality assurance and quality control for the Project and Work in accordance with the approved Project Management Plan, Good Industry Practice and applicable Law.
3.2.2 Developer shall develop the Project Management Plan and its component parts, plans and other documentation in accordance with the requirements set forth in Section 1.5.2.5
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms.
b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage.
c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications.
d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders.
e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims.
f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc.
g. Assist in community outreach meetings and media relations
h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
