Contractor’s Representative 14 Sample Clauses

Contractor’s Representative 14. The Contractor shall appoint the Contractor‟s Representative and shall give him all authority necessary to act on the Contractor‟s behalf under the Contract. Unless the Contractor‟s Representative is named in the Contract, the Contractor shall, prior to the Commencement Date, submit to the Project Manager for consent the name and particulars of the person the Contractor proposes to appoint as Contractor‟s Representative. If consent is withheld or subsequently revoked or if the appointed person fails to act as Contractor‟s Representative, the Contractor shall similarly submit the name and particulars of another suitable person for such appointment. The Contractor shall not, without the prior consent of the Project Manager, revoke the appointment of the Contractor‟s Representative or appoint a replacement. The whole time of the Contractor‟s Representative shall be given to directing the Contractor‟s performance of the Contract. If the Contractor‟s Representative is to be temporarily absent from the Site during the execution of the Works, a suitable replacement person shall be appointed, subject to the Project Manager‟s prior consent, and the Project Manager shall be notified accordingly. The Contractor‟s Representative shall, on behalf of the Contractor, receive instructions under GCC 3.3 [Instructions of the Project Manager]. The Contractor‟s Representative may delegate any powers, functions and authority to any competent person, and may at any time revoke the delegation. Any delegation or revocation shall not take effect until the Project Manager has received prior notice signed by the Contractor‟s Representative, naming the person and specifying the powers, functions and authority being delegated or revoked. The Contractor‟s Representative shall be fluent in the language for communications defined in GCC 1.4 [Law and Language].
Sample 1
AutoNDA by SimpleDocs

Related to Contractor’s Representative 14

  • Contractor’s Representative Contractor hereby designates [***INSERT NAME OR TITLE***], or his or her designee, to act as its representative for the performance of this Agreement (“Contractor’s Representative”). Contractor’s Representative shall have full authority to represent and act on behalf of the Contractor for all purposes under this Agreement. The Contractor’s Representative shall supervise and direct the Services, using his best skill and attention, and shall be responsible for all means, methods, techniques, sequences and procedures and for the satisfactory coordination of all portions of the Services under this Agreement.

  • Owner’s Representatives 9.1.1 Owner designates the individual listed below as its Senior Representative (“Owner Senior Representative”), which individual has the authority and responsibility for avoiding and resolving disputes under Section 10.2 of the General Conditions: 9.1.2 Owner designates the individual listed below as its Owner’s Representative, which individual has the authority and responsibility set forth in Section 3.3 of the General Conditions:

  • Owner’s Representative Owner designates the individual listed below as its Owner’s Representative to provide direct interface with Construction Manager with respect to Owner’s responsibilities: Xxxxx Xxxxxx, Owner’s Project Manager.

  • Buyers’ representatives After this Agreement has been signed by the Parties and the Deposit has been lodged, the Buyers have the right to place two (2) representatives on board the Vessel at their sole risk and expense. These representatives are on board for the purpose of familiarisation and in the capacity of observers only, and they shall not interfere in any respect with the operation of the Vessel. The Buyers and the Buyers’ representatives shall sign the Sellers’ P&I Club’s standard letter of indemnity prior to their embarkation.

  • CONTRACTOR’S REPRESENTATIONS In order to induce the City to enter into this Work Order, the Contractor makes the following representations: 7.1 Contractor has familiarized itself with the nature and extent of the Contract Documents including this Work Order, work, site, locality, and all local conditions and laws and regulations that in any manner may affect cost, progress, performance or furnishing of the work. 7.2 Contractor has obtained at his/her own expense and carefully studied, or assumes responsibility for obtaining and carefully studying, soil investigations, explorations, and test reports which pertain to the subsurface conditions at or contiguous to the site or otherwise may affect the cost, progress, performance or furnishing of the work as Contractor considers necessary for the performance or furnishing of the work at the stated work order price within the Work Order stated time and in accordance with the other terms and conditions of the Contract Documents, including specifically the provisions of the IFB; and no additional examinations, investigations, explorations, tests, reports, studies or similar information or data are or is deemed necessary by Contractor for such purposes. 7.3 Contractor has reviewed and checked all information and data shown or indicated on the Contract Documents with respect to existing Underground Facilities at or contiguous to the site and assumes responsibility for the accurate location of said Underground Facilities. No additional examinations, investigations, explorations, tests, reports, studies or similar information or data in respect of said Underground Facilities are or is deemed necessary by the Contractor in order to perform and furnish the work under this Work Order price, within the Work Order time and in accordance with the other terms and conditions of the Contract Documents. 7.4 Contractor has correlated the results of all such observations, examinations, investigations, explorations, tests, reports and studies with the terms and conditions of the Contract Documents. 7.5 Contractor has given the City’s Contract Administrator written notice of all conflicts, errors or discrepancies that he or she has discovered in the Contract Documents and the written resolution thereof by City or its designee is acceptable to the Contractor.

  • Sellers’ Representative (a) Each of the Sellers hereby appoints Xxxx Xxxxx as Seller’s Representative hereunder for the purposes of representing his or its individual interests. Each of the Sellers hereby authorizes the Sellers’ Representative to act on his or its behalf with respect to all matters arising under this Agreement requiring or contemplating the possibility of some notice to be sent to or from, or some action to be taken by, the Sellers, including acting as the Sellers’ representative for the purpose of settling on behalf of the Sellers any claims made by Buyer under Section 12.1(a)(i), representing the Sellers in any indemnification proceedings under Section 12.3, approving any waivers or amendments in accordance with Section 13.6, but excluding the settling of any claims made by Buyer under Section 12.1(a)(ii) against a Seller. Except as aforesaid, each Seller hereby agrees to be bound by any and all notices sent and actions taken (and notices not sent and actions not taken) by the Sellers’ Representative on his or its behalf pursuant to this Agreement. If for any reason the Sellers’ Representative shall be unable to perform its duties hereunder as Sellers’ Representative, the holders of a majority in interest of the Interests owned immediately prior to the Initial Closing shall appoint a replacement Sellers’ Representative. Buyer shall be entitled to rely exclusively upon any communications or writings given or executed by the Sellers’ Representative and shall not be liable in any manner whatsoever for any action taken or not taken in reliance upon the actions taken or not taken or communications or writings given or executed by the Sellers’ Representative. Buyer shall be entitled to disregard any notices or communications given or made by any Seller, in his or its individual capacity, which is contrary to a notice or communication given or made by the Sellers’ Representative. (b) In performing his duties under this Agreement, and in exercising or failing to exercise all or any of the powers conferred upon the Sellers’ Representative hereunder or thereunder, (i) the Sellers’ Representative shall not assume any, and shall incur no, responsibility whatsoever to any Seller by reason of any error in judgment or other act or omission performed or omitted hereunder or in connection with this Agreement, unless by the Sellers’ Representative’s gross negligence or willful misconduct, and (ii) the Sellers’ Representative shall be entitled to rely on the advice of counsel, public accountants or other independent experts experienced in the matter at issue, and any error in judgment or other act or omission of the Sellers’ Representative pursuant to such advice shall in no event subject the Sellers’ Representative to liability to any Seller unless by the Sellers’ Representative’s gross negligence or willful misconduct. All of the immunities and powers granted to the Sellers’ Representative under this Agreement shall survive the Initial Closing, any Subsequent Closing and/or any termination of this Agreement.

  • Contractor Representative The Contractor shall appoint a Contractor Representative fluent in English, who shall:

  • City’s Representative The City hereby designates Xxx Xxxxx, or his or her designee, to act as its representative for the performance of this Agreement (“City’s Representative”). City’s Representative shall have the power to act on behalf of the City for all purposes under this Contract. Consultant shall not accept direction or orders from any person other than the City’s Representative or his or her designee.

  • CONTRACTOR CUSTOMER SERVICE REPRESENTATIVE Contractor shall designate a customer service representative (and inform Enterprise Services of the same) who shall be responsible for addressing Purchaser issues pertaining to this Master Contract.

  • Project Representatives The Contractor designates the following individual as project representative for all matters concerning this Agreement: Xxx Xxxxxxxxx, Principal 00000 Xxxxxx Xxxxxxxx Xxxxxxx, Xxxxx 000, Xxxxxxxx, Xxxxxxxx 00000 Phone: 000.000.0000 Email: Xxx@XXXX.xxx The Authority designates the following individual as Contract Administrator/project representative to be the initial point of contact for all matters concerning this Agreement: Xxxx Xxxxxxxxxxxxx, Authority Buyer 000 Xxxx Xxxxxxxx Xxxxxx, Xxxxxxx, Xxxxxxxx 00000 Phone: 000.000.0000 Email: XxxxxxxxxxxxxX0@xxxxxxxx.xxx Except for changes to the performance schedule (not including the project’s completion date), the designated project representatives shall have no authority to make promises or binding obligations on behalf of the Authority, as such authority rests with the duly authorized persons executing this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!