CONVEYANCE AND POSSESSION OF SAID VILLA Sample Clauses

CONVEYANCE AND POSSESSION OF SAID VILLA. 6.1 Schedule for possession of the said Villa– The Promoter agrees and understands that timely delivery of possession of the Villa to the Allottee(s) is the essence of the Agreement. The Promoter assures to handover possession of the said Villa on or before 07/03/2025 unless there is delay or failure due to war, flood, drought, fire, pandemic, cyclone, earthquake or any other calamity caused by nature effecting the regular development of the Phase IV of the Project (“Force Majeure”). If, however, the completion of Villa is delayed due to the Force Majeure conditions then the Allottee(s) agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the said Villa and the Promoter shall not be liable to pay any penalty/interest/compensation during such Force Majeure condition, provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee(s) agrees and confirms that, in the event it becomes impossible for the Promoter to implement the contract due to Force Majeure conditions, which shall be assessed by the Promoter, the Promoter shall inform the Allottee(s) about such impossibility along with notice of termination of one month and upon termination of this allotment, the Promoter shall refund to the Allottee(s) the entire amount received by the Promoter from the Allottee(s) with Interest (computed at the Interest Rate)within forty-five (45) days from the date on which termination became effective. After refund of the money paid by the Allottee(s), the Allottee(s) agrees that he/ she shall not have any rights, claims etc. against the Sellers and the Sellers shall be released and discharged from all its obligations and liabilities under this Agreement.
Sample 1
AutoNDA by SimpleDocs

Related to CONVEYANCE AND POSSESSION OF SAID VILLA

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2

  • REMOVAL OF RECORDS FROM PREMISES Where performance of the Contract involves use by the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) of Authorized User owned or licensed papers, files, computer disks or other electronic storage devices, data or records at Authorized User facilities or offices, or via remote access, the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) shall not remotely access, modify, delete, copy or remove such Records without the prior written approval of the Authorized User. In no case, with or without the written approval of the Authorized User, can the Authorized User data be accessed, moved or sent outside the continental United States.

  • Assumption of Tariff Obligations Interconnection Customer agrees to abide by all rules and procedures pertaining to generation and transmission in the PJM Region, including but not limited to the rules and procedures concerning the dispatch of generation or scheduling transmission set forth in the Tariff, the Operating Agreement and the PJM Manuals.

  • RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES The Allottee hereby agrees to purchase the [Apartment/Plot] on the specific understanding that is/her right to the use of Common Areas shall be subject to timely payment of total maintenance charges, as determined and thereafter billed by the maintenance agency appointed or the association of allottees (or the maintenance agency appointed by it) and performance by the Allottee of all his/her obligations in respect of the terms and conditions specified by the maintenance agency or the association of allottees from time to time.

  • General Conditions Applicable to Option to Build If the Interconnection Customer assumes responsibility for the design, procurement and construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades,

  • Insurance and Fingerprint Requirements Information Insurance If applicable and your staff will be on TIPS member premises for delivery, training or installation etc. and/or with an automobile, you must carry automobile insurance as required by law. You may be asked to provide proof of insurance. Fingerprint It is possible that a vendor may be subject to Chapter 22 of the Texas Education Code. The Texas Education Code, Chapter 22, Section 22.0834. Statutory language may be found at: xxxx://xxx.xxxxxxxx.xxxxx.xxxxx.xx.xx/ If the vendor has staff that meet both of these criterion: (1) will have continuing duties related to the contracted services; and (2) has or will have direct contact with students Then you have ”covered” employees for purposes of completing the attached form. TIPS recommends all vendors consult their legal counsel for guidance in compliance with this law. If you have questions on how to comply, see below. If you have questions on compliance with this code section, contact the Texas Department of Public Safety Non-Criminal Justice Unit, Access and Dissemination Bureau, FAST-FACT at XXXX@xxxxx.xxxxx.xx.xx and you should send an email identifying you as a contractor to a Texas Independent School District or ESC Region 8 and TIPS. Texas DPS phone number is (000) 000-0000. See form in the next attribute to complete entitled: Texas Education Code Chapter 22 Contractor Certification for Contractor Employees

  • Specific Provisions for Access Rights to Software For the avoidance of doubt, the general provisions for Access Rights provided for in this Section 9 are applicable also to Software. Parties’ Access Rights to Software do not include any right to receive source code or object code ported to a certain hardware platform or any right to receive respective Software documentation in any particular form or detail, but only as available from the Party granting the Access Rights.

  • Certain Requirements as to Furniture, Equipment and Fixtures If the Assuming Institution purchases owned Bank Premises or accepts an assignment of the lease (or enters into a sublease or a new lease in lieu thereof) for leased Bank Premises as provided in Section 4.6(a) or 4.6(b), or if the Assuming Institution does not exercise such option but within twelve (12) months following Bank Closing obtains the right to occupy such premises (whether by assignment, lease, sublease, purchase or otherwise), other than in accordance with Section 4.6(a) or (b), the Assuming Institution shall (i) effective as of the date of Bank Closing, purchase from the Receiver all Furniture and Equipment and Fixtures owned by the Failed Bank at Fair Market Value and located thereon as of Bank Closing, (ii) accept an assignment or a sublease of the leases or negotiate new leases for all Furniture and Equipment and Fixtures leased by the Failed Bank and located thereon, and (iii) if applicable, accept an assignment or a sublease of any ground lease or negotiate a new ground lease with respect to any land on which such Bank Premises are located; provided, that the Receiver shall not have disposed of such Furniture and Equipment and Fixtures or repudiated the leases specified in clause (ii) or (iii).

  • CONDITION OF PREMISES The Premises are demised to Tenant and Tenant accepts the same “as-is”, except that (a) if, not later than sixty (60) days following the date of this Lease, Tenant notifies Landlord that the Initial Premises or a portion thereof (clearly designated in such notice to Landlord) are to be delivered in shell condition (but absent such notice Landlord will not otherwise be obligated to perform the Shell Work, time being of the essence of such notice), the Landlord shall, with respect to such designated portion(s) of the Premises, perform the Shell Work described in Exhibit B-1 at Landlord’s sole cost and expense prior to September 1, 2013, and all other work necessary to prepare the Initial Premises for Tenant’s occupancy shall be performed at Tenant’s sole cost and expense, in accordance with the applicable provisions of this Lease and (b) as to space added to the Premises pursuant to Section 42.01, if Tenant elects as provided therein, that some or all of the space so added shall be delivered in shell condition (but absent such notice Landlord will not otherwise be obligated to perform the Shell Work, time being of the essence of such notice), the Landlord shall, with respect to such designated portion(s) of the Premises, perform the Shell Work described in Exhibit B-1 at Landlord’s sole cost and expense prior to the date which is ninety (90) days following the date on which the additional space would be delivered under Section 42.01 but for the Tenant election that the same be delivered in shell condition, and all other work necessary to prepare the space so added under Section 42.01 for Tenant’s occupancy shall be performed at Tenant’s sole cost and expense, in accordance with the applicable provisions of this Lease. Tenant’s taking possession of any portion of the Premises shall be conclusive evidence that such portion of the Premises was in good order and satisfactory condition when Tenant took possession, and except for latent defects not readily apparent from a careful inspection of the Premises without cutting into or otherwise disturbing walls, floors or ceilings and punchlist items of which Tenant has delivered notice to Landlord, excluding items of damage caused by Tenant or its agents, independent contractors or suppliers (subject to the provisions of Section 3.01 of this Lease). No promise of Landlord to alter, remodel or improve the Property and no representation by Landlord or its agents respecting the condition of the Property has been made to Tenant or relied upon by Tenant other than as may be contained in this Lease or in any written amendment hereto signed by Landlord and Tenant.

  • State Specific Provisions N/A. ATTACHED EXHIBIT. The Exhibit noted below, if marked with an "X" in the space provided, is attached to this Note: X Exhibit A Modifications to Multifamily Note

Time is Money Join Law Insider Premium to draft better contracts faster.