Separate Contractor Any person or entity other than Contractor that enters into an agreement with Owner to perform the construction of all or any portion of the construction on a Project.
Data shared with Subcontractors If DSHS Data provided under this Contract is to be shared with a subcontractor, the Contract with the subcontractor must include all of the data security provisions within this Contract and within any amendments, attachments, or exhibits within this Contract. If the Contractor cannot protect the Data as articulated within this Contract, then the contract with the sub- Contractor must be submitted to the DSHS Contact specified for this contract for review and approval.
Engineer's Coordination with Owner Engineer shall be available for conferences with City so that Project can be designed with the full benefit of City's experience and knowledge of existing needs and facilities and be consistent with current policies and construction standards. City shall make available to Engineer all existing plans, maps, field notes, and other data in its possession relative to the Project. Engineer may show justification to City for changes in design from City standards due to the judgment of said Engineer of a cost savings to City and/or due to the surrounding topographic conditions. City shall make the final decision as to any changes after appropriate request by Engineer.
COORDINATION WITH OTHER CONTRACTORS Contractor expressly acknowledges and agrees that other contractors may be performing work on other projects at the Site, while the Work is taking place, in which event Contractor shall fully cooperate with District and other contractors while performing the Work, at no additional cost to District.
Agreements with Subcontractors Business Associate shall enter into a Business Associate Agreement with any Subcontractor to whom it provides PHI received from Covered Entity or created or received by Business Associate on behalf of Covered Entity in which the Subcontractor agrees to the same restrictions and conditions that apply through this Agreement to Business Associate with respect to such PHI. Business Associate must enter into this Business Associate Agreement before any use by or disclosure of PHI to such agent. The written agreement must identify Covered Entity as a direct and intended third party beneficiary with the right to enforce any breach of the agreement concerning the use or disclosure of PHI. Business Associate shall provide a copy of the Business Associate Agreement it enters into with a subcontractor to Covered Entity upon request. Business associate may not make any disclosure of PHI to any Subcontractor without prior written consent of Covered Entity.
Coordination with Workers' Compensation When an employee has incurred an on-the- job injury or an on-the-job disability and has filed a claim for workers' compensation, medical costs connected with the injury or disability shall be paid by the employee's health plan, pursuant to M.S. 176.191, Subdivision 3.
Separate Contracts The Owner reserves the right at any time and from time to time upon notice to Contractor to perform, or cause to be performed by other Contractors, other work at the Site in connection with the development of the Project that is not contemplated hereby or that is contemplated hereby if the Contractor and the Owner shall be unable to agree upon a Change Order incorporating such work as Work of the Contractor under this Contract. In either case, the Owner shall assure that such personnel or Contractors do not cause any conflict with the Work of Contractor. Contractor shall afford the Owner and other Contractors reasonable opportunity for the introduction, protection, and storage of material and equipment at the Site and the execution of work, and shall properly connect, if required by Contract Documents, and coordinate its work with theirs. If any work by the Owner or its other Contractors increases Contractor's costs or extends the time of performance, Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable costs actually incurred by Contractor as a result thereof and to an extension of time for performance for such reasonable time as the Design Professional shall determine. Contractor has no responsibility hereunder to certify the suitability or correctness of any work performed by Owner's own personnel or other Contractors under direct contract with the Owner. This Article also applies to installation of loose equipment and fixtures by the Owner, Using Agency, or a Separate Contractor.
Contractor Certification regarding Business with Certain Countries and Organizations Pursuant to Subchapter F, Chapter 2252, Texas Government Code], Contractor certifies Contractor is not engaged in business with Iran, Sudan, or a foreign terrorist organization. Contractor acknowledges this Agreement may be terminated and payment withheld if this certification is inaccurate.
SUB-CONTRACTORS Transfer Agent may, without further consent on the part of Customer, subcontract with other subcontractors for telephone and mailing services as may be required from time to time; provided, however, that the Transfer Agent shall be as fully responsible to the Customer for the acts and omissions of any subcontractor as it is for its own acts and omissions.
Contractor’s Employees B7.1 The Council reserves the right under the Contract to refuse to admit to, or to withdraw permission to remain on, any premises occupied by or on behalf of the Council:
