Engineer's Coordination with Owner. Engineer shall be available for conferences with City so that Project can be designed with the full benefit of City's experience and knowledge of existing needs and facilities and be consistent with current policies and construction standards. City shall make available to Engineer all existing plans, maps, field notes, and other data in its possession relative to the Project. Engineer may show justification to City for changes in design from City standards due to the judgment of said Engineer of a cost savings to City and/or due to the surrounding topo- graphic conditions. City shall make the final decision as to any changes after appropriate request by Engineer.
Engineer's Coordination with Owner. Engineer shall be available for conferences with City so that Project can be designed with the full benefit of City’s experience and knowledge of existing needs and facilities and be consistent with current policies and construction standards. City shall make available to Engineer all existing plans, maps, field notes, and other data in its possession relative to the Project. Engineer may show justification to City for changes in design from City standards due to the judgment of said Engineer of a cost savings to City and/or due to the surrounding topographic conditions. City shall make the final decision as to any changes after appropriate request by Engineer. Engineer shall accompany City representatives on Project observation visits during construction of Project at appropriate frequencies to ensure the project is progressing based on Engineer’s plans and specifications. City may require more frequent construction observation visits as construction problems arise as a result of Project design.
Engineer's Coordination with Owner. 13.1 The ENGINEER shall be available for conferences with OWNER so that SERVICES and work can be provided and completed with the full benefit of OWNER experience and knowledge of existing needs and facilities and be consistent with current policies and construction standards of the OWNER.
Engineer's Coordination with Owner. ENGINEER shall be available for conferences with CITY so that Project can be designed with the full benefit of CITY’S experience and knowledge of existing needs and facilities and be consistent with current policies and construction standards. CITY shall make available to ENGINEER all existing plans, maps, field notes, and other data in its possession relative to the Project. ENGINEER may show justification to CITY for changes in design from CITY standards due to the judgement of said ENGINEER of a cost savings to CITY and/or due to the surrounding topographic conditions. CITY shall make the final decision as to any changes after appropriate request by ENGINEER
Engineer's Coordination with Owner. ENGINEER shall hold periodic conferences with CITY, so that the LOMR can be prepared with the full benefit of CITY’s experience and knowledge of existing needs and facilities and be consistent with current policies. CITY shall make available to ENGINEER all existing plans, maps field notes, and other data in its possession relative to the Project. ENGINEER may show justification to CITY of changes from CITY standards due to the judgment of said ENGINEER of a cost savings to CITY and/or due to the surrounding topographic conditions. CITY shall make the final decision after appropriate approval as to any changes. ENGINEER is held responsible to CITY for any and all necessary revisions made to the documents due to errors or change in topographic conditions resulting from his delay in final document preparation.
Engineer's Coordination with Owner. Engineer shall be available for conferences with City so that Project can be designed with the full benefit of City's experience and knowledge of existing needs and facilities and be consistent with current policies and construction standards. City shall make available to Engineer all existing plans, maps, field notes, and other data in its possession relative to the Project. Engineer may show justification to City for changes in design from City standards due to the judgment of said Engineer. Engineer shall accompanyCity representatives on Project observation visits during construction of Project when design issues arise. City shall make the final decision as to any changes after appropriate request by Engineer. Engineer shall accompanyCity representatives on Project observation visits during construction of Project when design issues arise.
