Updated Appraisals For so long as the Loan remains outstanding, if any Event of Default shall occur hereunder, or if, in Lender’s judgment, a material depreciation in the value of the Land and/or the Improvements shall have occurred, then in any such event, Lender, may cause the Land and Improvements to be appraised by an appraiser selected by Lender, and in accordance with Lender’s appraisal guidelines and procedures then in effect, and Borrower agrees to cooperate in all respects with such appraisals and furnish to the appraisers all requested information regarding the Land and Improvements and the Facility. Borrower agrees to pay all reasonable costs incurred by Lender in connection with such appraisal which costs shall be secured by the Mortgage and shall accrue interest at the Default Rate until paid.
Amendment, Etc. of Material Contracts Cancel or terminate any Material Contract or consent to or accept any cancellation or termination thereof, amend or otherwise modify any Material Contract or give any consent, waiver or approval thereunder, waive any default under or breach of any Material Contract, agree in any manner to any other amendment, modification or change of any term or condition of any Material Contract or take any other action in connection with any Material Contract that would impair in any material respect the value of the interest or rights of any Loan Party thereunder or that would impair or otherwise adversely affect in any material respect the interest or rights, if any, of any Agent or any Lender Party, or permit any of its Subsidiaries to do any of the foregoing, in each case in a manner that could reasonably be expected to have a Material Adverse Effect, in each case taking into account the effect of any agreements that supplement or serve to substitute for, in whole or in part, such Material Contract.
Final Plans On or before thirty (30) days following the date of full execution of this Lease, Landlord shall submit to Tenant two (2) sets of Landlord’s proposed space and construction plans and specifications prepared by Landlord’s architect, for the Tenant Improvements, Within three (3) business days after receipt of Landlord’s plans and specifications Tenant shall either: (a) evidence its approval by endorsement on one (1) set of said plans and specifications (and return such signed or initialed set to Landlord); or (b) indicate those revisions or corrections which Tenant requires and the reasons therefor; provided Landlord shall not be obligated to accept any revisions which Landlord shall reasonably determine: (i) do not conform to the standards of design, motif and decor reasonably established or adopted by Landlord for the Building; (ii) would subject Landlord or the Premises to any additional cost, expense, liability, violation, fine, penalty, or forfeiture; would adversely affect the reputation, character, or nature of the Building; (iii) would provide for or require any installation of work which is or might be unlawful, create an unsound or dangerous condition, adversely affect the structural soundness of the Premises or Building; (iv) interfere with or abridge the use and enjoyment of any adjoining or other space in the Building, or (v) is of a special use or nature with little or no residual value (unless Tenant agrees to pay for such improvements and the removal thereof upon the expiration or earlier termination of this Lease). Landlord shall, within five (5) days thereafter, submit four (4) sets of proposed plans and specifications, as so revised or corrected, to Tenant for its approval in accordance with this paragraph, which plans will then be considered the final plans (the “Final Plans”). The Final Plans may subsequently be amended by Tenant provided that significant changes will require Landlord’s prior written approval, which approval shall be given or reasonably refused within five (5) business days after receipt of such amended plans and specifications and, provided further that if such change order will delay the anticipated Commencement Date specified in Section 1 of the Lease the change order shall be considered a Tenant Delay (as hereinafter defined). The parties will work cooperatively to complete the plan approval process expeditiously.
Notice of Commission Stop Orders The Company will advise the Agent, promptly after it receives notice or obtains knowledge thereof, of the issuance or threatened issuance by the Commission of any stop order suspending the effectiveness of the Registration Statement, of the suspension of the qualification of the Placement Shares for offering or sale in any jurisdiction, or of the initiation or threatening of any proceeding for any such purpose; and it will promptly use its commercially reasonable efforts to prevent the issuance of any stop order or to obtain its withdrawal if such a stop order should be issued. The Company will advise the Agent promptly after it receives any request by the Commission for any amendments to the Registration Statement or any amendment or supplements to the Prospectus or any Issuer Free Writing Prospectus or for additional information related to the offering of the Placement Shares or for additional information related to the Registration Statement, the Prospectus or any Issuer Free Writing Prospectus.
BACKGROUND STATEMENT The Borrower has requested that the Lenders make available to the Borrower a revolving credit facility in the aggregate principal amount of $100,000,000, subject to the availability provisions hereof. The Borrower will use the proceeds of these facilities as provided in Section 2.14. The Lenders are willing to make available to the Borrower the credit facilities described herein subject to and on the terms and conditions set forth in this Agreement.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2
Authorization, Approval, etc No authorization, approval, or other action by, and no notice to or filing with, any governmental authority, regulatory body or any other Person is required either
APPROVAL OF PLANS AND SPECIFICATIONS The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.
Construction Schedule 5.1 Coordination:
Effective Date, Term and Approval This Agreement shall become effective with respect to a Fund, if approved by the shareholders of such Fund, on the Effective Date for such Fund, as set forth in Appendix A attached hereto. If so approved, this Agreement shall thereafter continue in force and effect until June 30, 2001, and may be continued from year to year thereafter, provided that the continuation of the Agreement is specifically approved at least annually:
