Correction or reperformance Sample Clauses

Correction or reperformance. If contractor is required to correct or re- perform, it shall be at no cost to the City, and any materials or services corrected or re-performed by the contractor pursuant to this clause shall be subject to all provisions of this clause to the same extent as work initially performed. 7.2.1.1. Unless extended in writing by the Purchasing Agent, the Contractor shall undertake with due diligence to begin the repairs and/or replacements within ten (10) days after receiving written notice that such repairs or replacements are necessary and to complete the work as expeditiously as possible. If the Contractor should neglect to begin such repairs or replacements within this period, or, in case of emergency, where in the judgment of the Department Representative, delay would cause serious loss or damage, the repairs and/or replacements may be made by the City and charged to the Contractor. 7.2.1.2. If despite Contractor’s reasonable efforts, a non-conforming service cannot be reperformed, Contractor shall refund or credit monies paid by City for the non-conforming Service.
AutoNDA by SimpleDocs
Correction or reperformance. If the Contractor is required to correct or reperform, it shall be at no cost to the Authority, and any work corrected or reperformed by the Contractor shall be subject to this clause to the same extent as work initially performed. If the Contractor fails or refuses to correct or reperform, the Contracting Officer may, by contract or otherwise, correct or replace with similar services and charge to the Contractor the cost occasioned to the Authority thereby.
Correction or reperformance. If contractor is required to correct or re- perform, it shall be at no cost to the City, and any materials or services corrected or re-performed by the contractor pursuant to this clause shall be subject to all provisions of this clause to the same extent as work initially performed.

Related to Correction or reperformance

  • Correction of Errors Contractor shall perform, at its own cost and expense and without reimbursement from the District, any work necessary to correct errors or omissions which are caused by the Contractor’s failure to comply with the standard of care required herein.

  • Nonperformance As used in this Contract, “failure to perform” means failure, for whatever reason, to deliver goods and/or perform work as specified and scheduled in this Contract. If Contractor fails to perform under this Contract, then District, after giving seven days’ written notice and opportunity to cure to Contractor, has the right to complete the work itself, to obtain the contracted goods and/or services from other contractors, or a combination thereof, as necessary to complete the work. Both parties agree that Contractor shall bear any reasonable cost difference, as measured against any unpaid balance due Contractor, for these substitute goods or services.

  • Correction No corrections shall be made in the tender documents. Any corrections that are to be made shall be made by crossing the incorrect portion and writing the correct portions above with the initials of tenderer.

  • Product Performance Contractor hereby warrants and represents that the Products acquired by the Authorized User under the terms and conditions of this Contract conform to the specifications, performance standards and documentation in the Authorized User Agreement., and the documentation fully describes the proper procedure for using the Products. Contractor further warrants and represents that if the Products acquired by the Authorized User pursuant to an Authorized User Agreement under this Contract include software application development, software application customization, software programming, software integration or similar items (“Software Deliverables”) then such Software Deliverables shall be free from defects in material and workmanship and conform with all requirements of the Contract and Authorized User Agreement for the warranty period of one (1) year from the date of acceptance of the completed project (“Project warranty period”). Contractor also warrants that the Products, in the form provided to the Authorized User, do not infringe any copyright, trademark, trade secret or other right of any third party.

  • Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).

  • Error Correction If an error results from an act or omission of the Custodian in performing the services under this Agreement, the Custodian may take such remedial action as it considers appropriate under the circumstances, which may include effecting corrective transactions involving the Client’s assets, where and to the extent reasonably necessary to place the Client in the position (or its equivalent) it would have been had the error not occurred. The Custodian will be responsible for Losses arising from its errors in accordance with the terms of this Agreement and will be entitled to retain gains arising from its errors or related remedial actions unless otherwise prohibited by Law. Where an error results in a series of related Losses and gains, the Custodian will be entitled to net gains against Losses when permitted by Xxx. The Custodian will have no duty to notify or account to the Client for any Loss or gain associated with an error it has fully remediated.

  • Software Performance HP warrants that its branded software products will conform materially to their specifications and be free of malware at the time of delivery. HP warranties for software products will begin on the date of delivery and unless otherwise specified in Supporting Material, will last for ninety (90) days. HP does not warrant that the operation of software products will be uninterrupted or error-free or that software products will operate in hardware and software combinations other than as authorized by HP in Supporting Material.

  • Nonconforming Work 5.6.1 Rejection, Removal and Replacement of Nonconforming Work

  • Due Performance Each party to this Agreement undertakes the obligation that the other's expectation of receiving due performance will not be impaired. When reasonable grounds for insecurity arise with respect to the performance of either party, the other may, in writing, demand adequate assurance of due performance and until such written assurance is received may, if commercially reasonable, suspend any performance for which the agreed return has not been received.

  • CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby. 13.2.2 If, within one year after the Date of Substantial Completion of the Work or designated portion thereof or within one year after acceptance by the State of designated equipment or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be defective or not in accordance with the Contract Documents, the Contractor shall correct it promptly after receipt of a written notice from the State to do so unless the State has previously given the Contractor a written acceptance of such condition. This obligation shall survive termination of the Contract. The State shall give such notice promptly after discovery of the condition. 13.2.3 The Contractor shall remove from the site all portions of the Work which are defective or non-conforming and which have not been corrected under Subparagraphs 4.5.1, 13.2.1 and 13.2.4 If the Contractor fails to correct defective or nonconforming Work as provided in Subparagraphs 4.5.1, 13.2.1 and 13.2.2, the State may correct it in accordance with Paragraph 13.2.5 If the Contractor does not proceed with the correction of such defective or non- conforming Work within a reasonable time fixed by written notice from the Architect, the State may remove it and may store the materials or equipment at the expense of the Contractor. If the Contractor does not pay the cost of such removal and storage within ten days thereafter, the State may upon ten additional days written notice sell such Work at auction or at private sale and shall account for the net proceeds thereof, after deducting all the costs that should have been borne by the Contractor, including compensation for the Architect's and the State’s additional services and expenses made necessary thereby. If such proceeds of sale do not cover all costs which the Contractor should have borne, the difference shall be charged to the Contractor and an appropriate Change Order shall be issued. If the payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contractor shall pay the difference to the State. 13.2.6 The Contractor shall bear the cost of making good all work of the State or separate contractors destroyed or damaged by such correction or removal. 13.2.7 Nothing contained in this Paragraph 13.2 shall be construed to establish a period of limitation with respect to any other obligation which the Contractor might have under the

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!