CONTRACT ITEM CHANGES A. If a manufacturer discontinues a contracted item, that item will automatically be considered deleted from the contract with no penalty to Contractor. However, H-GAC may at its sole discretion elect to make a contract award to the next lowest Respondent for the item, or take any other action deemed by H-GAC, at its sole discretion, to be in the best interests of its Customers.
Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Housing.
Service Level Expectations Without limiting any other requirements of the Agreement, the Service Provider shall meet or exceed the following standards, policies, and guidelines:
Criminal History Category With regard to determining defendant’s criminal history points and criminal history category, based on the facts now known to the government, defendant’s criminal history points equal zero and defendant’s criminal history category is I.
Budget Categories Use the first column only (Column 1) to report the budget category breakouts (Lines 6a through 6h) and indirect charges (Line 6j) for the total funding requested for the first year of your project only.
Service Changes PBI may modify its Service by giving written notice to you (a “Service Change Notice”), which will state whether the change is material. After receiving a Service Change Notice, if the change is material, you may terminate Service by giving us a termination notice at the address indicated in Section 21 or you may create a case at xxxxxxxxxxx.xxx/xx/xxxxxxx-xx.xxxx (follow the instructions under “how to create a case”).
Rental Rates and Wage Rates for Change Orders As soon as is practical, but prior to the completion of the Construction Preparation Period and in any event prior to the commencement of any Work on the Site, the Contractor shall submit in accordance with the style and format of a specimen to be furnished by the Owner for consideration of the Owner the following: (1) a proposal for rental rates on heavy construction equipment that shall apply in the event Change Order Work is performed, and (2) a proposal for wage rates for the types of project labor that shall apply in the event of the execution of any Change Order Work. Under penalty of false swearing, a principal of the contracting firm shall certify that the proposal for rental rates and proposal for wage rates do not exceed current costs for like services. The Owner will in no event consider a rental rate in excess of eighty percent of the rate set forth in the latest edition of the "Compilation of Nationally Averaged Rental Rates for Construction Equipment" of the Associated Equipment Distributors unless the rates proposed in excess of eighty percent are supported by proof satisfactory to the Owner that the excess rates are reasonable. If the equipment is owned by the Contractor the costs shall be charged at a maximum of eighty percent of market monthly rental rates for the amount of time used. If applicable, transportation costs may be included. The decision of the Owner shall be final, binding and conclusive on all parties. Rental rates shall be payable only for the actual time the equipment is required on the Site.
Service Rates The rates for services provided to a specific child by the Provider shall be set forth in the PSO for the child. The Provider may not increase the rate for any service described in a PSO during the term of the PSO unless the PSO provides for an automatic rate increase option, in which case the rate may only be increased in the initial month of the Buyer’s fiscal year and must be agreed to in writing by the Buyer. The provider is required to have all services and rate information entered and up-to-date in the Service Fee Directory by the beginning of the contract year. The Provider shall provide to the Buyer written notice of any planned rate increase (90 days) prior to the initial month of the Buyer’s next fiscal year. Such written notice shall contain the justification for the increase and shall be submitted in triplicate to the Buyer’s Children’s Services Act Manager.
Offense Level Calculations i. The base offense level is 7, pursuant to Guideline § 2B1.1(a)(1).
Change in Scope of Work Any change in the scope of the Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition, or deletion is approved in advance and in writing by a valid change order executed by the District. Contractor specifically understands, acknowledges, and agrees that the District shall have the right to request any alterations, deviations, reductions, or additions to the Project or Work, and the cost thereof shall be added to or deducted from the amount of the Contract Price by fair and reasonable valuations. Contractor also agrees to provide the District with all information requested to substantiate the cost of the change order and to inform the District whether the Work will be done by the Contractor or a subcontractor. In addition to any other information requested, Contractor shall submit, prior to approval of the change order, its request for a time extension (if any), as well as all information necessary to substantiate its belief that such change will delay the completion of the Work. If Contractor fails to submit its request for a time extension or the necessary supporting information, it shall be deemed to have waived its right to request such extension.
