Customer’s Obligations The Customer shall:
(a) provide the Supplier with:
(i) all necessary co-operation in relation to this agreement; and
(ii) all necessary access to such information as may be required by the Supplier; in order to render the Services, including but not limited to Customer Data, security access information and configuration services;
(b) comply with all applicable laws and regulations with respect to its activities under this agreement;
(c) carry out all other Customer responsibilities set out in this agreement in a timely and efficient manner. In the event of any delays in the Customer's provision of such assistance as agreed by the parties, the Supplier may adjust any agreed timetable or delivery schedule as reasonably necessary;
(d) ensure that the Authorised Users use the Services and the Documentation in accordance with the terms and conditions of this agreement and shall be responsible for any Authorised User’s breach of this agreement;
(e) obtain and shall maintain all necessary licences, consents, and permissions necessary for the Supplier, its contractors and agents to perform their obligations under this agreement, including without limitation the Services;
(f) ensure that its network and systems comply with the relevant specifications provided by the Supplier from time to time; and
(g) be solely responsible for procuring and maintaining its network connections and telecommunications links from its systems to the Supplier’s data centres, and all problems, conditions, delays, delivery failures and all other loss or damage arising from or relating to the Customer's network connections or telecommunications links or caused by the internet.
SUPPLIER’S OBLIGATIONS 4.2.1 The Supplier shall be responsible for implementing all the necessary resources for the performance of its obligations under the Contract, with the exception of those specifically mentionedin the Contractas beingunder the responsibility of the Purchaser. The Supplier shall haveall of thematerials andtoolsneededfor theperformanceof the Contractandshall allocate qualified staff in sufficient numbers to perform the Contract within the contractual deadline. The Supplier shall ensureappropriatepersonneltraining andqualification andsubmitanyproof relating to such qualification upon Purchaser’s request. Within seven (7) days, at the latest, of the Contract coming into force, the Supplier shall appoint a staff member as aprojectmanager and shall inform the Purchaser accordingly. The project manager shall plan, coordinate and monitor all the Supply’sneedsin compliancewith the Contractandthe Good Industry Practices andshall be the Supplier’s contact person for the Purchaser.
4.2.2 The Supplier shall request from the Purchaser in a timely manner, any approvals and instructions needed for the correct performance of the Contract. If applicable, the Purchaser shall grant access to the site where the Supply is to be performed (the “Site”) and /or make available to the Supplier the materials and/or perform the works identified in the Contract.
4.2.3 The Supplier shall promptly remedy or shall ensure that its subcontractors promptly remedy any defects relating to the Supply noted during the abovementioned visits as well as any defect notified to it by the Purchaser concerning its performance.
4.2.4 The Supplier shall ensure that the Supply provided are fit for the purposes that may reasonablybeinferred from the Contractandinaccordancewith the timetableforperformance defined in the Contract. In any event the Supplier commitshimself toachieveperformance and results stipulated in the Contract. The performance deadlinesmay only be extended or reduced through an amendment to the Contract, in accordance with the provisions of Article
5.1. The Supply shall be delivered in a state of full completion with the complete Documentation associated therewith as well as all instructions, recommendations and other indications necessary in order for them to be used correctly and under the appropriate safety conditions. “Documentation” shall mean any operation and maintenance manuals, drawings, calculations, technical data, logic diagrams, progress reports, quality documentation, conformity certificates, test reports, bill of lading, certificates of origin, export control classification list number as per any applicable export regulation - such as (i) the European Council Regulation 428/2009 (as amended), (ii) the U.S. Export Administration Regulations (“EAR”), (iii) percentage of U.S. origin content, (iv) U.S. Export Control Classification Number (“ECCN”), (v) U.S. Munitions List category (“USML”),(vi) (if applicable) export authorizations and licenses, and/or (vii) Harmonized Tariff Code - and any such other documents required under the Contract and/or applicable laws. The Supplier shall also furnish such programme of design, manufacture and delivery as the Purchaser may reasonably require. If so required by the Purchaser, the Supplier shall submit any such Documentation to the Purchaser with sufficient time for review and approval. Where the Documentation provided by the Supplier is not compliant with Purchaser’s contractual requirements, the Supplier must make the necessary modifications, and indemnify the Purchaser for any costs, liabilities or penalties incurred by the Purchaser due to the delays or non-compliance in Documentation delivered by the Supplier and shall not be entitled to an adjustment of the delivery schedule in case of any revision.
THE CUSTOMER’S OBLIGATIONS (1) The Customer must maintain procedures relating to a withdrawal of the goods, recall and tampering and records necessary to support a recall of the goods, and allow the Supplier to inspect such procedures and records at any time on reasonable notice.
(2) The Customer must provide any services, resources or facilities to the Supplier as may be reasonably required in respect of a recall of the goods.
(3) The Supplier agrees to refund or provide credit to the Customer for any units of the goods that are recalled under this clause unless the conduct of the Customer or its employees, contractors or other persons it has engaged has given rise to the recall of the goods.
The Supplier's Obligations The Supplier will in writing, by the time and date specified by the Contracting Body in accordance with paragraph 3.1.3(b) provide the Contracting Body with either:
3.2.1 a statement to the effect that it does not wish to tender in relation to the relevant Service Requirements; or
3.2.2 the Statement of Work and full details of its tender made in respect of the relevant Statement of Requirements. In the event that the Supplier submits a Statement of Work, it should include, as a minimum:
a) an email response subject line to comprise unique reference number and Supplier name, so as to clearly identify the Supplier;
b) a brief summary, in the email (followed by a confirmation letter), stating whether or not the Supplier is bidding for the Statement of Requirements;
c) a proposal covering the Services Requirements; and
d) confirmation of discounts applicable to the work, as referenced in Framework Agreement Schedule 3 (Charging Structure).
3.2.3 The Supplier shall ensure that any prices submitted in relation to a further competition held pursuant to this paragraph 3 shall be based on the Charging Structure and take into account any discount to which the Contracting Body may be entitled as set out in Framework Agreement Schedule 3 (Charging Structure).
3.2.4 The Supplier agrees that:
a) all tenders submitted by the Supplier in relation to a further competition held pursuant to this paragraph 3 shall remain open for acceptance by the Contracting Body for ninety (90) Working Days (or such other period specified in the invitation to tender issued by the relevant Contracting Body in accordance with the Ordering Procedure); and
b) all tenders submitted by the Supplier are made and will be made in good faith and that the Supplier has not and will not fix(ed) or adjust(ed) the amount of the offer by or in accordance with any agreement or arrangement with any other person. The Supplier certifies that it has not and undertakes that it will not:
(a) communicate to any person other than the person inviting these offers the amount or approximate amount of the offer, except where the disclosure, in confidence, of the approximate amount of the offer was necessary to obtain quotations required for the preparation of the offer; and
(b) enter into any arrangement or agreement with any other person that he or the other person(s) shall refrain from making an offer or as to the amount of any offer to be submitted.
HIRER’S OBLIGATIONS a) The Hirer acknowledges having received the Vehicle in a clean condition, with a full fuel tank and full bottle of gas (if applicable). The Hirer will return the Vehicle in a clean condition with a full fuel tank and a full bottle of gas (if applicable, and subject to any pre-purchase fuel and/or pre- purchase gas option being taken), on the Return Date at the time and at the Return Point set out in the Rental Agreement.
b) The Hirer must ensure that all reasonable care is taken in handling and parking the Vehicle and that it is left securely locked when not in use.
c) The Hirer must ensure that the recommended levels are maintained with respect to the water in the radiator and battery, the oil and the tyre pressures of the Vehicle.
d) Smoking and/or animals (excluding registered guide or assistance dogs) are not permitted in the Vehicle at any time. If this condition is breached, the Hirer must pay to JUCY a cleaning fee determined by JUCY in its reasonable opinion and being not more than $250.
e) The Hirer must ensure that all Authorised Drivers comply with, and all Authorised Drivers shall be bound by, these terms and conditions and all Authorised Drivers must carry their driver’s licence with them when driving the Vehicle.
f) In the event of any new damage to the Vehicle, the Hirer must notify JUCY of the full circumstances of the damage as soon as practicable (being not more than 48 hours) from the time the Hirer has knowledge of the damage.
g) If there is an equipment defect or mechanical failure of the Vehicle during the Term of Hire, the Hirer must notify JUCY as soon as practicable, and in any event within 48 hours, from the time the Hirer has knowledge of the defect or failure to give JUCY the opportunity to rectify the problem during the Term of Hire. JUCY does not accept liability for any claims submitted after this period.
h) The Hirer must ensure that a copy of this Agreement is kept in the Vehicle throughout the Term of Hire and produced without delay for inspection on demand by an enforcement officer
i) The Hirer shall not:
i) drive or use the Vehicle (or permit the Vehicle to be driven or used) otherwise than in a prudent and cautious manner. For the purposes of these terms and conditions, a single Vehicle rollover shall be considered a breach of this clause 6(i) unless the Stress Free Plus excess reduction has been taken out;
Developer’s Obligations 7.1.1 In consideration of the Rights hereby granted, the Developer shall pay to the Authority an annual fee of Rs. /- (Rupees only) (“Fee”) commencing from the 1st (first) anniversary of Appointed Date. The Fee is exclusive of GST and all other applicable taxes and shall be payable by the Developer at actual over and above the Fee. The Fee is payable to the Authority on or before 30 (thirty) days prior to the start of every year in advance as set out in Schedule 1 throughout the Agreement Period. During the Agreement Period the Fee shall be increased by 5% (five percent) every year over the previous year’s Fee on compounded basis.
7.1.2 The Developer should pay the Fee to the Authority notwithstanding the fact that, the development of Project Facilities is not completed within the specified period or Developer does not start the commercial operation of the Project. In other words, the Developer shall not be entitled to seek any reduction of Fee, claim, damages, compensation or any other consideration from the Authority on account of any reason.
7.1.3 Any delay in payment of the Fee shall attract an interest for the delayed period at the rate of SBI PLR plus 5% per annum on the outstanding amount, which shall be due from the date of such payment till the amount is realized by the Authority. In addition to the foregoing, any delay in payment of Fee beyond a period of 60 (sixty) days from the due date of such payment will be construed to be Material Breach under this Agreement.
Conditions Precedent to Buyer’s Obligations Each and every obligation of Buyer to be performed on the Closing Date shall be subject to the satisfaction prior to or at the Closing of each of the following conditions:
Conditions to Buyer’s Obligations The obligations of Buyer to consummate the transactions provided for hereby are subject, in the discretion of Buyer, to the satisfaction, on or prior to the Closing Date, of each of the following conditions, any of which may be waived by Buyer:
Conditions to Buyer’s Obligation The obligation of Buyer to consummate the transactions to be performed by it in connection with the Closing is subject to satisfaction of the following conditions:
(i) this Agreement and the Merger shall have received the Requisite Target Stockholder Approval;
(ii) the representations and warranties set forth in Section 4 above shall be true and correct in all material respects at and as of the Closing Date, except to the extent that such representations and warranties are qualified by the term "material," or contain terms such as "Material Adverse Effect" or "Material Adverse Change," in which case such representations and warranties (as so written, including the term material or Material) shall be true and correct in all respects at and as of the Closing Date;
(iii) Target shall have performed and complied with all of its covenants hereunder in all material respects through the Closing, except to the extent that such covenants are qualified by the term "material," or contain terms such as "Material Adverse Effect" or "Material Adverse Change," in which case Target shall have performed and complied with all of such covenants (as so written, including the term "material" or "Material") in all respects through the Closing;
(iv) no action, suit, or proceeding shall be pending or threatened before any court or quasi-judicial or administrative agency of any federal, state, local, or foreign jurisdiction or before any arbitrator wherein an unfavorable injunction, judgment, order, decree, ruling, or charge would (A) prevent consummation of any of the transactions contemplated by this Agreement, (B) cause any of the transactions contemplated by this Agreement to be rescinded following consummation, (C) adversely affect the right of Surviving Corporation to own the former assets, to operate the former business, and to control the former Subsidiaries of Buyer, or (D) adversely affect the right of any of the former Subsidiaries of Buyer to own its assets and to operate its business (and no such injunction, judgment, order, decree, ruling, or charge shall be in effect);
(v) Target shall have delivered to Buyer a certificate to the effect that each of the conditions specified above in 6(b)(i)-(iv) is satisfied in all respects;
(vi) this Agreement and the Merger shall have received the Requisite Buyer Stockholder Approval;
(vii) all actions to be taken by Target in connection with consummation of the transactions contemplated hereby and all certificates, opinions, instruments, and other documents required to effect the transactions contemplated hereby will be reasonably satisfactory in form and substance to Buyer. Buyer may waive any condition specified in this Section 6(b) if it executes a writing so stating at or prior to the Closing.
Conditions Precedent to Seller’s Obligations The obligation of the Sellers to consummate the transfer of the Transferred Assets to the Buyer on the Closing Date is subject to the satisfaction (or waiver by the Sellers) as of the Closing of the following conditions:
(a) Each of the representations and warranties made by the Buyer in this Agreement shall be true and correct in all respects as of the Closing Date as though such representations and warranties were made on and as of the Closing Date (except to the extent such representations and warranties relate to a specific date, in which case, such representations and warranties shall be true and correct in all respects as of such specific date), except for breaches or inaccuracies that would not reasonably be expected to have a material adverse effect on the Buyer or impair or delay the ability of the Buyer to consummate the transactions contemplated by this Agreement or the Closing Documents or otherwise perform its obligations under this Agreement or the Closing Documents;
(b) The Buyer shall have performed or complied in all material respects with each obligation and covenant required by this Agreement to be performed or complied with by the Buyer on or before the Closing.
(c) The Sellers shall have received all of the applicable documents required to be delivered by the Buyer under Article VI;
(d) No order or injunction of any court or administrative agency of competent jurisdiction nor any statute, rule, regulation or executive order promulgated by any Governmental Authority of competent jurisdiction shall be in effect as of the Closing that restrains or prohibits the transfer of the Transferred Assets or the consummation of any other transaction contemplated hereby; and
(e) No action, suit or other proceeding shall have been commenced against Buyer or any Seller that would reasonably be expected to prevent the Closing.
